REGULATIONS
Vol. 29 Iss. 3 - October 08, 2012

TITLE 18. PROFESSIONAL AND OCCUPATIONAL LICENSING
BOARD FOR CONTRACTORS
Chapter 22
Final Regulation

Title of Regulation: 18VAC50-22. Board for Contractors Regulations (amending 18VAC50-22-10 through 18VAC50-22-70, 18VAC50-22-210, 18VAC50-22-230, 18VAC50-22-260).

Statutory Authority: §§ 54.1-201 and 54.1-1102 of the Code of Virginia.

Effective Date: December 1, 2012.

Agency Contact: Eric L. Olson, Executive Director, Board for Contractors, 9960 Mayland Drive, Suite 400, Richmond, VA 23233, telephone (804) 367-2785, FAX (804) 527-4401, or email contractors@dpor.virginia.gov.

Summary:

The Board of Contractors is amending its regulations to account for several statutory changes, clarify current requirements, and respond to changes in affected industries. Specifically, the amendments:

1. Separate the current manufactured/modular home contractor specialty license into two licenses: one for manufactured home contractors and one for industrial building (modular home) contractors;

2. Require applicants for a specialty classification to pass a qualifying exam;

3. Amend the requirements for licensure by reciprocity to allow individuals to gain licensure in Virginia if they were originally licensed in a state with licensure eligibility criteria that are substantially equivalent to Virginia; and

4. Require legal business entities that dissolve and reform under another business name to return their old, invalid, license to the board within 30 days of the change.

The proposed increase in the net worth or equity that firms must prove to qualify for licensure as Class B or Class A contractors was removed from the final regulation leaving the current requirement in place.

Summary of Public Comments and Agency's Response: A summary of comments made by the public and the agency's response may be obtained from the promulgating agency or viewed at the office of the Registrar of Regulations.

Part I
Definitions

18VAC50-22-10. General definitions.

The following words and terms when used in this chapter, unless a different meaning is provided or is plainly required by the context, shall have the following meanings:

"Address of record" means the mailing address designated by the licensee to receive notices and correspondence from the board.

"Affidavit" means a written statement of facts, made voluntarily, and confirmed by the oath or affirmation of the party making it, taken before a notary or other person having the authority to administer such oath or affirmation.

"Business entity" means a sole proprietorship, partnership, corporation, limited liability company, limited liability partnership, or any other form of organization permitted by law.

"Change order" means any modification to the original contract including, but not limited to, the time to complete the work, change in materials, change in cost, and change in the scope of work.

"Controlling financial interest" means the direct or indirect ownership or control of more than 50% ownership of a firm.

"Firm" means any business entity recognized under the laws of the Commonwealth of Virginia.

"Formal vocational training" means courses in the trade administered at an accredited educational facility; or formal training, approved by the department, conducted by trade associations, businesses, military, correspondence schools or other similar training organizations.

"Full-time employee" means an employee who spends a minimum of 30 hours a week carrying out the work of the licensed contracting business.

"Helper" or "laborer" means a person who assists a licensed tradesman and who is not an apprentice as defined in 18VAC50-30-10.

"Licensee" means a firm holding a license issued by the Board for Contractors to act as a contractor, as defined in § 54.1-1100 of the Code of Virginia.

"Net worth" means assets minus liabilities. For purposes of this chapter, assets shall not include any property owned as tenants by the entirety.

"Prime contractor" means a licensed contractor that performs, supervises, or manages the construction, removal, repair, or improvement of real property pursuant to the terms of a primary contract with the property owner/lessee. The prime contractor may use its own employees to perform the work or use the services of other properly licensed contractors.

"Principal place of business" means the location where the licensee principally conducts business with the public.

"Reciprocity" means an arrangement by which the licensees of two states are allowed to practice within each other's boundaries by mutual agreement.

"Reinstatement" means having a license restored to effectiveness after the expiration date has passed.

"Renewal" means continuing the effectiveness of a license for another period of time.

"Responsible management" means the following individuals:

1. The sole proprietor of a sole proprietorship;

2. The partners of a general partnership;

3. The managing partners of a limited partnership;

4. The officers of a corporation;

5. The managers of a limited liability company;

6. The officers or directors of an association or both; and

7. Individuals in other business entities recognized under the laws of the Commonwealth as having a fiduciary responsibility to the firm.

"Sole proprietor" means any individual, not a corporation, who is trading under his own name, or under an assumed or fictitious name pursuant to the provisions of §§ 59.1-69 through 59.1-76 of the Code of Virginia.

"Supervision" means providing guidance or direction of a delegated task or procedure by a tradesman licensed in accordance with Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia, being accessible to the helper or laborer, and periodically observing and evaluating the performance of the task or procedure.

"Supervisor" means the licensed master or journeyman tradesman who has the responsibility to ensure that the installation is in accordance with the applicable provisions of the Virginia Uniform Statewide Building Code and provides supervision to helpers and laborers as defined in this chapter.

"Tenants by the entirety" means a tenancy which is created between a husband and wife and by which together they hold title to the whole with right of survivorship so that, upon death of either, the other takes whole to exclusion of the deceased's remaining heirs.

"Virginia Uniform Statewide Building Code" or "USBC" means building regulations comprised of those promulgated by the Virginia Board of Housing and Community Development in accordance with § 36-98 of the Code of Virginia, including any model codes and standards that are incorporated by reference and that regulate construction, reconstruction, alteration, conversion, repair, maintenance or use of structures, and building and installation of equipment therein.

18VAC50-22-20. Definitions of license classifications.

