REGULATIONS
Vol. 37 Iss. 1 - August 31, 2020

TITLE 20. PUBLIC UTILITIES AND TELECOMMUNICATIONS
STATE CORPORATION COMMISSION
Chapter 314
Final Regulation

REGISTRAR'S NOTICE: The State Corporation Commission is claiming an exemption from the Administrative Process Act in accordance with § 2.2-4002 A 2 of the Code of Virginia, which exempts courts, any agency of the Supreme Court, and any agency that by the Constitution is expressly granted any of the powers of a court of record.

Title of Regulation: 20VAC5-314. Regulations Governing Interconnection of Small Electrical Generators (amending 20VAC5-314-10 through 20VAC5-314-170; adding 20VAC5-314-35, 20VAC5-314-38, 20VAC5-314-39, 20VAC5-314-165).

Statutory Authority: §§ 12.1-13 and 56-578 of the Code of Virginia.

Effective Date: October 15, 2020.

Agency Contact: Mike Cizenski, Utilities Engineer, Public Utility Regulation Division, State Corporation Commission, P.O. Box 1197, Richmond, VA 23218, telephone (804) 371-9441, or email mike.cizenski@scc.virginia.gov.

Summary:

The amendments add definitions; establish a preapplication process; provide further information regarding (i) the treatment of queue numbers and interdependent projects, (ii) the modification of interconnection requests, and (iii) the Level 1, Level 2, and Level 3 interconnection requirements and processes; and modify and add schedules.

Changes since publication of the proposed regulation include (i) simplifying the definition of ''small generating facility'' by removing the reference to ''storage for later injection''; (ii) clarifying that the regulation applies to utilities providing interconnections to retail electric customers, independently owned generators, and any other parties operating or intending to operate a distributed generating facility parallel with utility systems and to equipment used for the storage of electricity for later injection to utility systems; and (iii) adding 20VAC5-314-165 regarding sale of an existing or proposed small generating facility.

AT RICHMOND, AUGUST 3, 2020

COMMONWEALTH OF VIRGINIA, ex rel.

STATE CORPORATION COMMISSION

CASE NO. PUR-2018-00107

Ex Parte: In the matter of revising
the Commission's Regulations Governing
Interconnection of Small Electrical Generators

AMENDING ORDER

On July 29, 2020, the State Corporation Commission ("Commission") issued its Order Adopting Regulations in the above-captioned docket. Thereafter, a scribal error was discovered on page 19 of 178 of Appendix A to the Order Adopting Regulations.

NOW THE COMMISSION, upon consideration of this matter, is of the opinion and finds that this error should be corrected.

Accordingly, IT IS ORDERED THAT:

(1) This case is reopened to consider the amendment described herein.

(2) Appendix A to the Commission's Order Adopting Regulations, specifically 20 VAC 5-314-39 C, hereby is amended. The sentence, "Changes that qualify as material modifications are described as follows: . . ." is stricken and replaced with the sentence, "Changes that do not qualify as material modifications are described as follows: . . ."

(3) Page 19 of Appendix A, as amended, is attached to this Amending Order.

(4) Copies of the revised Regulations Governing Interconnection of Small Electrical Generators, 20 VAC 5-314-10 et seq., including the amendment herein, shall be published in the Virginia Register of Regulations and shall be posted on the website of the Commission's Division of Utility Regulation.

(5) The Staff of the Division of Public Utility Regulation also shall email a copy of the Order Adopting Regulations and attached regulations, including the amendment described herein, to all persons and entities who participated in the workgroup held to receive input on the regulations and/or who filed comments in this docket.

(6) The Interim Clerk of the Commission hereby is directed to serve a copy of this Amending Order on every investor-owned electric utility and electric cooperative in the Commonwealth, who shall forthwith thereafter notify all their interconnection customers of this amendment.

(7) This case is dismissed.

A COPY HEREOF shall be sent by the Clerk of the Commission to all persons on the official Service List in this matter. The Service List is available from the Clerk of the Commission.

AT RICHMOND, JULY 29, 2020

COMMONWEALTH OF VIRGINIA, ex rel.

STATE CORPORATION COMMISSION

CASE NO. PUR-2018-00107

Ex Parte: In the matter of revising
the Commission's Regulations Governing
Interconnection of Small Electrical Generators

ORDER ADOPTING REGULATIONS

On May 8, 2009, the State Corporation Commission ("Commission") adopted Regulations Governing Interconnection of Small Electrical Generators, 20 VAC 5-314-10 et seq. ("Interconnection Regulations"), in Case No. PUE-2008-00004.1 The Commission initiated that rulemaking in accordance with § 56-578 of the Code of Virginia ("Code") which provides, in part:

The Commission shall establish interconnection standards to ensure transmission and distribution safety and reliability, which standards shall not be inconsistent with nationally recognized standards acceptable to the Commission. In adopting standards pursuant to this subsection, the Commission shall seek to prevent barriers to new technology and shall not make compliance unduly burdensome and expensive.

In that case, the Commission noted that "all electric energy distributors have the obligation to connect any retail customer, including those using distributed generation, located within its service territory to the distributor's facilities used for delivery of retail electric energy, subject to [the Commission's] rules and regulations and approved tariff provisions relating to connection of service."2 Given the passage of time since the Commission established the Interconnection Regulations, recent changes in applicable laws and Federal Energy Regulatory Commission ("FERC") guidelines, and technological changes in the power industry, the Commission has concluded that it is appropriate to revisit the Interconnection Regulations.3

On September 5, 2018, the Commission entered an Order Initiating Rulemaking Proceeding in this docket to determine whether, and the extent to which, any of the Interconnection Regulations should be revised. In this regard, the Commission directed Commission Staff ("Staff") to solicit comments from, and to schedule a meeting or meetings (as necessary) with, stakeholders and persons having an interest in the Interconnection Regulations and the interconnection of small electrical generators in the Commonwealth of Virginia; to develop, with appropriate input from interested persons, a proposal for any necessary revisions to the current Interconnection Regulations; and to prepare and file a report ("Staff Report") on its findings and recommendations.

Subsequent to the Commission's Order Initiating Rulemaking, Staff developed initial draft revisions to the Interconnection Regulations ("Initial Draft Revisions") and shared them with interested stakeholders, who were provided an opportunity to comment on the Initial Draft Revisions and participate in a multiple-day working group meeting. Written comments were received from eight entities, and ten entities in addition to Staff participated in the working group meetings.4

In response to the written and verbal comments received from the interested stakeholders, Staff made updates to the Initial Draft Revisions. On September 12, 2019, the Staff filed its Staff Report, which included these proposed updates ("Proposed Rules").

On December 3, 2019, the Commission entered an Order for Notice and Comment ("Notice Order"). In the Notice Order, we found that the Proposed Rules should be considered for adoption; provided interested persons an opportunity to comment on, or to suggest modifications or supplements to, the Proposed Rules, or to request a hearing thereon, on or before February 21, 2020; and provided Staff an opportunity to respond to any comments on or before March 20, 2020 ("Staff comments"). We also directed that a copy of the Proposed Rules be sent to the Registrar of Regulations for publication in the Virginia Register of Regulations.5

Comments were filed by Virginia Electric and Power Company ("Dominion"); the Virginia, Maryland & Delaware Association of Electric Cooperatives ("VMDAEC" or "Cooperatives"); Cypress Creek Renewables ("Cypress Creek"); Virginia Solar, LLC ("VA Solar"); and Staff.6 No participant requested a hearing on the Proposed Rules.7

NOW THE COMMISSION, upon consideration of this matter, is of the opinion and finds that the revised regulations attached hereto as Appendix A should be adopted as final rules, as discussed herein. In developing these revised regulations, we have reviewed the Proposed Rules and considered and weighed the arguments and comments presented in this proceeding in support of each participant's requests.8

Before turning to the participants' requests, we first note that we have simplified the definition of ''small generating facility'' ("SGF") by removing the reference to ''storage for later injection.'' We find that this change to the definition better describes a generating facility as that term is used at the present time and is therefore appropriate. However, this change should not be construed as a finding that storage devices are exempted from the requirements of the Interconnection Regulations. We therefore also find that it is appropriate to clarify in both the title of the Interconnection Regulations and in 20 VAC 5-314-10 that the regulations shall apply to utilities providing interconnections to retail electric customers, independently owned generators, and any other parties operating, or intending to operate, a distributed generating facility in parallel with utility systems, and to equipment used for the storage of electricity for later injection to utility systems.9

VMDAEC's Recommended Changes to the Proposed Rules

VMDAEC submitted comments recommending numerous changes to the Proposed Rules. VMDAEC divided its comments into: (i) matters of most important concern; (ii) matters of moderate concern; and (iii) matters of minor concern.10

The Commission adopts the following edits to the Proposed Rules to address concerns raised by VMDAEC:

• 20 VAC5-314-20, Schedule 1 of 20 VAC5-314-170, and Schedule 10 of 20 VAC 5-314-170 at Attachment 1, shall all be amended to include the following definition:

"Processing fee" means a non-refundable cost to administer or file an application.11

• 20 VAC 5-314-35 C is amended as follows:

Using the information provided in the Preapplication Report Request Form in subsection B of this section, and as described in Schedule 4 of 20 VAC 5‑314-170, the utility will identify the substation or area bus, bank, or circuit likely to serve the proposed point of interconnection….12

• 20 VAC 5-314-40 D (6) shall be amended to state as follows:

The [interconnection customer ("IC")] has paid, or has made arrangements satisfactory to the utility to pay, the cost of the SGF metering pursuant to 20 VAC 5-314-80, and any costs associated with minor modifications;13

• 20 VAC 5-314-40 D (7)(e) shall be amended to state:

Voltage balance limitation. The SGF shall not create a voltage imbalance of more than 3.0% measured from phase to phase or phase to ground at any other customer's revenue meter if the utility distribution transformer, with the secondary connected to the point of interconnection, is a three-phase transformer, unless the IC reimburses the utility for its cost to modify any facilities needed to accommodate the interconnection and such modifications are completed.14

• Schedule 6 of 20 VAC 5-314-170 at Section 2 shall be amended as shown below:

If the interconnection request is submitted as Level 2, the nonrefundable processing fee payable to the utility is $1,000.

If the interconnection request is submitted as Level 3, the IC shall submit to the utility:

a. The a nonrefundable processing fee of $1,000. Upon being designated by the Utility as a Project A or if the IC elects to proceed with the Project B, Level 3 Interconnection Customers shall also be obligated to submit

b. An an interconnection request study deposit of $10,000 plus $1.00 per kWAC, pursuant to 20VAC5-314-38.