The following words and terms when used in this chapter unless a different meaning is provided or is plainly required by the context shall have the following meanings:

"Building contractors" (Abbr: BLD) means those individuals whose contracts include construction on real property owned, controlled or leased by another person of commercial, industrial, institutional, governmental, residential (single-family, two-family or multifamily) and accessory use buildings or structures. This classification also provides for remodeling, repair, improvement or demolition of these buildings and structures. A holder of this license can do general contracting.

If the BLD contractor performs specialty services other than those listed below, all required specialty designations shall be obtained. The BLD contractor may act as a prime contractor and contract with subcontractors to perform work not permitted by the BLD license. The building classification includes but is not limited to the functions carried out by the following specialties:

Billboard/sign contracting

Commercial improvement contracting

Concrete contracting

Farm improvement contracting

Home improvement contracting

Industrialized building contracting

Landscape service contracting

Marine facility contracting

Masonry contracting

Modular manufactured building contracting

Recreational facility contracting

Roofing contracting

"Electrical contractors" (Abbr: ELE) means those individuals whose contracts include the construction, repair, maintenance, alteration, or removal of electrical systems under the National Electrical Code. This classification provides for all work covered by the National Electrical Code electrical provisions of the USBC including electrical work covered by the alarm/security systems contracting (ALS), electronic/communication service contracting (ESC) and fire alarm systems contracting (FAS) specialties. A firm holding an electrical ELE license is responsible for meeting all applicable tradesman licensing standards individual license and certification regulations.

"Highway/heavy contractors" (Abbr: H/H) means those individuals whose contracts include construction, repair, improvement, or demolition of the following:

Bridges

Dams

Drainage systems

Foundations

Parking lots

Public transit systems

Rail roads

Roads

Runways

Streets

Structural signs & lights

Tanks

The functions carried out by these contractors include but are not limited to the following:

Building demolition

Clearing

Concrete work

Excavating

Grading

Nonwater well drilling

Paving

Pile driving

Road marking

Steel erection

These contractors also install, maintain, or dismantle the following:

1. Power systems for the generation and primary and secondary distribution of electric current ahead of the customer's meter;

2. Pumping stations and treatment plants;

3. Telephone, telegraph, or signal systems for public utilities; and

4. Water, gas, and sewer connections to residential, commercial, and industrial sites, subject to local ordinances.

This classification may also install backflow prevention devices incidental to work in this classification when the installer has received formal vocational training approved by the board that included instruction in the installation of backflow prevention devices.

"HVAC contractors" (Abbr: HVA) means those individuals whose work includes the installation, alteration, repair, or maintenance of heating systems, ventilating systems, cooling systems, steam and hot water heaters, heating systems, boilers, process piping, and mechanical refrigeration systems, including tanks incidental to the system. This classification does not provide for fire suppression installations, sprinkler system installations, or gas piping. A firm holding a HVAC license is responsible for meeting all applicable tradesman licensure standards individual license and certification regulations. This classification may install backflow prevention devices incidental to work in this classification.

"Plumbing contractors" (Abbr: PLB) means those individuals whose contracts include the installation, maintenance, extension, or alteration, or removal of all piping, fixtures, appliances, and appurtenances in connection with any of the following:

Backflow prevention devices

Boilers

Hot water baseboard heating systems

Hot water heaters

Hydronic systems

Limited area sprinklers (as defined by BOCA) the USBC)

Process piping

Public/private water supply systems within or adjacent to any building, structure or conveyance

Sanitary or storm drainage facilities

Steam heating systems

Storage tanks incidental to the installation of related systems

Venting systems related to plumbing

These contractors also install, maintain, extend or alter the following:

Liquid waste systems

Sewerage systems

Storm water systems

Water supply systems

This classification does not provide for gas piping or the function of fire sprinkler contracting as noted above. A firm holding a plumbing PLB license is responsible for meeting all applicable tradesman licensure standards individual license and certification regulations. The classification may install sprinkler systems permitted to be designed in accordance with the plumbing provisions of the USBC when the installer has received formal vocational training approved by the board that included instruction of installation of sprinkler systems.

"Specialty contractors" means those individuals whose contracts are for specialty services which do not generally fall within the scope of any other classification within this chapter.

18VAC50-22-30. Definitions of specialty services.

The following words and terms when used in this chapter unless a different meaning is provided or is plainly required by the context shall have the following meanings:

"Alternative energy system contracting" (Abbr: AES) means that service which provides for the installation, repair or improvement, from the customer's meter, of alternative energy generation systems, supplemental energy systems and associated equipment annexed to real property. This service does not include the installation of emergency generators powered by fossil fuels. No other classification or specialty service provides this function. This specialty does not provide for electrical, plumbing, gas fitting, or HVAC functions.

"Asbestos contracting" (Abbr: ASB) means that service which provides for the installation, removal, or encapsulation of asbestos containing materials annexed to real property. No other classification or specialty service provides for this function.

"Asphalt paving and sealcoating contracting" (Abbr: PAV) means that service which provides for the installation of asphalt paving and/or sealcoating on subdivision streets and adjacent intersections, driveways, parking lots, tennis courts, running tracks, and play areas, using materials and accessories common to the industry. This includes height adjustment of existing sewer manholes, storm drains, water valves, sewer cleanouts and drain grates, and all necessary excavation and grading. The H/H classification also provides for this function.

"Billboard/sign contracting" (Abbr: BSC) means that service which provides for the installation, repair, improvement, or dismantling of any billboard or structural sign permanently annexed to real property. H/H and BLD are the only other classifications that can perform this work except that a contractor in this specialty may connect or disconnect signs to existing electrical circuits. No trade related plumbing, electrical, or HVAC work is included in this function.

"Blast/explosive contracting" (Abbr: BEC) means that service which provides for the use of explosive charges for the repair, improvement, alteration, or demolition of any real property or any structure annexed to real property.

"Commercial improvement contracting" (Abbr: CIC) means that service which provides for repair or improvement to nonresidential property and multifamily property as defined in the Virginia Uniform Statewide Building Code. The BLD classification also provides for this function. The CIC classification does not provide for the construction of new buildings, accessory buildings, electrical, plumbing, HVAC, or gas work.

"Concrete contracting" (Abbr: CEM) means that service which provides for all work in connection with the processing, proportioning, batching, mixing, conveying and placing of concrete composed of materials common to the concrete industry. This includes but is not limited to finishing, coloring, curing, repairing, testing, sawing, grinding, grouting, placing of film barriers, sealing and waterproofing. Construction and assembling of forms, molds, slipforms, pans, centering, and the use of rebar is also included. The BLD and H/H classifications also provide for this function.

"Electronic/communication service contracting" (Abbr: ESC) means that service which provides for the installation, repair, improvement, or removal of electronic or communications systems annexed to real property including telephone wiring, computer cabling, sound systems, data links, data and network installation, television and cable TV wiring, antenna wiring, and fiber optics installation, all of which operate at 50 volts or less. A firm holding an ESC license is responsible for meeting all applicable tradesman licensure standards. The ELE classification also provides for this function.

"Elevator/escalator contracting" (Abbr: EEC) means that service which provides for the installation, repair, improvement or removal of elevators or escalators permanently annexed to real property. A firm holding an EEC license is responsible for meeting all applicable tradesman licensure standards individual license and certification regulations. No other classification or specialty service provides for this function.

"Environmental monitoring well contracting" (Abbr: EMW) means that service which provides for the construction of a well to monitor hazardous substances in the ground.

"Environmental specialties contracting" (Abbr: ENV) means that service which provides for installation, repair, removal, or improvement of pollution control and remediation devices. No other specialty provides for this function. This specialty does not provide for electrical, plumbing, gas fitting, or HVAC functions.

"Equipment/machinery contracting" (Abbr: EMC) means that service which provides for the installation or removal of equipment or machinery including but not limited to conveyors or heavy machinery. Boilers exempted by the Virginia Uniform Statewide Building Code but regulated by the Department of Labor and Industry are also included in this specialty. This specialty does not provide for any electrical, plumbing, process piping or HVAC functions.

"Farm improvement contracting" (Abbr: FIC) means that service which provides for the installation, repair or improvement of a nonresidential farm building or structure, or nonresidential farm accessory-use structure, or additions thereto. The BLD classification also provides for this function. The FIC specialty does not provide for any electrical, plumbing, HVAC, or gas fitting functions.

"Fire alarm systems contracting" (Abbr: FAS) means that service which provides for the installation, repair, or improvement of fire alarm systems which operate at 50 volts or less. The ELE classification also provides for this function. A firm with an FAS license is responsible for meeting all applicable tradesman licensure standards.

"Fire sprinkler contracting" (Abbr: SPR) means that service which provides for the installation, repair, alteration, addition, testing, maintenance, inspection, improvement, or removal of sprinkler systems using water as a means of fire suppression when annexed to real property. This specialty does not provide for the installation, repair, or maintenance of other types of fire suppression systems. The PLB classification allows for the installation of limited area sprinklers as defined by BOCA systems permitted to be designed in accordance with the plumbing provisions of the USBC. This specialty may engage in the installation of backflow prevention devices in the fire sprinkler supply main and incidental to the sprinkler system installation when the installer has received formal vocational training approved by the board that included instruction in the installation of backflow prevention devices.

"Fire suppression contracting" (Abbr: FSP) means that service which provides for the installation, repair, improvement, or removal of fire suppression systems including but not limited to halon and other gas systems; dry chemical systems; and carbon dioxide systems annexed to real property. No other classification provides for this function. The FSP specialty does not provide for the installation, repair, or maintenance of water sprinkler systems.

"Gas fitting contracting" (Abbr: GFC) means that service which provides for the installation, repair, improvement, or removal of gas piping and appliances annexed to real property. A firm with holding a GFC license is responsible for meeting all applicable tradesman individual (tradesman) licensure standards regulations.

"Home improvement contracting" (Abbr: HIC) means that service which provides for repairs or improvements to one-family and two-family residential buildings or structures annexed to real property. The BLD classification also provides for this function. The HIC specialty does not provide for electrical, plumbing, HVAC, or gas fitting functions. It does not include high rise buildings, buildings with more than two dwelling units, or new construction functions beyond the existing building structure other than decks, patios, driveways and utility out buildings.

"Industrial building contracting" (Abbr: IBC) means that service that provides for the installation or removal of an industrialized building as defined in the Virginia Industrialized Building Safety Regulations. This classification covers foundation work in accordance with the provisions of the USBC and allows the licensee to complete internal tie-ins of plumbing, gas, electrical, and HVAC systems. It does not allow for installing additional plumbing, gas, electrical, or HVAC work such as installing the service meter, or installing the outside compressor for the HVAC system. The BLD classification also provides for this function.

"Landscape irrigation contracting" (Abbr: ISC) means that service which provides for the installation, repair, improvement, or removal of irrigation sprinkler systems or outdoor sprinkler systems. The PLB and H/H classifications also provide for this function. This specialty may install backflow prevention devices incidental to work in this specialty when the installer has received formal vocational training approved by the board that included instruction in the installation of backflow prevention devices.

"Landscape service contracting" (Abbr: LSC) means that service which provides for the alteration or improvement of a land area not related to any other classification or service activity by means of excavation, clearing, grading, construction of retaining walls for landscaping purposes, or placement of landscaping timbers. This specialty may remove stumbs and roots below grade. The BLD classification and H/H classifications also provides provide for this function.