An IC transferring from the Level 1 process shall pay the nonrefundable processing fee of $1,000 minus any previously paid Level 1 processing fee.

An IC transferring from the Level 2 to the Level 3 process shall not be required to pay an additional $1,000 processing fee.

If the SGF is a standby generating facility, the interconnection request shall be designated a Project A and the IC shall be obligated to submit an interconnection request study deposit is of $5,000 in conjunction with the initial study agreement as provided for in 20 VAC 5-314-38 and 20 VAC 5-314-70.

If the interconnection request is submitted solely due to a transfer of ownership or change of control of the SGF, the nonrefundable processing fee is $500.15

• Schedule 10 of 20 VAC 5-314-170 at Article 3.3 shall be amended to state:

No termination shall become effective until the Parties have complied with all laws and regulations applicable to such termination, such as any local or Virginia Department of Environmental Quality decommissioning requirements….16

• Schedule 10 of 20 VAC 5-314-170 at Articles 3.1 and 3.3 shall be amended to state:

3.1 Effective date. This Agreement shall become effective upon execution by the Parties. The Utility shall promptly file this Agreement with the Division of Public Utility Regulation upon execution.

3.3 Termination. No termination shall become effective until the Parties have complied with all laws and regulations applicable to such termination, including the filing with the Division of Public Utility Regulation of a notice of termination of this Agreement such as any local or Virginia Department of Environmental Quality decommissioning requirements.17

• Schedule 10 of 20 VAC 5-314-170 at Article 14 shall be amended as set forth in Staff's comments to add affected parties as signatories to the Small Generator Interconnection Agreement ("SGIA").18

The Commission declines to adopt the following recommended changes made by VMDAEC for the reasons discussed herein.

First, VMDAEC requests that the definition of "distribution upgrades" in the Proposed Rules be amended to include "existing facilities for the use of the IC as a direct result of the interconnection" and that Article 4 of the SGIA19 state specifically that ICs shall be responsible for the cost of any existing facilities for their use as a result of the interconnection.20 According to the Cooperatives, such amendments to the Interconnection Regulations would prevent ICs from being able to "'ride for free' on facilities that have been paid for, or are currently being paid for, by Cooperative member‑consumers."21 VMDAEC states that it could develop the formulae or excess facilities analyses used to calculate the operations and maintenance ("O&M") cost for these facilities and submit the formulae as a compliance filing in this docket.22

The Commission finds that it is not necessary for this issue to be addressed in the Proposed Rules and, further, concludes that it is reasonable not to allow for the filing of such formulae or analyses as a compliance filing for purposes of the instant rulemaking proceeding.23 As Staff noted in its comments, this issue is specific to the Cooperatives.24 Moreover, the Cooperatives are seeking ongoing, long-term O&M payments, going well beyond the actual interconnection process, which is the focus of the Interconnection Regulations. For these reasons, to the extent the Cooperatives would like to address such matters further, we find that they would be better considered in a separate formal petition in which other interested persons have an opportunity to participate.

Similarly, VMDAEC seeks to modify the definition of "network upgrades" as follows:

"Network upgrades" means additions, modifications, and enhancements and other direct costs to the utility's transmission system that are required in order to accommodate the interconnection of the small generating facility with the utility's system. Network upgrades do not include distribution upgrades.25

The Cooperatives state that this modification is necessary to ensure an IC would properly pay the costs of any line losses that are created due to the IC generating behind an Old Dominion Electric Cooperative delivery point, and which would otherwise be borne by the Cooperative's member‑consumers.26 Like above, this issue goes beyond the actual interconnection process and appears to be specific to the Cooperatives; therefore, it would be best considered in a different proceeding where the relevant issues could be fully evaluated and interested parties would have an opportunity to participate.

Next, the Cooperatives "encourage the Commission to reconcile terminology and/or processes that may be at odds with the [PJM Interconnection, L.L.C. ("PJM")] interconnection process."27 Code § 56‑578 C states, "The Commission shall establish interconnection standards to ensure transmission and distribution safety and reliability, which standards shall not be inconsistent with nationally recognized standards acceptable to the Commission." As Staff noted in its September 12, 2019 Staff Report, the proposed revisions are intended to update the regulations the Commission previously adopted in 2009 and to align them with recent standards, including the FERC Small Generator Interconnection Procedures Rules ("FERC Rules").28 In addition to the PJM interconnection process and the FERC Rules, many states have their own interconnection regulations.29 As a result, it may be impossible for the Commission to develop regulations that do not conflict in some way with regulations promulgated by other entities. The FERC Rules served as the basis for the Interconnection Regulations that we adopted in 2009,30 and we find that it is appropriate for the FERC Rules, as updated, to continue to serve as a basis for these regulations.31

VMDAEC further seeks amendment of 20 VAC 5-314-130 to alleviate the Cooperatives of all reporting requirements.32 As proposed, 20 VAC 5-314-30 states in pertinent part that each utility shall annually file a written report with Staff that includes certain information concerning the utility's SGF queue, and a listing of those facilities interconnected during the preceding calendar year. The Proposed Rules direct the utilities to include ten items of data for each SGF in their annual reports.33 According to the Cooperatives, "While it may be considered simply a 'cost of doing business' to some, we consider it a burden on the time, personnel, and resources that should be devoted to serving our member-consumers" and therefore VMDAEC "cannot support, and will request a waiver of, the reporting requirements."34

The regular provision of such information to Staff is necessary to ensure the Commission and its Staff have an accurate understanding of the Virginia distributed generation queue and will also facilitate the Commission's and Staff's knowledge of the overall electric system in Virginia. The reports will also help the Commission determine whether the ten items set forth in the Proposed Rules that utilities must provide are adequate to improve our understanding of the generation queue and the overall electric system, or whether future amendments to 20 VAC 5‑314‑130 are needed to obtain that understanding. We therefore find the reports to be of significant value. We also note that the Cooperatives state in their comments that they do not object to collecting or maintaining this data.35 Further, the reports are only to be submitted annually, which we do not find to be unduly burdensome. We therefore decline to remove the Cooperatives from the reporting requirements of 20 VAC 5‑314‑130.36 As VMDAEC notes, the Commission may waive any or all provisions of the Interconnection Regulations for good cause shown.37 However, any request for waiver would be evaluated based on the facts and circumstances set forth in the request.

Next, the Cooperatives recommend "a fail-safe date" by which a Level 3 IC should be interconnected or forced to re-start the process.38 They also recommend that the IC file interim updates with the utility at 6-month intervals.39 Staff opposes these recommendations, stating in part that the SGIA already in essence includes such a fail‑safe date, as it includes language stating that the agreement shall remain in effect for a period of 10 years, with opportunities to annually renew the agreement thereafter.40 At this time, the Commission declines to adopt these proposals. VMDAEC cites no evidence or example of a situation where the current 10-year term of the SGIA was problematic for a cooperative. Concerning the suggested 6-month reports, the Commission declines to adopt such a rule for every Level 3 interconnection. We note that a utility and an IC are free to agree to 6-month reporting requirements if deemed necessary; the Proposed Rules require a construction planning meeting where such terms could be discussed.41 Furthermore, the construction planning meeting requires the utility and IC to determine and document construction milestones. The failure of either party to meet a milestone obligation requires, among other things, notification to the other party and amendments to the milestones.42

Next, the Cooperatives state that the Proposed Rules "should be clear that a Level 1 IC must sign an SGIA."43 The current Interconnection Regulations do not require a Level 1 IC to sign an SGIA. Further, the FERC Rules do not require an equivalent‑sized IC to sign an SGIA.44 Given this, and as the Cooperatives have provided no support for this requested change, we do not find that a Level 1 IC should be required to sign an SGIA at this time.

VMDAEC further recommends that the Proposed Rules be modified to acknowledge that the inclusion of storage will necessitate additional studies, and to require energy storage to be evaluated on the basis of maximum generating/output capacity.45 The Proposed Rules do not limit the types of evaluations, or number of studies, that may be performed. Moreover, the Commission does not believe such particulars should be specifically detailed in the Proposed Rules, as certain types or numbers of studies may be necessary in some, but not all, circumstances. Including such detailed information would reduce the flexibility and efficiency of the Interconnection Regulations.

The Cooperatives propose changing the fee set forth in 20 VAC 5-314-40 D that utilities may charge a Level 1 IC to inspect certain equipment settings from $50 to $150‑200 to better align with the Cooperative's observed inspection costs.46 We find the $50 inspection fee, which is comparable to the inspection fee in the Commission's Regulations Governing Net Energy Metering, to be reasonable at this time.47

VMDAEC also raises several concerns that we find are already adequately addressed in the Proposed Rules, and therefore the Commission declines to adopt the following recommended changes at this time:

• No additional language is needed to further clarify that costs related to interconnection requests should be borne by the IC;48

• As is discussed further below, due to concerns that the funds from the interconnection request deposit are usually exhausted by the time the facilities study occurs, the Proposed Rules increase the interconnection request study deposit for a Level 3 interconnection request from the lesser of $1,000 or 50% of the estimated cost of the feasibility study to $10,000 plus $1.00 per kilowatt of alternating current ("kWAC") generating capacity, and we do not find further changes to the schedule of deposits for the Level 3 interconnection process to be necessary at this time;49

• Further requirements for ICs that construct their own interconnection facilities are not needed because the Proposed Rules include language allowing the utility to request additional technical information from any IC as may reasonably become necessary while conducting its interconnection studies;50

• Section 20 VAC 5-314-39 of the Proposed Rules describes the specific changes in a project that are significant enough to be considered material modifications, and a utility could require a re‑study of an existing interconnection should an IC make such a material modification. As such, we decline to include any further language defining changes in technology or setting specific periods of time that require a re‑study of a facility's impact on the grid;51

• We will not at this time modify the definition of "network upgrades" to include "enhancements, and other direct costs…" in order to ensure that any North American Electric Reliability Corporation reliability reporting costs that may result from an IC interconnecting on a cooperative's system are borne by the IC and not the cooperative's member‑consumers, because we concur with Staff that ''the definition for 'network upgrades,' whose costs are recoverable from the IC per the Proposed Rules, is sufficient to address this VMDAEC concern;''52 and

• The SGIA already reflects the power factor and voltage and compels the IC to abide by those determinations.53

Dominion's Recommended Changes to the Proposed Rules

In its comments, Dominion recommends several revisions to the Proposed Rules. Except as described below, the Commission adopts the additional changes proposed by Dominion, as set forth in its comments and its attached redline version of the Proposed Rules (''redline'').

First, Dominion proposes changes to 20 VAC 5-314-39. Specifically, in the Proposed Rules, 20 VAC 5-314-39 states as follows:

B. Changes that qualify as material modifications are described as follows: …

7. A change reducing the maximum generating capacity of the SGF (i) by more than 25% before the Feasibility Study Agreement or Combined Study Agreement has been executed or (ii) by more than 10% after the Feasibility Study Agreement or Combined Study Agreement has been executed.

Dominion requests that an IC instead be permitted to reduce its generating capacity by only up to 10% without triggering a material modification because the higher limit of 25% "may have significant downstream effects on other queued projects…."54 In response, Staff stated that the proposed 25% reduction is only allowed to occur early in the process and thus would likely cause, at most, only minor downstream impacts on other queued projects.55 Staff further stated, "During the working group, solar developers expressed concern that the 10% limit was too restrictive and, therefore, caused them to sometimes submit multiple interconnection requests for the same point of interconnection…."56 We find that allowing ICs to reduce their generating capacity by up to 25% before execution of any initial study agreement, and only limiting the reduction to 10% after the IC has executed its initial study agreement, provides important flexibility to the IC without causing major negative impacts to the utility.57 We therefore decline to adopt the change requested by Dominion.

Next, Dominion has proposed including a new section to the Interconnection Regulations: 20 VAC 5-314-165 (Assignment; Sale of an Existing or Proposed SGF).58 Subsection D of the proposed section states, in part, "Where the IC has not executed an interconnection agreement, the utility may continue to study the IC under a pre-existing study agreement or may require the new owner to execute a new study agreement."59 In response, Staff noted that it does not oppose this language, but suggested including additional language to ensure the new owner would still retain the existing queue position:

Where the IC has not executed an [i]nterconnection [a]greement, the utility may continue to study the IC under a pre‑existing study agreement or may require the new owner to execute a new study agreement, though under either scenario the new owner would retain the existing queue position.60

We approve the inclusion of 20 VAC 5-314-165 in the Interconnection Regulations, as amended to include the additional language recommended by Staff.

VA Solar's Recommended Changes to the Proposed Rules

VA Solar opposes the proposed changes in fees outlined in Schedule 6 of 20 VAC 5-314-170 for Level 3 interconnection requests, specifically the interconnection request study deposit of $10,000 plus $1.00 per kWAC of the nameplate capacity.61 Instead, VA Solar supports approval of a flat interconnection request study deposit of $10,000.62 In contrast, Staff believes the larger up-front deposit will help deter ICs from filing multiple requests for the same point of interconnection that could overwhelm the queue, and that the proposed study costs better align the interconnection study deposit with the projected costs of the studies.63 We agree that the study deposit fee of $10,000 plus $1.00 per kWAC of the nameplate capacity more adequately represents the significant investment in time and money that utilities spend to develop the interconnection request studies. Further, if the deposit provided by the IC for the study costs exceeds the invoiced fees, the Proposed Rules specifically require the utility to refund the excess to the IC.64 This requirement ensures that an IC is only responsible for the actual costs of the studies and nothing more.65 For these reasons, we reject VA Solar's proposed changes to the fees in Schedule 6 of 20 VAC 5-314-170.

Next, VA Solar asserts that "it would be beneficial" for the Interconnection Regulations to allow for solar projects to be able to provide reactive power to the grid through the use of smart inverters, in part because the use of such technology may reduce costs related to voltage issues that ICs must bear.66 VA Solar also recommends amending Article 1.8.2 of the SGIA to require a utility to pay the IC if the IC provides reactive power to the utility and the utility receives compensation for the ability to provide reactive power, stating: "In addition, if the [u]tility pays its own or affiliated generators for reactive power service within the specified range or receives compensation for the ability to provide reactive power, it must similarly pay the IC."67

However, as Staff notes in its September 12, 2019 Staff Report, the Institute of Electrical and Electronics Engineers' ("IEEE") Standard 154768 is the primary standard that establishes criteria and requirements for interconnection of distributed energy resource ("DER") equipment, including smart inverters, to the power system.69 While the IEEE Standard 1547 was recently updated ("IEEE 1547-2018" or "IEEE Standard 1547-2018"),

no DER equipment has yet been certified as compliant with the new IEEE Standard 1547-2018 and Staff is unaware as to when this certification will be available. IEEE Standard 1547-2018 covers only the performance, capabilities, and functions of DER equipment, rather than the certification testing required for the equipment. A companion standard, IEEE Standard 1547.1, is being revised to specify the type, production, commissioning, and periodic tests required in order to certify DER equipment to the IEEE 1547‑2018 Standard. This certification standard is not complete. It is Staff's understanding that IEEE 1547-2018 cannot be fully implemented until the companion testing IEEE Standard 1547.1 is published and DERs are certified by an approved national testing lab. In addition to finalizing the certification standard, the specific operational set-points for certified equipment needs to be defined by regional transmission operators such as [PJM], and/or electric utilities before IEEE 1547-2018 certified DER equipment can be deployed. Finally, the Underwriters Laboratories' UL 1741 Standard, which specifies requirements for utility-interactive equipment such as inverters, converters, charge controllers, and interconnection system equipment, and which is intended to supplement and be used in conjunction with the IEEE Standard 1547, has not completed revisions to reflect changes in IEEE Standards 1547-2018 and 1547.1. In short, significant work must still be completed before IEEE 1547-2018 compliant DERs will be available.70

As such, the key industry certification and testing standards necessary to support approval of the usage of smart inverters for reactive power applications are not yet available.71 For these reasons, we find that it is premature to require a utility to accept reactive power on its grid at this time or to require the utility to pay an IC because the utility receives compensation for the ability to provide reactive power.72 However, the Commission recognizes that this topic may need to be revisited, and the Interconnection Regulations may need to be reopened for further possible revisions, as a result of the changes to IEEE 1547-2018 and IEEE 1547.1,73 once all of the necessary testing and certification processes have been completed.74

Cypress Creek's Recommended Changes to the Proposed Rules

Cypress Creek recommends several changes to the Proposed Rules. First, Cypress Creek proposes the following change to 20 VAC 5-314-10:

Any IC that has not executed an interconnection agreement with the utility prior to [the effective date of the 2019 revisions to this chapter] shall have 30 calendar days following the later of [the effective date of the 2019 revisions to this chapter], or the posted date of notice in writing from the utility to demonstrate site control pursuant to Schedules 5 or 6 of 20VAC5-314-l70, and to post an additional deposit as specified in Schedule 6 of 20VAC5‑314‑l70.75

According to Cypress Creek, the above language should be stricken because the new fee schedule should apply only to projects that enter the queue after the adoption of these regulations, and projects that are already in the queue should not be subject to the proposed deposit requirements.76 We disagree with Cypress Creek that all projects in the queue, regardless of where in the queue the project is, whether the project has begun being studied, or whether a deposit has already been made, automatically should be relieved of the deposit requirements. We also note that the Proposed Rules are not imposing any new fees, as ICs will continue to be responsible for the total actual study costs, but instead are simply increasing the required upfront deposit amounts to align more closely with actual study costs. However, we agree that the language should be clarified with respect to projects that have already begun to be studied or have already paid some deposit. The Commission therefore makes the following change to the relevant portion of 20 VAC 5-314-10:

Any IC that has not executed an interconnection agreement with the utility prior to October 15, 2020, shall have 30 calendar days following the later of October 15, 2020, or the posted date of notice in writing from the utility to (i) demonstrate site control pursuant to Schedules 5 or 6 of 20VAC5-314-l70, (ii) execute a combined study agreement as provided for in 20VAC5‑314‑70 or individual revised study agreements conforming with those set forth in Schedules 7, 8, and 9 of 20 VAC 5‑314‑170, and (iii) to post an additional the deposit as specified in Schedule 6 of 20VAC5-314-l70 minus any study costs previously paid.

Next, Cypress Creek recommends adding language to the SGIA to prohibit the reissuance of SGIAs at a higher cost than the original agreement to ensure utilities "[b]ear the risk of signing contracts that have significant inaccuracies."77 We recognize Cypress Creek's concerns but also find it appropriate for ICs to pay the actual project costs, even if those actual costs exceed the utility's initial estimates.78 We note that the Proposed Rules newly introduce a construction planning meeting that precedes execution of the SGIA. This meeting should provide an additional opportunity for parties to review project details and potentially identify inaccuracies in the SGIA before it is executed, reducing the probability that additional changes in the SGIA will become necessary after it has been executed.79 The Proposed Rules and the SGIA also include a dispute resolution procedure to address situations where the IC and utility cannot come to agreement on an issue.80

Cypress Creek also recommends changes to the Proposed Rules to permit the provision of reactive power to the grid and to require a utility to pay the IC if the utility receives compensation for its ability to provide reactive power. We decline to adopt such changes at this time for the reasons previously discussed.

Finally, to the extent that a requested revision by any participant in this proceeding is not specifically addressed above, we find that the requested revision is not necessary or appropriate at this time for purposes of implementing these Interconnection Regulations. However, our denial of any proposals herein does not preclude participants from recommending the same or similar changes in future rulemaking proceedings.

Accordingly, IT IS ORDERED THAT:

(1) The Regulations Governing Interconnection of Small Electrical Generators and Storage, 20 VAC 5-314-10 et seq., as shown in Appendix A to this Order, hereby are adopted and are effective as of October 15, 2020.

(2) The Commission's Information Resources Division forthwith shall send a copy of this Final Order and the attached regulations to the Registrar of Regulations for publication in the Virginia Register of Regulations.

(3) A copy of this Final Order and the attached regulations forthwith shall be posted on the website of the Division of Public Utility Regulation. In addition, the Staff of the Division of Public Utility Regulation shall email a copy of the Final Order and attached regulations to all persons and entities who participated in the workgroup held to receive input on the regulations and/or who filed comments in this docket.

(4) The Interim Clerk of the Commission hereby is directed to serve a copy of the attached regulations on every investor‑owned electric utility and electric cooperative in the Commonwealth, who shall forthwith thereafter notify all their interconnection customers of this Final Order and the attached regulations.

(5) This case is dismissed.