"Lead abatement contracting" (Abbr: LAC) means that service which provides for the removal or encapsulation of lead-containing materials annexed to real property. No other classification or specialty service provides for this function, except that the PLB and HVA classifications may provide this service incidental to work in those classifications.

"Liquefied petroleum gas contracting" (Abbr: LPG) means that service which includes the installation, maintenance, extension, alteration, or removal of all piping, fixtures, appliances, and appurtenances used in transporting, storing or utilizing liquefied petroleum gas. This excludes hot water heaters, boilers, and central heating systems that require a HVA or PLB license. The GFC specialty also provides for this function. A firm holding a LPG license is responsible for meeting all applicable tradesman licensure standards individual license and certification regulations.

"Manufactured home contracting" (Abbr: MHC) means that service that provides for the installation or removal of a manufactured home as defined in the Virginia Manufactured Home Safety Regulations. This classification does not cover foundation work; however, it does allow installation of piers covered under HUD regulations. It does allow a licensee to do internal tie-ins of plumbing, gas, electrical, or HVAC equipment. It does not allow for installing additional plumbing, gas, electrical, or HVAC work such as installing the service meter, or installing the outside compressor for the HVAC system. The H/H and BLD classifications also provide for this function.

"Marine facility contracting" (Abbr: MCC) means that service which provides for the construction, repair, improvement, or removal of any structure the purpose of which is to provide access to, impede, or alter a body of surface water. The BLD and H/H classifications also provide for this function. The MCC specialty does not provide for the construction of accessory structures or electrical, HVAC or plumbing functions.

"Masonry contracting" (Abbr: BRK) means that service which includes the installation of brick, concrete block, stone, marble, slate or other units and products common to the masonry industry, including mortarless type masonry products. This includes installation of grout, caulking, tuck pointing, sand blasting, mortar washing, parging and cleaning and welding of reinforcement steel related to masonry construction. The BLD classification and HIC and CIC specialties also provide for this function.

"Modular/manufactured building contracting" (Abbr: MBC) means that service which provides for the installation or removal of a modular or manufactured building manufactured under ANSI standards. This classification does not cover foundation work; however, it does allow installation of piers covered under HUD regulations. It does allow a licensee to do internal tie ins of plumbing, gas and electrical or HVAC equipment. It does not allow for installing additional plumbing, electrical, or HVAC work such as installing the service meter, or installing the outside compressor for the HVAC system. The H/H and BLD classifications also provide for this function.

"Natural gas fitting provider contracting" (Abbr: NGF) means that service which provides for the incidental repair, testing, or removal of natural gas piping or fitting annexed to real property. This does not include new installation of gas piping for hot water heaters, boilers, central heating systems, or other natural gas equipment which requires a HVA or PLB license. The GFC specialty also provides for this function. A firm holding a NGF license is responsible for meeting all applicable tradesman licensure standards individual license and certification regulations.

"Painting and wallcovering contracting" (Abbr: PTC) means that service which provides for the application of materials common to the painting and decorating industry for protective or decorative purposes, the installation of surface coverings such as vinyls, wall papers, and cloth fabrics. This includes surface preparation, caulking, sanding and cleaning preparatory to painting or coverings and includes both interior and exterior surfaces. The BLD classification and the HIC and CIC specialties also provide for this function.

"Radon mitigation contracting" (Abbr: RMC) means that service which provides for additions, repairs or improvements to buildings or structures, for the purpose of mitigating or preventing the effects of radon gas. This function can only be performed by a firm holding the BLD classification or CIC (for other than one-family and two-family dwellings), FIC (for nonresidential farm buildings) or HIC (for one-family and two-family dwellings) specialty services. No electrical, plumbing, gas fitting, or HVAC functions are provided by this specialty.

"Recreational facility contracting" (Abbr: RFC) means that service which provides for the construction, repair, or improvement of any recreational facility, excluding paving and the construction of buildings, plumbing, electrical, and HVAC functions. The BLD classification also provides for this function.

"Refrigeration contracting" (Abbr: REF) means that service which provides for installation, repair, or removal of any refrigeration equipment (excluding HVAC equipment). No electrical, plumbing, gas fitting, or HVAC functions are provided by this specialty. This specialty is intended for those contractors who repair or install coolers, refrigerated casework, ice-making machines, drinking fountains, cold room equipment, and similar hermetic refrigeration equipment. The HVAC classification also provides for this function.

"Roofing contracting" (Abbr: ROC) means that service which provides for the installation, repair, removal or improvement of materials common to the industry that form a watertight, weather resistant surface for roofs and decks. This includes roofing system components when installed in conjunction with a roofing project, application of dampproofing or waterproofing, and installation of roof insulation panels and other roof insulation systems above roof deck. The BLD classification and the HIC and CIC specialties also provide for this function.

"Sewage disposal systems contracting" (Abbr: SDS) means that service which provides for the installation, repair, improvement, or removal of septic tanks, septic systems, and other on-site sewage disposal systems annexed to real property.

"Swimming pool construction contracting" (Abbr: POL) means that service which provides for the construction, repair, improvement or removal of in-ground swimming pools. The BLD classification and the RFC specialty also provide for this function. No trade related plumbing, electrical, backflow or HVAC work is included in this specialty.

"Vessel construction contracting" (Abbr: VCC) means that service which provides for the construction, repair, improvement, or removal of nonresidential vessels, tanks, or piping that hold or convey fluids other than sanitary, storm, waste, or potable water supplies. The H/H classification also provides for this function.