AN ATTESTED COPY hereof shall be sent electronically by the Clerk of the Commission to: C. Meade Browder, Jr., Senior Assistant Attorney General, Office of the Attorney General, Division of Consumer Counsel.

________________________________________

1Commonwealth of Virginia, ex rel. State Corporation Commission, Ex Parte: In the matter of establishing interconnection standards for distributed electric generation, Case No. PUE-2008-00004, 2009 S.C.C. Ann. Rept. 287, Order Adopting Regulations (May 8, 2009).

2Commonwealth of Virginia, ex rel. State Corporation Commission, Ex Parte: In the matter of establishing interconnection standards for distributed electric generation, Case No. PUE-2008-00004, 2008 S.C.C. Ann. Rept. 469, Order Establishing Proceeding (Feb. 26, 2008).

3In 2013, the Commission amended numerous rules and regulations, including the Interconnection Regulations, to: (1) recognize certain internal organizational changes; (2) correct outdated references to statutes in the Code and remove obsolete rules and schedules that are no longer required; and (3) bring the regulations into compliance with the Virginia Register Form, Style and Procedures Manual issued by the Virginia Code Commission. See Commonwealth of Virginia, ex rel. State Corporation Commission, Ex Parte: In the matter of amending regulations, Case No. PUE‑2013-00016, 2013 S.C.C. Ann. Rept. 367, Order Amending Regulations (June 18, 2013).

4Staff Report at 2-3.

5The Proposed Rules were published in the Virginia Register of Regulations on December 23, 2019.

6Appalachian Power Company filed a letter stating it would not file comments.

7In its comments, VMDAEC did not request a hearing but stated that "a hearing on this matter would be helpful to the overall rulemaking process [and the Cooperatives] intend to participate in such a hearing if the Commission deems a hearing to be appropriate." VMDAEC comments at 13. We do not deem a hearing to be necessary in this proceeding.

8See Board of Supervisors of Loudoun County v. State Corp. Comm'n, 292 Va. 444, 454 n.10 (2016) ("We note that even in the absence of this representation by the Commission, pursuant to our governing standard of review, the Commission's decision comes to us with a presumption that it considered all of the evidence of record.") (citation omitted).

9Related changes were also made to the following provisions of the Interconnection Regulations: 20 VAC 5-314-39; 20 VAC 5-314-150; Schedule 1 of 20 VAC 5-314-170; and Schedule 10 of 20 VAC 5-314-170 at Attachment 1.

10See VMDAEC comments at 3-13.

11Id. at 12; Staff comments at 26.

12VMDAEC comments at 11; Staff comments at 23.

13VMDAEC comments at 12; Staff comments at 25.

14VMDAEC comments at 12; Staff comments at 25.

15VMDAEC comments at 11.

16Staff comments at 15-16; VMDAEC comments at 7.

17VMDAEC comments at 8-9; Staff comments at 6, 17. See also Dominion comments at 16-17.

18VMDAEC comments at 10; Staff comments at 21.

19Schedule 10 of 20 VAC 5-314-170 at Article 4.

20VMDAEC comments at 4.

21Id. at 3.

22Id. at 4.

23See, e.g., Staff comments at 9-11.

24Id. at 11.

25See 20 VAC 5-314-20; VMDAEC comments at 9-10.

26VMDAEC comments at 9-10.

27Id. at 7.

28Staff Report at 3-4.

29See, e.g., id. at 4.

30See Staff comments at 16, n.39.

31The FERC Rules have been revised since 2009. See Requirements for Frequency and Voltage Ride Through Capability of Small Generating Facilities, Order No. 828, 156 FERC 61,062 (2016); Small Generator Interconnection Agreements and Procedures, Order No. 792, 145 FERC 61,159 (2013).

32VMDAEC comments at 8-9.

3320 VAC 5‑314‑130.

34VMDAEC comments at 8.

35Id. at 9. Collecting and maintaining the data likely represents a significant portion of the effort required to make the annual reports.

36However, we do find that the following edit should be made to 20 VAC 5‑314‑130 B: ''Each utility shall annually, on or before January 31, file submit a written report with to the commission staff ….''

37See 20 VAC 5­‑314-10 B.

38VMDAEC comments at 10.

39Id.

40Staff comments at 20-21.

41See 20 VAC 5-314-70 F.

42See id; Schedule 10 of 20 VAC 5-314-170 at Article 6.2.

43VMDAEC comments at 10.

44See Staff comments at 20.

45VMDAEC comments at 10-12.

46Id. at 12.

47See 20 VAC 5-315-40 A; Staff comments at 26.

48VMDAEC comments at 5; Staff comments at 12. See, e.g., Schedule 10 of 20 VAC 5‑314-170 at Articles 4.2-4.3.

49VMDAEC comments at 5. See also Schedule 6 of 20 VAC 5-314-170 at Section 2. The Facilities Study Agreement also requires ICs to pay any study costs that exceed the deposit within 20 business days. See Schedule 9 of 20 VAC 5-314-170 at Section 5.2.

50VMDAEC comments at 6-7; Staff comments at 12-15. See also 20 VAC 5-314-70 C(5); 20 VAC 5-314-70 D(5); and Schedule 9 of 20 VAC 5-314-170 at Section 9.0.

51VMDAEC comments at 7; Staff comments at 16.

52VMDAEC comments at 9; Staff comments at 19. We further decline to amend the definition of "network upgrades" for the reasons discussed above.

53VMDAEC comments at 11; Staff comments at 22; Schedule 10 of 20 VAC 5-314-170 at Article 1.8.1.

54Dominion comments at 15.

55Staff comments at 4.

56Id.

57Id. We also note that ICs may reduce their generating capacity by up to 60% prior to the commencement of the feasibility study under the PJM interconnection process, which is significantly higher than the proposed 25% reduction that we approve herein. Id. at 5.

58See Dominion comments at 17.

59Dominion redline at 51.

60Staff comments at 7.

61VA Solar comments at 1.

62Id.

63Staff comments at 27-28.

64See, e.g., Schedule 7 of 20 VAC 5-314-170 at Section 4.2; Schedule 8 of 20 VAC 5-314-170 at Section 4.2; and Schedule 9 of 20 VAC 5-314-170 at Section 5.2. See also Schedule 10 of 20 VAC 5‑314-170 at Article 6.1.

65Should a utility undertake certain grid improvement projects, such as, for example, engaging in a hosting capacity analysis, the costs of such analysis should not be borne by ICs as part of these regulations, and any benefits, such as a decrease in study costs, that would result from these grid improvements should be passed along to ICs so that the ICs pay only the true costs of interconnecting.

66VA Solar comments at 2.

67Id. at 2 (emphasis omitted).

68IEEE Standard for Interconnection and Interoperability of Distributed Energy Resources with Associated Electric Power Systems Interfaces, The Institute of Electrical and Electronics Engineers, Inc., Standard 1547, 2018.

69Staff Report at 5.

70Id. at 6-7 (internal citations omitted).

71Subsequent to the filing of the September 12, 2019 Staff Report, IEEE 1547.1 ("IEEE1547.1-2020") was published. However, it does not appear that all of the processes described in the Staff Report have been completed, including the update to the UL 1741 Standard. Nor does the record in this case suggest that any smart inverters have yet been certified to operate consistent with the recently published IEEE 1547.1-2020. See IEEE Standard Conformance Test Procedures for Equipment Interconnecting Distributed Energy Resources with Electric Power Systems and Associated Interfaces, The Institute of Electrical and Electronics Engineers, Inc., Standard 1547.1-2020, 2020.

72We note that the Proposed Rules do address reactive power and would allow the IC and utility to mutually agree upon the power factor range of the output of the SGF. See Schedule 10 of 20 VAC 5‑314‑170 at Article 1.8. As Staff discusses, "This added language gives more latitude to the IC but still gives the utility the ability to dictate the required limits for its system." Staff comments at 28. We further note that Article 1.8.2 of Schedule 10 does require the utility to pay the IC for reactive power in certain circumstances:

The [u]tility is required to pay the IC for reactive power that the IC provides or absorbs from the SGF when the [u]tility requests the IC to operate its SGF outside the range specified in Section 1.8.1 of this Agreement, unless mutually agreed upon by the [p]arties. In addition, if the [u]tility pays its own or affiliated generators for reactive power service within the specified range, it must similarly pay the IC.

73IEEE Standard Conformance Test Procedures for Equipment Interconnecting Distributed Resources with Electric Power Systems, The Institute of Electrical and Electronics Engineers, Inc., Standard 1547.1, July 1, 2005.

74In addition, we note that the National Association of Regulatory Utility Commissioners ("NARUC") recently adopted a resolution recommending that states examine the possibility of adopting or implementing the determinations and requirements set forth in IEEE Standard 1547-2018. See NARUC Resolution Recommending State Commissions Act to Adopt and Implement Distributed Energy Resource Standard IEEE 1547-2018, Feb. 12, 2020.

75Cypress Creek comments at 1.

76Id.

77Id. at 3.

78While we recognize that actual construction costs encountered after an SGIA is executed may in some cases differ from utilities' engineering estimates determined during the study process, we nevertheless expect utilities to give accurate good-faith estimates at all stages of the study process.

79See 20 VAC 5-314-70 F.

80See 20 VAC 5-314-100; Schedule 10 of 20 VAC 5-314-170 at Article 10.

[ CHAPTER 314
REGULATIONS GOVERNING INTERCONNECTION OF SMALL ELECTRICAL GENERATORS AND STORAGE ]

20VAC5-314-10. Applicability and scope; waiver.

A. These regulations are This chapter is promulgated pursuant to § 56-578 of the Virginia Electric Utility Regulation Act (§ 56-576 et seq. of the Code of Virginia). They establish This chapter establishes standardized interconnection and operating requirements for the safe operation of electric generating facilities with a rated capacity of 20 megawatts (MW) or less connected to electric utility distribution (and in certain cases transmission) systems in Virginia. These regulations apply This chapter applies to utilities providing interconnections to retail electric customers, independently owned generators, and any other parties operating, or intending to operate, a distributed generation generating facility in parallel with utility systems. [ This chapter also applies to equipment used for the storage of electricity for later injection to utility systems. ] These regulations do This chapter does not apply to customer generators operating pursuant to the Virginia State Corporation Commission's Regulations Governing Net Energy Metering (20VAC5-315) or those that fall under the jurisdiction of the Federal Energy Regulatory Commission (FERC).

If the utility has turned over control of its transmission system to a Regional Transmission Entity (RTE), and if the small generator interconnection process identifies upgrades to the transmission system as necessary to interconnect the small generating facility, then the utility will coordinate with the RTE, and the procedures herein in this chapter will be adjusted as necessary to satisfy the RTE's requirements with respect to such upgrades.

There are three review paths for the interconnection of generation generating facilities subject to this chapter in Virginia having an output of not more than 20 MW:

Level 1 - A request to interconnect a certified small generating facility (SGF) no larger than 500 kilowatts (kW) shall be evaluated under the Level 1 process.

Level 2 - A request to interconnect a certified SGF no larger than 2 MW and not qualifying for the Level 1 process shall be evaluated under the Level 2 process.

Level 3 - A request to interconnect an SGF no larger than 20 MW and not qualifying for the Level 1 process or Level 2 process, shall be evaluated under the Level 3 process.

The utility may limit place restrictions upon the interconnection of an SGF to a distribution feeder to a capacity substantially less than 20 MW, depending upon the characteristics of that feeder and the potential for upgrading it, as well as the nature of the loads and other generation on the feeder relative to the proposed point of interconnection. If the SGF cannot be safely and reliably interconnected to the utility's distribution feeder, the utility shall work with the IC interconnection customer (IC) to interconnect the SGF to the utility's transmission system. In such cases, the interconnection of the SGF may be governed by the regulations promulgated by FERC rather than the regulation of the Virginia State Corporation Commission.

The utility shall designate an employee or office from which the interconnection customer (IC) IC may informally request information concerning the interconnection application process. The name, telephone number, and email address of such contact employee or office shall be made available on the utility's Internet website. Electric Readily available electric system information relevant to the location of the proposed SGF shall be provided to the IC upon request, in writing, and may include interconnection studies and any other relevant materials, to the extent such provision does not violate confidentiality provisions of prior agreements or release critical infrastructure information. The utility shall comply with reasonable requests for such information unless the information is proprietary or confidential and cannot be provided pursuant to a prior confidentiality agreement. If the information is proprietary or confidential and cannot be provided, the utility shall state as such.Any one developer shall have no more than five active informal requests for information at one time. ]

The utility shall make reasonable efforts to meet all time frames timeframes provided in these regulations unless the utility and the IC agree to a different schedule. If the utility cannot meet a deadline provided herein in this chapter, it shall notify the IC in writing, explain the reason for the failure to meet the deadline, and provide an estimated time by which it will complete the applicable interconnection procedure in the process.

Should an IC fail to meet a timeframe or default on another requirement under this chapter or fail to respond to a request for information from the utility, the utility shall also provide the IC written notice identifying the missed deadline or requirement and allow the IC an opportunity to cure on or before the close of business on the 10th business day following the posted date of such notice to cure, prior to the utility taking action to withdraw the IC's interconnection request.

Each utility shall have on file with the commission terms and conditions applicable to the interconnection of SGFs. Such terms and conditions shall, at a minimum, incorporate this chapter by reference, shall set forth terms and conditions applicable to SGFs for which no Small Generator Interconnection Agreement (SGIA) is executed, and shall not conflict with the provisions of this chapter. The terms and conditions applicable to SGFs for which no SGIA is executed shall be reasonably consistent with the terms and conditions of the SGIA.

B. The commission may waive any or all parts of the provisions of this chapter for good cause shown.

C. This chapter shall not apply to SGFs already interconnected as of(insert the effective date of this chapter) October 15, 2020 ], unless:

1. The IC proposes a material modification; or

2. Application of this chapter is agreed to in writing by the utility and the IC.

D. This chapter shall apply if the IC has not actually interconnected the SGF as of (insert the effective date of this chapter) October 15, 2020 ].

Any IC that has not executed an interconnection agreement with the utility prior to(insert the effective date of this chapter) October 15, 2020, ] shall have 30 calendar days following the later of(insert the effective date of this chapter) October 15, 2020, ] or the posted date of notice in writing from the utility to(i) ] demonstrate site control pursuant to Schedule 5 or 6 of 20VAC5-314-170; (ii) execute a combined study agreement as provided for in 20VAC5-314-70 or individual revised study agreements conforming with those set forth in Schedules 7, 8, and 9 of 20VAC5-314-170; ] and(iii) ] to postan additional the ] deposit as specified in Schedule 6 of 20VAC5-314-170minus any study costs previously paid ].

Any IC that has executed an interconnection agreement with the utility prior to(insert the effective date of this chapter) October 15, 2020, ] but where the utility has not actually interconnected the SGF or where the IC has not begun making payments, shall have 60 calendar days following the later of(insert the effective date of this chapter) October 15, 2020, ] or the posted date of notice in writing from the utility to submit upgrade and interconnection facility payments (or financial security acceptable to the utility for attachment facilities and distribution upgrades) required pursuant to 20VAC5-314-50 F 2. Any amount previously paid by the IC at the time the deposit or payment is due under this subsection shall be credited toward the deposit amount or other payment required under this subsection.

Should an IC fail to comply with the provisions of this subsection following receipt of a written notice specifying how the IC failed to comply and the expiration of an opportunity to cure by the close of business on the 10th business day following the posted date of such notice to cure, the IC will lose its queue number and the interconnection request shall be deemed withdrawn.

20VAC5-314-20. Definitions.

The following terms when used in this chapter shall have the following meaning unless the context clearly indicates otherwise:

"Affected system" means an electric utility system other than that of the utility that may be affected by the proposed interconnection.

"Affected system operator" means an entity that operates an affected system or, if the affected system is under the operational control of an independent system operator or a regional transmission entity, such independent entity.

"Applicable laws and regulations" means all duly promulgated applicable federal, state, and local laws, regulations, rules, ordinances, codes, decrees, judgments, directives, or judicial or administrative orders, permits, and other duly authorized actions of any government authority.

"Attachment facilities" means the facilities and equipment owned, operated, and maintained by the utility that are built new in order to physically connect the customer's interconnection facilities to the utility system. Attachment facilities shall not include distribution upgrades or previously existing distribution and transmission facilities.

"Business day" means Monday through Friday, excluding federal holidays.

"Calendar day" means Sunday through Saturday, including all holidays.

"Certified" has the meaning ascribed to it in Schedule 2 of this chapter 20VAC5-314-170.

"Commission" means the Virginia State Corporation Commission.

"Competitive service provider" means any entity, other than the utility, supplying electric energy service to the interconnection customer.

"Customer's interconnection facilities" means all of the facilities and equipment owned, operated, and maintained by the interconnection customer IC, between the small generating facility and the point of interconnection necessary to physically and electrically interconnect the small generating facility to the utility system.

"Default" means the failure of a breaching party to cure its breach under the small generator interconnection agreement SGIA.

"Distribution system" means the utility's facilities and equipment generally delivering electricity to ultimate customers from substations supplied by higher voltages (usually at transmission level). For purposes of these regulations this chapter, all portions of the utility's transmission system regulated by the commission for which interconnections are not within Federal Energy Regulatory Commission (FERC) FERC jurisdiction are considered also to be subject to these interconnection regulations this chapter.

"Distribution upgrades" means the additions, modifications, and upgrades enhancements made to the utility's distribution system at or beyond on the utility's side of the point of interconnection necessary to abate problems ensure continued system reliability and power quality on the utility's distribution system caused by the interconnection of the small generating facility SGF. Distribution upgrades do not include network upgrades or the customer's interconnection facilities or the utility's attachment facilities.

"Facilities study" has the meaning ascribed to it in 20VAC5-314-70 E.

"Feasibility study" has the meaning ascribed to it in 20VAC5-314-70 C.

"FERC" means the Federal Energy Regulatory Commission.

"Good Utility Practice" means any of the practices, methods, and acts engaged in or approved by a significant portion of the electric industry during the relevant time period, or any of the practices, methods, and acts which that, in the exercise of reasonable judgment in light of the facts known at the time the decision was made, could have been expected to accomplish the desired result at a reasonable cost, consistent with good business practices, reliability, safety, and expedition. Good Utility Practice is not intended to be limited to the optimum practice, method, or act to the exclusion of all others, but rather to be acceptable include practices, methods, or acts generally accepted in the region.

"Governmental authority" means any federal, state, local, or other governmental regulatory or administrative agency, court, commission, department, board, or other governmental subdivision, legislature, rulemaking board, tribunal, or other governmental authority having jurisdiction over the parties, their respective facilities, or the respective services they provide, and exercising or entitled to exercise any administrative, executive, police, or taxing authority or power; provided that such term does not include the interconnection customer IC, the utility, or a utility affiliate.

"Interconnection customer" or "IC" means any entity proposing to interconnect a new small generating facility with the utility system.

"Interconnection request" means the IC's request, in accordance with this chapter, to interconnect a new small generating facility, or to increase the capacity of, or make a material modification to the operating characteristics of, an existing small generating facility that is interconnected with the utility system.

"Interconnection studies" means the studies conducted by the utility, or, if agreed to by the utility and the IC, a third party agreed to by the utility and the interconnection customer supervised by the utility, in order to determine the interaction of the small generating facility with the utility system and the affected systems in order to specify any modifications to the small generating facility or the electric systems studied to ensure safe and reliable operation of the small generating facility in parallel with the utility system.

"Interdependent customer" or "interdependent project" means an IC or project whose upgrades to the utility system or attachment facilities are impacted by another earlier-queued generating facility, as determined by the utility.

"Material modification" means a modification that has a material impact on the cost or timing of any interconnection request with a later queue priority date has the meaning ascribed to it in 20VAC5-314-39.

"Maximum generating capacity" means the maximum continuous electrical output of the SGF at any time as measured at the point of interconnection or the maximum kW delivered to the utility during any metering period, whichever is greater. Requested maximum generating capacity will be specified by the IC in the interconnection request and an approved maximum generating capacity will subsequently be included as a limitation in the interconnection agreement.

"Network upgrades" means additions, modifications, and enhancements to the utility's transmission system that are required in order to accommodate the interconnection of the small generating facility with the utility's system. Network upgrades do not include distribution upgrades.

"Operating requirements" means any operating and technical requirements that may be applicable due to regional transmission entity, independent system operator, control area, or the utility's requirements, including those set forth in the Small Generator Interconnection Agreement SGIA.

"Party" or "parties" means the utility, interconnection customer or both or the IC.

"Point of interconnection" means the point where the customer's interconnection facilities connect physically and electrically to the utility utility's system.