"Water well/pump contracting" (Abbr: WWP) means that service which provides for the installation of a water well system, including geothermal wells, which includes construction of a water well to reach groundwater, as defined in § 62.1-255 of the Code of Virginia, and the installation of the well pump and tank, including pipe and wire, up to and including the point of connection to the plumbing and electrical systems. No other classification or specialty service provides for construction of water wells. This regulation shall not exclude PLB, ELE or HVAC from installation of pumps and tanks.

Note: Specialty contractors engaging in construction which involves the following activities or items or similar activities or items may fall under the CIC, HIC and/or FIC specialty services, or they may fall under the BLD classification.

Appliances

Fireplaces

Rubber linings

Awnings

Fireproofing

Sandblasting

Blinds

Fixtures

Scaffolding

Bulkheads

Floor coverings

Screens

Cabinetry

Flooring

Sheet metal

Carpentry

Floors

Shutters

Carpeting

Glass

Siding

Casework

Glazing

Skylights

Ceilings

Grouting

Storage bins and lockers

Chimneys

Grubbing

Stucco

Chutes

Guttering

Temperature controls

Conduit rodding

Insulation

Terrazzo

Curtains

Interior decorating

Tile

Curtain walls

Lubrication

Vaults

Decks

Metal work

Vinyl flooring

Doors

Millwrighting

Wall panels

Drapes

Mirrors

Wall tile

Drywall

Miscellaneous iron

Waterproofing

Epoxy

Ornamental iron

Weatherstripping

Exterior decoration

Partitions

Welding

Facings

Protective coatings

Windows

Fences

Railings

Wood floors

Fiberglass

Rigging

Part II
Entry

18VAC50-22-40. Requirements for a Class C license.

A. A firm applying for a Class C license must meet the requirements of this section.

B. For every classification or specialty in which the firm seeks to be licensed, the firm shall name a qualified individual who meets the following requirements:

1. Is at least 18 years old;

2. Has a minimum of two years experience in the classification or specialty for which he is the qualifier;

3. Is a full-time employee of the firm as defined in this chapter or is a member of the responsible management of the firm; and

4. Where appropriate, has passed the trade-related examination or has completed an education and training program approved by the board and required for the specialties listed below:

Blast/explosive contracting

Electrical

Fire sprinkler

Gas fitting

HVAC

Plumbing

Radon mitigation

Water well drilling

5. Has obtained, pursuant to the tradesman regulations, a master tradesman license as required for those classifications and specialties listed in 18VAC50-22-20 and 18VAC50-22-30.

4. a. Has obtained the appropriate certification for the following specialties:

Blast/explosive contracting (Department of Fire Programs explosive use certification)

Fire sprinkler (NICET Sprinkler III certification)

Radon mitigation (EPA or DEQ accepted radon certification)

b. Has obtained, pursuant to the Individual Licensing and Certification Regulations, a master license for Plumbing, HVAC, Electrical, Gas Fitting, Natural Gas Fitting Provider, and Liquefied Petroleum Gas Contracting.

c. Has obtained, pursuant to the Individual Licensing and Certification Regulations, certification as an Elevator Mechanic for Elevator Escalator Contracting and certification as a Water Well Systems Provider for Water Well/Pump Contracting.

d. Has completed a board-approved examination for all other classifications and specialties that do not require other certification or licensure.

C. The firm shall provide information for the past five years prior to application on any outstanding, past-due debts and judgments; outstanding tax obligations; defaults on bonds; or pending or past bankruptcies. The firm, its qualified individual or individuals, and all members of the responsible management of the firm shall submit information on any past-due debts and judgments or defaults on bonds directly related to the practice of contracting as defined in Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia.

D. The firm, the qualified individual, and all members of the responsible management of the firm shall disclose at the time of application any current or previous contractor licenses held in Virginia or in other jurisdictions and any disciplinary actions taken on these licenses. This includes but is not limited to any monetary penalties, fines, suspensions, revocations, surrender of a license in connection with a disciplinary action, or voluntary termination of a license in Virginia or in any other jurisdiction.

E. In accordance with § 54.1-204 of the Code of Virginia, each applicant shall disclose the following information about the firm, all members of the responsible management, and the qualified individual or individuals for the firm:

1. All misdemeanor convictions within three years of the date of application; and

2. All felony convictions during their lifetime.

Any plea of nolo contendere shall be considered a conviction for purposes of this subsection. The record of a conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt. The board, in its discretion, may deny licensure to any applicant in accordance with § 54.1-204 of the Code of Virginia.

F. A member of responsible management shall have successfully completed a board-approved basic business course.

18VAC50-22-50. Requirements for a Class B license.

A. A firm applying for a Class B license must meet the requirements of this section.

B. A firm shall name a designated employee who meets the following requirements:

1. Is at least 18 years old;

2. Is a full-time employee of the firm as defined in this chapter, or is a member of responsible management as defined in this chapter;

3. Has passed a board-approved examination as required by § 54.1-1108 of the Code of Virginia or has been exempted from the exam requirement in accordance with § 54.1-1108.1 of the Code of Virginia; and

4. Has followed all rules established by the board or by the testing service acting on behalf of the board with regard to conduct at the examination. Such rules shall include any written instructions communicated prior to the examination date and any oral or written instructions given at the site on the date of the exam.

C. For every classification or specialty in which the firm seeks to be licensed, the firm shall name a qualified individual who meets the following requirements:

1. Is at least 18 years old;

2. Has a minimum of three years experience in the classification or specialty for which he is the qualifier;

3. Is a full-time employee of the firm as defined in this chapter or is a member of the responsible management of the firm;

4. Where appropriate, has passed the trade-related examination or has completed an education and training program approved by the board and required for the classifications and specialties listed below:

Blast/explosive contracting

Electrical

Fire sprinkler

Gas fitting

HVAC

Plumbing

Radon mitigation

Water well drilling

5. Has obtained, pursuant to the tradesman regulations, a master tradesman license as required for those classifications and specialties listed in 18VAC50-22-20 and 18VAC50-22-30.