"Processing fee" means a nonrefundable cost to administer or file an application. ]

"Project A" means any interconnection request that is not interdependent with another interconnection request.

"Project B" means any interconnection request that is interdependent with only one other interconnection request and ] has a higher queue number thana designated ] Project A.

"Queue number" refers to the number assigned by the utility, establishing a customer's interconnection request position in the study queue relative to all other valid interconnection requests. A lower queue number will be studied prior to a higher queue number, except in the case of interdependent projects.

"Regional Transmission Entity" or "RTE" means an entity having the management and control of a utility's transmission system as further set forth in § 56-579 of the Code of Virginia.

"Small generating facility" or "generating facility" or "generator" or "SGF" means the interconnection customer's IC's equipment used for the production of electricity [ or storage for later injection ], as identified in the interconnection request.

"Small Generator Interconnection Agreement" or "SGIA" means the agreement between the utility and the interconnection customer IC as set forth in Schedule 6 10 of 20VAC5-314-170.

"Standby generating facility" means an electric generating facility primarily designed for standby or backup power in the event of a loss of power supply from the utility. Such facilities may operate in parallel with the utility for a brief period of time when transferring load back to the utility after an outage, or when testing the operation of the facility and transferring load from and back to the utility.

"Supplemental review" has the meaning ascribed to it in 20VAC5-314-60 I H.

"System" or "utility system" means the distribution and transmission facilities owned, controlled, or operated by the utility that are used to deliver electricity.

"System impact study" has the meaning ascribed to in 20VAC5-314-70 D.

"System upgrades" means distribution upgrades and network upgrades collectively.

"Tariff" means the rates, terms, and conditions filed by the utility with the commission for the purpose of providing commission-regulated electric service to retail customers.

"Transmission system" means the utility's facilities and equipment delivering electric energy to the distribution system, such facilities being operated at voltages voltage levels above the utility's typical distribution system voltages voltage levels.

"Utility" means the public utility company subject to regulation by the commission pursuant to Chapter 10 (§ 56-232 et seq.) of Title 56 of the Code of Virginia with regard to rates and/or or service quality, to which whose system the interconnection customer IC proposes to interconnect a small generating facility.

20VAC5-314-30. Siting of distributed generation facilities.

Prior to installing a small generating facility an SGF, the interconnection customer IC must ensure compliance with local, state, and federal laws and regulations, including all applicable easements and permits, and §§ 56-265.2 and 56-580 of the Code of Virginia, as applicable.

20VAC5-314-35. Preapplication.

A. The IC may informally request electric system information for a proposed project for a specific site by providing in writing details of the potential generating facility project, including site address, grid coordinates, project size, and proposed point of interconnection, to the utility's designated employee or office described in 20VAC5-314-10. Electric system information provided to the IC in response to the informal requests shall include relevant system studies, interconnection studies, and other materials useful to providing an understanding of an interconnection at a particular point on the utility's distribution system, to the extent such provision does not violate confidentiality provisions of prior agreements or critical infrastructure requirements. The utility shall comply with reasonable requests for such information in a timely manner, not to exceed 10 business days. The information produced by the utility is nonbinding, does not confer any rights, and the IC shall still successfully apply to interconnect to the utility's system. The IC shall still meet the requirements of 20VAC5-314-40 or 20VAC5-314-50 to apply to interconnect to the utility's system and to obtain a queue number. Any one developer shall have no more than five active informal requests for information at one time.

B. In addition to the option of informally requesting information described in subsection A of this section, an IC may submit a formal written request form along with a nonrefundable fee of $500 for a preapplication report on a proposed project at a specific site. The utility shall provide the preapplication data described in subsection C of this section to the IC within 20 business days of receipt of the completed request form and payment of the fee. The preapplication report produced by the utility is nonbinding, does not confer any rights, and the IC must still successfully apply to interconnect to the utility's system. The written Preapplication Report Request Form shall include all of the information as described in Schedule 4 of 20VAC5-314-170. The utility shall notify the IC if there are any deficiencies in the IC's submittal within five business days of submission of the Preapplication Report Request Form.Any one developer shall have no more than five active formal requests for information at one time. ]

C. Using the information provided in the Preapplication Report Request Form in subsection B of this section,and as described in Schedule 4 of 20VAC5-314-170, ] the utility will identify the substation or area bus, bank, or circuit likely to serve the proposed point of interconnection. This selection by the utility does not necessarily indicate, after application of the Level 2 screens or Level 3 study process, that this point of interconnection will be suitable or the most costs effective for interconnection. The IC must request additional preapplication reports if information about multiple points of interconnection is requested. Subject to subsection D of this section, the preapplication report will provide the following information:

1. Total capacity (in MW) of substation or area bus, bank, or circuit based on normal or operating ratings likely to serve the proposed point of interconnection.

2. Existing aggregate generation capacity (in MW) interconnected to a substation or area bus, bank, or circuit (i.e., amount of generation online) likely- to serve the proposed point of interconnection.

3. Aggregate queued generation capacity (in MW) for a substation or area bus, bank, or circuit (i.e., amount of generation in the queue) likely to serve the proposed point of interconnection.

4. Substation nominal distribution voltage or transmission nominal voltage if applicable.

5. Nominal distribution circuit voltage at the proposed point of interconnection.

6. Approximate circuit distance between the proposed point of interconnection and the substation.

7. Relevant line sections actual or estimated peak load and minimum load data, including daytime minimum load and absolute minimum load, when available.

8. Number and rating of protective devices and number and type (standard, bidirectional) of voltage regulating devices between the proposed point of interconnection and the substation or area. At the substation, identify the number of capacitors and if the substation has a load tap changer.

9. Number of phases available at the proposed point of interconnection. If a single phase, distance from the three-phase circuit.

10. Limiting conductor ratings from the proposed point of interconnection to the distribution substation.

11. Whether the proposed point of interconnection is located on a spot network, grid network, or radial supply.

12. Based on the proposed point of interconnection, existing or known constraints such as, but not limited to, electrical dependencies at that location, short circuit interrupting capacity issues, power quality or stability issues on the circuit, capacity constraints, or secondary networks.

13. Other information regarding an affected system the utility deems relevant to the IC (e.g., substation upgrades that allow bidirectional power flows).

D. The preapplication report need only include existing data that is readily available to the utility. A preapplication report request does not obligate the utility to conduct a study or other analysis of the proposed generator in the event that data is not readily available. If the utility cannot complete all or some of a preapplication report due to lack of available data, the utility shall provide the IC with a preapplication report that includes the data that is available as well as a description of any data that was not available. Notwithstanding any of the provisions of this section, the utility shall, in good faith, include data in the preapplication report that represents the best available information at the time of reporting.

20VAC5-314-38. Queue number and interdependent projects.

A. Queue number and queue position. The utility shall assign a queue number to an interconnection request based upon the date-stamp and time-stamp of receipt of a completed Interconnection Request Form by the utility. A later received Interconnection Request Form shall be assigned a higher numerical queue number than an earlier received Interconnection Request Form. The queue number and relative position of each interconnection request will be used to determine the cost responsibility for the upgrades necessary to accommodate the interconnection.

B. Interdependent projects.

1. Upon an IC's submission of an interconnection request for the 20VAC5-314-40 Level 1 interconnection process,20VAC5-314-60 Level 2 interconnection process, or 20VAC5-314-70 Level 3 interconnection process, the utility shall review the interconnection request and make a preliminary determination of whether any interdependencies exist between the IC's proposed SGF and any other IC with a lower queue number. If the interconnection request is for a standby SGF with zero export, then the proposed SGF shall be studied as a Project A. For all other interconnections, any preliminary determination by the utility that the SGF does not create an interdependency will result in the interconnection request being preliminarily designated as a Project A, and the utility shall proceed immediately to either the 20VAC5-314-40, 20VAC5-314-60, or 20VAC5-314-70 Level 1, 2, or 3 study process, as applicable. At the 20VAC5-314-70 B scoping meeting, the utility shall advise the IC regarding its preliminary determination of whether interdependency would be created by the SGF. If no 20VAC5-314-70 B scoping meeting is scheduled, then the utility shall notify the IC in writing within five business days after making its preliminary determination of whether interdependency would be created by the SGF. If applicable, the Project A IC will pay the interconnection request study deposit required for the 20VAC5-314-70 Level 3 study process as identified in Schedule 6 of 20VAC5-314-170in conjunction with the execution of the initial study agreement delivered by the utility pursuant to 20VAC5-314-70 ]. An SGF preliminarily reviewed for system impacts and designated as a Project A may still be determined later to create an interdependency and may then be redesignated by the utility as an interdependent project during the 20VAC314-70 D system impact study process, thereby losing its Project A designation. Once the system impact study report is issued by the utility and the report designates an SGF as a Project A for purposes of the 20VAC314-70 E facilities study, the interconnection request shall retain this Project A designation during the facilities study, without change.

2. If the utility determines that the IC's proposed SGF is interdependent with oneor more ] other interconnectionrequests request ] with a lower queue number (i.e., an earlier submitted interconnection request), the utility shall notify the IC in writing or at the 20VAC5-314-70 B scoping meeting that the interconnection request is designated as a Project B.

a. Following the 20VAC5-314-70 B scoping meeting, the Project B IC shall then have the option to either:

(1) Wait without further advancement of the interconnection request until Project A has executed a final interconnection agreement and begun making payments for any required upgrades, customer interconnection facilities, and other charges under 20VAC314-50D F ]. Under this option, Project B is not required to adhere to the timeline in 20VAC5-314-70 C until Project A has signed an SGIA and begun making payments or withdrawn its interconnection request; or

(2) Proceed to the 20VAC314-70 D system impact study process. If the Project B IC chooses this option, the utility shall provide the Project B IC a Feasibility Study Agreement pursuant to 20VAC5-314-70 C or a System Impact Study Agreement pursuant to 20VAC5-314-70 D within 10 business days. If the Project B IC signs a System Impact Study Agreement and pays the interconnection request study deposit pursuant to Schedule 6 of 20VAC5-314-170, the Project B shall receive a system impact study report that assumes the Project A interconnection request with the lower queue number completes construction and interconnection, and another system impact study report that assumes the Project A interconnect request with the lower queue number is not constructed and is withdrawn. The Project B IC is responsible for all costs for studying with and without Project A.

b. The utility shall not proceed to a Project B facilities study until after the Project B IC returns a signed Facilities Study Agreement to the utility and the utility has issued the 20VAC314-70 E facilities study report for Project A. Once the Project A facilities study report has been issued, the Project B IC shall then have the option to either:

(1) Wait without further advancement of the interconnection request until Project A has executed a final interconnection agreement and begun making payments for any required upgrades, customer interconnection facilities, and other charges under 20VAC314-50D F ]. Under this option, Project B is not required to adhere to the timeline in 20VAC5-314-70 E until Project A has signed an SGIA and begun making payments or withdrawn its interconnection request; or

(2) Proceed with a 20VAC314-70 E facilities study process. If the Project B IC chooses this option, the utility shall provide the Project B IC a Facilities Study Agreement pursuant to 20VAC5-314-70 E within 10 business days. If the Project B IC signs a Facilities Study Agreement prior to Project A committing to construction by signing the final interconnection agreement and beginning to make payments, then Project B's facilities study shall assume that the Project A interconnection request with the lower queue number will complete construction and interconnection. If Project A is later canceled prior to the Project A IC making payment for the required upgrades, the utility shall revise the Project B facilities study at the Project B IC's expense.

3. If the utility determines that the IC's proposed SGF is interdependent with more than one other interconnection request with a lower queue number (i.e., an earlier submitted interconnection request), the utility shall notify the IC at the 20VAC5-314-70 B scoping meeting and describe generally the number and type of interdependencies of interconnection requests with lower queue numbers.

a. The utility shall not study a project if it is interdependent with more than one earlier queued project. The utility will study a project when interdependency with only one earlier queued project exists. The removal of interdependency with multiple projects may be the result of (i) upgrades to the utility system that eliminate the cause of the interdependency, (ii) withdrawal of interdependent projects with lower queue numbers, or (iii) a lower queue number project signing an interconnection agreement and making payments identified in their SGIA.

b. Within five business days of an interconnection request becoming a Project B interconnection request that is interdependent with only one other interconnection request with a lower queue number, the utility shall schedule the 20VAC5-314-70 B scoping meeting and provide the new Project B IC the options specified in subdivision 2 a of this subsection. Upon being designated by the utility as a Project B, the IC's queue number shall be used to determine the order in which the interconnection request is studied under 20VAC314-70 D relative to all other interconnection requests.

C. Interconnection requests submitted prior to(insert the effective date of this chapter) October 15, 2020 ]. Other than as set forth in 20VAC5-314-10 C, nothing in this chapter affects an IC's queue number assigned before(insert the effective date of this chapter) October 15, 2020 ]. Interconnection requests that have received a system impact study report as of(insert the effective date of this chapter) October 15, 2020, ] that did not identify any interdependency with another project shall be deemed a Project A. Any interconnection requests for which the utility has not completed the system impact study and issued a system impact study report (or combined study report, as applicable) to the IC as of(insert the effective date of this chapter) October 15, 2020, ] shall be reviewed for interdependency pursuant to this section.

Should an IC fail to comply with 20VAC5-314-10 C following receipt of written notice specifying how the IC failed to comply and the expiration of an opportunity to cure by the close of business on the 10th business day following the posted date of such notice to cure, the IC shall lose its queue number and the interconnection request shall be deemed withdrawn.

20VAC5-314-39. Modification of the interconnection request.

A. As used in this chapter, "material modification" means a modification to machine data or equipment configuration or to the interconnection site of the SGF that has a material impact on the cost, timing, or design of any customer interconnection facilities or upgrades or that may adversely impact other interdependent interconnection requests with higher queue numbers. Material modifications include certain project revisions as defined insubdivision subsection ] B of this section, but exclude certain project revisions as defined insubdivision subsection ] C of this section.

B. Changes that qualify as material modifications are described as follows:

1. A change in point of interconnection to a new location, unless the change in a point of interconnection is on the same circuit less than two poles away from the original location, and the new point of interconnection is within the same protection zone as the original location;

2. A change or replacement of generating equipment, such as generators, inverters, transformers, relaying, or controls, that is not a like-kind substitution in size, ratings, impedances, efficiencies, or capabilities of the equipment specified in the original or preceding interconnection request;

3. A change from certified to noncertified devices ("Certified" means certified by an Occupational Safety and Health Administration recognized Nationally Recognized Test Laboratory, to relevant Underwriters Laboratories and Institute of Electrical and Electronics Engineers standards, authorized to perform tests to such standards.);

4. A change of transformer connections or grounding from that originally proposed;

5. A change to certified inverters with different specifications or different inverter control specifications or set-up than originally proposed;

6. An increase of the maximum generating capacity of an SGF; or

7. A change reducing the maximum generating capacity of the SGF (i) by more than 25% before the Feasibility Study Agreement or Combined Study Agreement has been executed or (ii) by more than 10% after the Feasibility Study Agreement or Combined Study Agreement has been executed.

C. Changes thatdo not ] qualify as material modifications are described as follows:

1. A change in ownership of an SGF; the new owner, however, will be required to execute a new Interconnection Request Form and study agreements for any study that has not been completed and the report issued by the utility;

2. A change or replacement of generating equipment, such as generators, inverters, solar panels, transformers, relaying, or controls, that is a like-kind substitution in size, ratings, impedances, efficiencies, or capabilities of the equipment specified in the original or preceding interconnection request;

3. An increase in the DC/AC ratio that does not increase the maximum AC output capability of the generating facility;

4. A decrease in the DC/AC ratio that does not reduce the AC output capability of the generating facility by more than the amount specified in subdivision B 7 of this section.

5. A change in the DC system configuration to include additional equipment that does not impact the maximum generating capacity, daily production profile, or the proposed AC configuration of the SGFor energy storage device ], including DC optimizers, DC-DC converters, DC charge controllers, powerplant controllers, and energy storage devices such that the output is delivered during the same periods and with the same profile considered during the system impact study.

D. To the extent an IC proposes to modify any information provided in the interconnection request deemed complete by the utility, the IC shall submit any such modifications to the utility in writing. If the utility determines that the proposed modifications constitute a material modification, the utility shall notify the IC in writing within 10 business days that the modification is a material modification, and the interconnection request shall be withdrawn from the queue unless the IC withdraws the proposed material modification within 10 business days of receipt of the utility's written notification. If the modification is determined by the utility not to be a material modification, then the utility shall notify the IC in writing that the modification has been accepted and that the IC shall retain its queue number. An IC may seek an informal determination from the utility of whether a proposed modification constitutes a material modification in accordance with subdivision E of this section.

E. Modification inquiry.

1. Prior to making any modification, the IC may submit an informal modification inquiry in writing that requests the utility to evaluate whether the proposed modifications to the original or most recent interconnection request is a material modification. The IC shall provide specific details on all changes that are to be considered by the utility.

2. In response to IC's informal request, if the utility evaluates the proposed modifications and determines that the changes are not material modifications, the utility shall inform the IC in writing within 10 business days. If the IC wishes to proceed with the proposed modifications, the IC shall submit a revised Interconnection Request Form that reflects the approved modifications.

20VAC5-314-40. Level 1 interconnection process.

A. The Level 1 interconnection process is available to any interconnection customer IC proposing to interconnect a small generating facility certified SGF with the utility system if the SGF is no larger than 500 kW.

B. The IC shall submit (i) a complete Level 1 Interconnection Request Form (Schedule 1 in 5 of 20VAC5-314-170) to the utility with; (ii) site control documentation pursuant to Schedule 5 of 20VAC5-314-170; and (iii) the required $100 processing fee attached to the utility. Alternatively, the utility may require use of a commission-approved Interconnection Request Form similar to Schedule 1 5 of 20VAC5-314-170, which shall be made available to customers on the utility's Internet website. The Interconnection Request Form shall be date-stamped and time-stamped by the utility upon receipt by the utility of (i) a substantially complete Interconnection Request Form submitted by a valid legal entity and signed by the IC, (ii) site control documentation, and (iii) processing fee. The date-stamp and time-stamp shall be used as the qualifying start date-stamp and time-stamp for the purpose of any timetable in these procedures.

The IC shall be notified of receipt by the utility within Within three business days of receiving the interconnection request, the utility shall notify the IC of receipt, which notification may shall be made by United States mail, email address, or fax number provided by the IC. As soon as practicable after receipt, but not later than 10 business days after the date of receipt of the interconnection request, the utility shall notify the IC if there are any deficiencies in the IC's submittal. If there are deficiencies, such notice shall include a written list detailing all information that must be provided by the IC to complete the interconnection request.

The IC shall have 10 business days after receipt of the notice of incomplete information to submit the listed information or to request an extension of time to provide such information. The acceptance of such request for time extension shall be at the utility's discretion. If the IC does not provide the listed information or a request for an extension of time within the deadline, the Interconnection Request Form will be deemed withdrawn.

The utility shall provide a copy of the final completed date- and time-stamped Interconnection Request Form to the Commission's Division of Energy Regulation.

C. Within 15 business days after the date the IC submits a complete Interconnection Request Form and requisite fee, the utility shall evaluate the request to determine whether the IC's project is interdependent with one or more earlier-queued projects. If it is determined that the IC's project does not create an interdependency, the utility shall designate the IC's project as Project A, and, if so, shall inform the IC what utility modifications are required to interconnect the SGF. If the utility determines that the IC's project is interdependent with one or more earlier-queued projects, the utility may delay study of the IC request until the interdependency is resolved and the IC becomes a Project A as further addressed in 20VAC5-314-38 B. If the utility delays study of the IC's project, the utility shall notify the IC in writing and identify the number of earlier-queued interdependent projects.

1. If the interconnection can be accomplished with minor modifications (e.g., changing meters, fuses, and relay settings) to the utility system, the IC and the utility may informally agree upon a plan to effectuate the required installations and modifications. The utility shall perform all installations and modifications of the utility system and the IC shall reimburse the utility for the cost of such installations and modifications. The IC shall perform all required modifications to its SGF.

2. Absent If the interconnection cannot be accomplished with minor modifications or the parties cannot come to an agreement between the parties regarding modifications to the utility system within 10 business days of study results being provided by the utility, the interconnection request will be transferred to the Level 2 process or handled according to 20VAC5-314-100 (Disputes) at the IC's option.

3. If the utility cannot reasonably determine that the modifications to the utility's system can be completed without additional study, the utility shall provide the IC, in writing, justification for that determination, and the interconnection request will be transferred to the Level 2 process or handled according to 20VAC5-314-100 at the IC's option.