4. a. Has obtained the appropriate certification for the following specialties:

Blast/explosive contracting (Department of Fire Programs explosive use certification)

Fire sprinkler (NICET Sprinkler III certification)

Radon mitigation (EPA or DEQ accepted radon certification)

b. Has obtained, pursuant to the Individual Licensing and Certification Regulations, a master license for Plumbing, HVAC, Electrical, Gas Fitting, Natural Gas Fitting Provider, and Liquefied Petroleum Gas Contracting.

c. Has obtained, pursuant to the Individual Licensing and Certification Regulations, certification as an Elevator Mechanic for Elevator Escalator Contracting and certification as a Water Well Systems Provider for Water Well/Pump Contracting.

d. Has completed a board-approved examination for all other classifications and specialties that do not require other certification or licensure.

D. Each firm shall submit information on its financial position. Excluding any property owned as tenants by the entirety, the firm shall state a net worth or equity of [ $15,000 $50,000 ] or more.

E. Each firm shall provide information for the five years prior to application on any outstanding, past-due debts and judgments; outstanding tax obligations; defaults on bonds; or pending or past bankruptcies. The firm, its designated employee, qualified individual or individuals, and all members of the responsible management of the firm shall submit information on any past-due debts and judgments or defaults on bonds directly related to the practice of contracting as defined in Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia.

F. The firm, the designated employee, the qualified individual, and all members of the responsible management of the firm shall disclose at the time of application any current or previous substantial identities of interest with any contractor licenses issued in Virginia or in other jurisdictions and any disciplinary actions taken on these licenses. This includes but is not limited to any monetary penalties, fines, suspension, revocation, or surrender of a license in connection with a disciplinary action. The board, in its discretion, may deny licensure to any applicant when any of the parties listed above have had a substantial identity of interest (as deemed in § 54.1-1110 of the Code of Virginia) with any firm that has had a license suspended, revoked, voluntarily terminated or surrendered in connection with a disciplinary action in Virginia or any other jurisdiction.

G. In accordance with § 54.1-204 of the Code of Virginia, each applicant shall disclose the following information about the firm, designated employee, all members of the responsible management, and the qualified individual or individuals for the firm:

1. All misdemeanor convictions within three years of the date of application; and

2. All felony convictions during their lifetime.

Any plea of nolo contendere shall be considered a conviction for purposes of this subsection. The record of a conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt. The board, in its discretion, may deny licensure to any applicant in accordance with § 54.1-204 of the Code of Virginia.

H. The designated employee or a member of responsible management shall have successfully completed a board-approved basic business course.

18VAC50-22-60. Requirements for a Class A license.

A. A firm applying for a Class A license shall meet all of the requirements of this section.

B. A firm shall name a designated employee who meets the following requirements:

1. Is at least 18 years old;

2. Is a full-time employee of the firm as defined in this chapter or is a member of the responsible management of the firm as defined in this chapter;

3. Has passed a board-approved examination as required by § 54.1-1106 of the Code of Virginia or has been exempted from the exam requirement in accordance with § 54.1-1108.1 of the Code of Virginia; and

4. Has followed all rules established by the board or by the testing service acting on behalf of the board with regard to conduct at the examination. Such rules shall include any written instructions communicated prior to the examination date and any oral or written instructions given at the site on the day of the exam.

C. For every classification or specialty in which the firm seeks to be licensed, the firm shall name a qualified individual who meets the following requirements:

1. Is at least 18 years old;

2. Has a minimum of five years of experience in the classification or specialty for which he is the qualifier;

3. Is a full-time employee of the firm as defined in this chapter or is a member of the firm as defined in this chapter or is a member of the responsible management of the firm;

4. Where appropriate, has passed the trade-related examination or has completed an education and training program approved by the board and required for the classifications and specialties listed below:

Blast/explosive contracting

Electrical

Fire sprinkler

Gas fitting

HVAC

Plumbing

Radon mitigation

Water well drilling

5. Has obtained, pursuant to the tradesman regulations, a master tradesman license as required for those classifications and specialties listed in 18VAC50-22-20 and 18VAC50-22-30.

4. a. Has obtained the appropriate certification for the following specialties:

Blast/explosive contracting (DHCD explosive use certification)

Fire sprinkler (NICET Sprinkler III certification)

Radon mitigation (EPA or DEQ accepted radon certification)

b. Has obtained, pursuant to the Individual Licensing and Certification Regulations, a master license for Plumbing, HVAC, Electrical, Gas Fitting, Natural Gas Fitting Provider, and Liquefied Petroleum Gas Contracting.

c. Has obtained, pursuant to the Individual Licensing and Certification Regulations, certification as an Elevator Mechanic for Elevator Escalator Contracting and certification as a Water Well Systems Provider for Water Well/Pump Contracting.

d. Has completed a board-approved examination for all other classifications and specialties that do not require other certification or licensure.

D. Each firm shall submit information on its financial position. Excluding any property owned as tenants by the entirety, the firm shall state a net worth or equity of [ $45,000 $100,000 or more ].

E. The firm shall provide information for the five years prior to application on any outstanding, past-due debts and judgments; outstanding tax obligations; defaults on bonds; or pending or past bankruptcies. The firm, its designated employee, qualified individual or individuals, and all members of the responsible management of the firm shall submit information on any past-due debts and judgments or defaults on bonds directly related to the practice of contracting as defined in Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia.

F. The firm, the designated employee, the qualified individual, and all members of the responsible management of the firm shall disclose at the time of application any current or previous substantial identities of interest with any contractor licenses issued in Virginia or in other jurisdictions and any disciplinary actions taken on these licenses. This includes but is not limited to, any monetary penalties, fines, suspensions, revocations, or surrender of a license in connection with a disciplinary action. The board, in its discretion, may deny licensure to any applicant when any of the parties listed above have had a substantial identity of interest (as deemed in § 54.1-1110 of the Code of Virginia) with any firm that has had a license suspended, revoked, voluntarily terminated, or surrendered in connection with a disciplinary action in Virginia or in any other jurisdiction.

G. In accordance with § 54.1-204 of the Code of Virginia, each applicant shall disclose the following information about the firm, all members of the responsible management, the designated employee and the qualified individual or individuals for the firm:

1. All misdemeanor convictions within three years of the date of application; and

2. All felony convictions during their lifetime.

Any plea of nolo contendere shall be considered a conviction for purposes of this subsection. The record of a conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt. The board, in its discretion, may deny licensure to any applicant in accordance with § 54.1-204 of the Code of Virginia.

H. The designated employee or a member of responsible management shall have successfully completed a board-approved basic business course.

18VAC50-22-70. Qualifications for licensure by reciprocity or substantial equivalency.

Firms originally licensed in a state with which the board has a reciprocal agreement or whose eligibility criteria are substantially equivalent may obtain a Virginia contractor's license in accordance with the terms of that agreement.

18VAC50-22-210. Change of business entity requires a new license.

Licenses are issued to firms as defined in this chapter and are not transferable. Whenever the legal business entity holding the license is dissolved or altered to form a new business entity, the original license becomes void and shall be returned to the board within 30 days of the change. Additionally, the firm shall apply for a new license, on a form provided by the board, within 30 days of the change in the business entity. Such changes include but are not limited to:

1. Death of a sole proprietor;

2. Death or withdrawal of a general partner in a general partnership or the managing partner in a limited partnership; and

3. Formation Conversion, formation, or dissolution of a corporation, a limited liability company, or an association or any other business entity recognized under the laws of the Commonwealth of Virginia.

18VAC50-22-230. Change of name or address.

A. A licensee must operate under the name in which the license is issued. Any name change shall be reported in writing to the board within 30 days of the change. The board shall not be responsible for the licensee's failure to receive notices or correspondence due to the licensee's not having reported a change of name.

B. Any change of address the address of record or principal place of business shall be reported in writing to the board within 30 days of the change. The board shall not be responsible for the licensee's failure to receive notices or correspondence due to the licensee's not having reported a change of address.

18VAC50-22-260. Filing of charges; prohibited acts.

A. All complaints against contractors may be filed with the Department of Professional and Occupational Regulation at any time during business hours, pursuant to § 54.1-1114 of the Code of Virginia.

B. The following are prohibited acts:

1. Failure in any material way to comply with provisions of Chapter 1 (§ 54.1-100 et seq.) or Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia or the regulations of the board.

2. Furnishing substantially inaccurate or incomplete information to the board in obtaining, renewing, reinstating, or maintaining a license.

3. Failure of the responsible management, designated employee, or qualified individual to report to the board, in writing, the suspension or revocation of a contractor license by another state or conviction in a court of competent jurisdiction of a building code violation.

4. Publishing or causing to be published any advertisement relating to contracting which contains an assertion, representation, or statement of fact that is false, deceptive, or misleading.

5. Negligence and/or incompetence in the practice of contracting.

6. Misconduct in the practice of contracting.

7. A finding of improper or dishonest conduct in the practice of contracting by a court of competent jurisdiction or by the board.

8. Failure of all those who engage in residential contracting, excluding subcontractors to the contracting parties and those who engage in routine maintenance or service contracts, to make use of a legible written contract clearly specifying the terms and conditions of the work to be performed. For the purposes of this chapter, residential contracting means construction, removal, repair, or improvements to single-family or multiple-family residential buildings, including accessory-use structures as defined in § 54.1-1100 of the Code of Virginia. Prior to commencement of work or acceptance of payments, the contract shall be signed by both the consumer and the licensee or his agent.

9. Failure of those engaged in residential contracting as defined in this chapter to comply with the terms of a written contract which contains the following minimum requirements:

a. When work is to begin and the estimated completion date;

b. A statement of the total cost of the contract and the amounts and schedule for progress payments including a specific statement on the amount of the down payment;

c. A listing of specified materials and work to be performed, which is specifically requested by the consumer;

d. A "plain-language" exculpatory clause concerning events beyond the control of the contractor and a statement explaining that delays caused by such events do not constitute abandonment and are not included in calculating time frames for payment or performance;

e. A statement of assurance that the contractor will comply with all local requirements for building permits, inspections, and zoning;

f. Disclosure of the cancellation rights of the parties;

g. For contracts resulting from a door-to-door solicitation, a signed acknowledgment by the consumer that he has been provided with and read the Department of Professional and Occupational Regulation statement of protection available to him through the Board for Contractors;

h. Contractor's name, address, license number, class of license, and classifications or specialty services; and

i. Statement providing that any modification to the contract, which changes the cost, materials, work to be performed, or estimated completion date, must be in writing and signed by all parties.

10. Failure to make prompt delivery to the consumer before commencement of work of a fully executed copy of the contract as described in subdivisions 8 and 9 of this subsection for construction or contracting work.

11. Failure of the contractor to maintain for a period of five years from the date of contract a complete and legible copy of all documents relating to that contract, including, but not limited to, the contract and any addenda or change orders.

12. Refusing or failing, upon request, to produce to the board, or any of its agents, any document, book, record, or copy of it in the licensee's possession concerning a transaction covered by this chapter or for which the licensee is required to maintain records.

13. Failing to respond to an investigator agent of the board or providing false, misleading or incomplete information to an investigator seeking information in the investigation of a complaint filed with the board against the contractor. Failing or refusing to claim certified mail sent to the licensee's address of record shall constitute a violation of this regulation.

14. Abandonment defined as the unjustified cessation of work under the contract for a period of 30 days or more.

15. The intentional and unjustified failure to complete work contracted for and/or to comply with the terms in the contract.

16. The retention or misapplication of funds paid, for which work is either not performed or performed only in part.

17. Making any misrepresentation or making a false promise that might influence, persuade, or induce.

18. Assisting another to violate any provision of Chapter 1 (§ 54.1-100 et seq.) or Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia, or this chapter; or combining or conspiring with or acting as agent, partner, or associate for another.

19. Allowing a firm's license to be used by another.

20. Acting as or being an ostensible licensee for undisclosed persons who do or will control or direct, directly or indirectly, the operations of the licensee's business.

21. Action by the firm, responsible management as defined in this chapter, designated employee or qualified individual to offer, give, or promise anything of value or benefit to any federal, state, or local employee for the purpose of influencing that employee to circumvent, in the performance of his duties, any federal, state, or local law, regulation, or ordinance governing the construction industry.

22. Where the firm, responsible management as defined in this chapter, designated employee or qualified individual has been convicted or found guilty, after initial licensure, regardless of adjudication, in any jurisdiction, of any felony or of any misdemeanor, there being no appeal pending therefrom or the time of appeal having elapsed. Any plea of guilty or nolo contendere shall be considered a conviction for the purposes of this subdivision. The record of a conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt.

23. Failure to inform the board in writing, within 30 days, that the firm, a member of responsible management as defined in this chapter, its designated employee, or its qualified individual has pleaded guilty or nolo contendere or was convicted and found guilty of any felony or of a Class 1 misdemeanor or any misdemeanor conviction for activities carried out while engaged in the practice of contracting.

24. Having been disciplined by any county, city, town, or any state or federal governing body including action by the Virginia Department of Health, which action shall be reviewed by the board before it takes any disciplinary action of its own.

25. Failure to abate a violation of the Virginia Uniform Statewide Building Code, as amended.

26. Failure of a contractor to comply with the notification requirements of the Virginia Underground Utility Prevention Act, Chapter 10.3 (§ 56-265.14 et seq.) of Title 56 of the Code of Virginia (Miss Utility).

27. Practicing in a classification, specialty service, or class of license for which the contractor is not licensed.

28. Failure to satisfy any judgments.

29. Contracting with an unlicensed or improperly licensed contractor or subcontractor in the delivery of contracting services.

30. Failure to honor the terms and conditions of a warranty.

31. Failure to obtain written change orders, which are signed by both the consumer and the licensee or his agent, to an already existing contract.

32. Failure to ensure that supervision, as defined in this chapter, is provided to all helpers and laborers assisting licensed tradesman.

33. Failure to obtain a building permit or applicable inspection, where required.

NOTICE: The forms used in administering the above regulation are not being published; however, the name of each form is listed below. The forms are available for public inspection by contacting the agency contact for this regulation, or at the office of the Registrar of Regulations, General Assembly Building, 2nd Floor, Richmond, Virginia.

[ FORMS (18VAC50-22)

Contractor Licensing Information, 27INTRO (5/09).

Trade-Related Examinations and Qualifications Information, 27EXINFO (5/09).

License Application, 27LIC (rev. 4/10).

Class C License Application (Short Form), 27CSF (rev. 4/10).

Additional License Classification/Specialty Designation Application, 27ADDCL (rev. 4/10).

Change of Qualified Individual Application, 27CHQI (rev. 4/10).

Change of Designated Employee Application, 27CHDE (rev. 4/10).

Changes of Responsible Management Form, 27CHRM (eff. 5/09).

Experience Reference, 27EXP (8/07).

Certificate of License Termination, 27TERM (5/09).

Education Provider Registration/Course Approval Application; Contractors Prelicense and Continuing Education, 27EDREG (rev. 6/09).

Certificate of License Termination, 27TERM (5/09).

Education Provider Listing Form, 27EDLIST (5/09).

Financial Statement, 27FINST (5/09).

Additional Qualified Individual Experience Reference Form, 27QIEXP (5/09).

Contractor Licensing Information, A503-27INTRO (rev. 9/12).

Requirements for Qualified Individuals, A503-27EXINFO (rev. 9/12).

License Application, A503-27LIC (rev. 9/12).

Expedited Class A License Application, A503-2705A_ELIC (rev. 9/12).

Class C License Application (Short Form), A503-27CSF (rev. 9/12).

Additional Specialty Designation Application, A503-27ADDSP (rev 9/12).

Change in Qualified Individual and Designated Employee Application, A503-27CH_QIDE (rev. 9/12).

Change of Responsible Management Application, A503-syCHRM (rev. 7/11).

Certificate of License Termination, A503-27TERM (3/11).

Education Provider Registration/Course Approval Application, A503-27EDREG (rev. 10/11).

Education Provider Listing Application, A503-27EDLIST (rev. 3/11).

Financial Statement, A503-27FINST (rev. 7/11).

Additional Qualified Individual Experience Reference Form, A504-27QIEXP (rev. 3/11). ]

VA.R. Doc. No. R08-1340; Filed September 17, 2012, 4:39 p.m.