D. An IC may begin operation of an SGF when any required modifications or additions as provided for in subsection C of this section are complete and when the following additional requirements are satisfied:

1. If required by the utility's tariff, the IC has installed a lockable, utility-accessible, load breaking manual disconnect switch;

2. A licensed electrician has certified, by signing the Interconnection Request Form, that any required manual disconnect switch has been installed properly and that the small generating facility SGF has been installed in accordance with the manufacturer's specifications as well as all applicable provisions of the National Electrical Code;

3. The vendor of the SGF has certified on the Interconnection Request Form that the SGF equipment is in compliance with the requirements established by Underwriters Laboratories or other national testing laboratories in accordance with IEEE Standard 1547, Standard for Interconnecting Interconnection and Interoperability of Distributed Energy Resources with Associated Electric Power Systems Interfaces, 2018;

4. In the case of a static inverter-connected SGF with an alternating current capacity in excess of 10 kilowatts, the IC has had the inverter settings inspected by the utility. The utility may not impose a charge for the fee on the customer of no more than $50 for each generator that requires this inspection;

5. In the case of a nonstatic inverter-connected SGF, the IC has interconnected according to the utility's interconnection guidelines, and the utility has inspected all protective equipment settings. The utility may not impose a charge for such fee on the customer of no more than $50 for each generator that requires this inspection.;

6. The IC has paid, or has made arrangements satisfactory to the utility to pay, the cost of the SGF metering pursuant to 20VAC5-314-80., and any costs associated with minor modifications ];

7. An SGF having an alternating current capacity greater than in excess of 25 kilowatts shall meet the following additional requirements before interconnection may occur:

a. Distribution facilities and customer impact limitations. An SGF shall not be permitted to interconnect to distribution facilities if the interconnection would reasonably utility has reasonably determined that the proposed IC could lead to damage to any of the utility's facilities or would reasonably could lead to voltage regulation or power quality problems at other customer revenue meters due to the incremental effect of the SGF on the performance of the system, unless the IC reimburses the utility for its cost to modify any facilities needed to accommodate the interconnection and such modifications are completed.

b. Secondary, service, and service entrance limitations. The capacity of the SGF shall be less than the capacity of the utility-owned secondary, service, and service entrance cable connected to the point of interconnection, unless the IC reimburses the utility for its cost to modify any facilities needed to accommodate the interconnection and such modifications are completed.

c. Transformer loading limitations. The SGF shall not have the ability to overload the utility's distribution transformer, or any distribution transformer winding, beyond manufacturer or nameplate ratings, unless the IC reimburses the utility for its cost to modify any facilities needed to accommodate the interconnection and such modifications are completed.

d. Integration with utility's grounding. The grounding scheme of the SGF shall comply with the IEEE 1547, Standard for Interconnecting Distributed Resources with Electric Power Systems, and shall be consistent with the grounding scheme used by the utility. If requested by an IC, the utility shall assist the IC in selecting a grounding scheme that coordinates with its the utility's distribution system.

e. Voltage Balance balance limitation. The SGF shall not create a voltage imbalance of more than 3.0% measured from phase to phaseor phase ] to ground at any other customer's revenue meter if the utility distribution transformer, with the secondary connected to the point of interconnection, is a three-phase transformer, unless the IC reimburses the utility for its cost to modify any facilities needed to accommodate the interconnection and such modifications are completed.

E. Site control documentation must be submitted with the Interconnection Request Form. Any information appearing in public records may not be labeled Confidential. (Confidential information is discussed in 20VAC5-314-110.) Site control may be demonstrated through:

1. Ownership of, a leasehold interest in, or a right to develop a site for the purpose of constructing the SGF;

2. An option to purchase or acquire a leasehold site for such purpose;

3. An exclusive or other business relationship between the IC and the entity having the right to sell, lease, or grant the IC the right to possess or occupy a site for such purpose; or

4. An existing permanent service metered account with the utility at the site and in the name of the IC.

F. E. Except as otherwise provided herein in this chapter, neither the utility nor the competitive service provider shall not impose any charges upon an IC for any interconnection requirements specified by this chapter.

G. F. The IC shall immediately notify the utility in writing of any changes in the ownership or control of, operational responsibility for, or contact information for the SGF and pay a $500 processing fee.

H. G. The utility shall not be required to maintain an interconnection with an SGF if the SGF or associated equipment is found to be out of compliance with the codes, standards, and or certifications applicable to the SGF.

I. H. Any IC that is not able to interconnect under the Level 1 interconnection process may apply for interconnection under the Level 2 process or Level 3 process.

20VAC5-314-50. Levels 2 and 3 interconnection request general requirements.

A. The interconnection customer IC shall submit (i) a completed Levels 2 and 3 Interconnection Request Form (Schedule 4 6 of 20VAC5-314-170 to the utility, with the); (ii) site control documentation pursuant to Schedule 6 of 20VAC5-315-170, and (iii) the required $1,000 processing fee or deposit specified in the Interconnection Request Form. The Interconnection Request Form shall be date-stamped and time-stamped by the utility to establish the IC's queue number upon receipt by the utility of (i) a substantially complete Interconnection Request Form submitted by a valid legal entity and signed by the IC, (ii) site control documentation, and (iii) the processing fee. The date-stamp and time-stamp of a completed Interconnection Request Form shall be used as the qualifying start date-stamp and time-stamp for the purposes of any timetable in these procedures. The interconnection customer shall be notified of receipt by the utility within Within three business days of receiving the interconnection request, the utility shall notify the IC of receipt, which notification may shall be made by US United States mail, email address, or fax number provided by the IC.

The utility shall notify the interconnection customer IC within 10 business days of the receipt of the Interconnection Request Form and site control documentation as to whether the Interconnection Request Form documentation is complete or incomplete. If the Interconnection Request Form is incomplete, the utility shall so notify the IC, including a written list detailing all information that must be provided by the IC to complete the Interconnection Request Form.

The interconnection customer IC shall have 10 business days after receipt of the notice of incomplete information to submit the listed information or to request an extension of time to provide such information. The acceptance of such request for time extension shall be at the utility's discretion but shall not exceed an additional 10 business days. If the IC does not provide the listed information or a request for an extension of time within the deadline, the Interconnection Request Form will be deemed withdrawn.

The utility shall provide a copy of the final completed date- and time-stamped Interconnection Request Form to the commission's Division of Energy Regulation.

B. Any material modification to machine data or equipment configuration or to the interconnection site of the small generating facility as specified in the Interconnection Request Form pursuant to 20VAC5-314-39 made by the IC but not agreed to in writing by the utility and the IC may be deemed by the utility as a withdrawal of the Interconnection Request Form interconnection request and may require submission of a new Interconnection Request Form interconnection request, unless proper notification of each party by the other and a reasonable time to cure the problems created by the changes are undertaken.

C. Site control documentation must be submitted with the Interconnection Request Form. Any information appearing in public records may not be labeled Confidential. (Confidential information is discussed in 20VAC5-314-110.) Site control may be demonstrated through:

1. Ownership of, a leasehold interest in, or a right to develop a site for the purpose of constructing the small generating facility;

2. An option to purchase or acquire a leasehold site for such purpose;

3. An exclusivity or other business relationship between the interconnection customer and the entity having the right to sell, lease, or grant the IC the right to possess or occupy a site for such purpose;

4. An existing permanent service metered account with the utility at the site and in the name of the IC.

D. The utility shall place interconnection requests into a first-come, first-served queue that is based on the interconnection's distribution feeder and distribution substation. The queue position shall be based upon the date- and time-stamp of the completed Interconnection Request Form. The queue position of an interconnection request will be used to determine the cost responsibility for the necessary upgrades.

C. The utility shall prioritize interdependent projects pursuant to 20VAC5-314-38. If applicable, the interconnection request study deposit specified in the Interconnection Request Form will be required pursuant to 20VAC5-314-38. At the utility's option, interconnection requests may be studied serially or in clusters for the purpose of the system impact study.

D. The IC shall immediately notify the utility in writing of any changes in the ownership or control of, operational responsibility for, or contact information for the SGF and pay a $500 processing fee.

E. The utility shall not be required to maintain an interconnection with an SGF if the SGF or associated equipment is found to be out of compliance with the codes, standards, and certification applicable to the SGF.

F. Small Generator Interconnection Agreement.

1. The steps describing the utility's determination of whether an SGF can be safely interconnected to its system and the utility's subsequent issuance of an executable SGIA to the IC are provided in 20VAC5-314-60 and 20VAC5-314-70 for the Level 2 and Level 3 interconnection processes respectively. After receiving the SGIA from the utility, the IC shall have 30 business days to sign and return the SGIA. If the IC does not return the SGIA within the deadline, the interconnection request shall be deemed withdrawn, and the IC shall lose its place in the utility's queue. After the SGIA is signed by the parties, the interconnection of the SGF shall proceed under the provisions of the SGIA.

2. The SGIA shall specify milestones for prepayment of estimated costs for all system upgrades identified by the utility during the study process. The SGIA shall also specify the prepayment or the provision of financial security for system upgrades or attachment facilities if acceptable to the utility prior to the start of the final design and construction of system upgrades and attachment facilities. Payment and financial security must be received by close of business 30 business days after the date the SGIA is delivered to the IC for signature. Failure to comply with the requirements of this section after an opportunity to cure shall result in the interconnection request being deemed withdrawn.Should an IC fail to comply with the provisions of this section following receipt of a written notice specifying how the IC failed to comply and the expiration of an opportunity to cure by the close of business on the 10th business day following the posted date of such notice to cure, the IC will lose its queue number and the interconnection request shall be deemed withdrawn. ]

20VAC5-314-60. Level 2 interconnection process.

A. The Level 2 interconnection process is available to an interconnection customer IC proposing to interconnect a small generating facility certified SGF with the utility system if the SGF is no larger than 2 MW and does not qualify for the Level 1 process, and meets the codes, standards, and certification requirements of Schedules 2 and 3 in of 20VAC5-314-170.

B. Within 15 business days after the utility notifies the IC it has received a complete Interconnection Request Form, the utility shall perform an initial review using the screens set forth below (20VAC5-314-60 in subsection C or 20VAC5-314-60 D of this section, as [ applicable) applicable ] and shall notify the IC of the results, including copies of the analysis and data underlying the utility's determinations under the screens.

C. Screens for interconnections to radial circuits.

1. For interconnection of a small generating facility an SGF to a radial distribution circuit, the aggregated generation, including the proposed small generating facility SGF, on the circuit shall not exceed 15% of the line section's annual peak load as most recently measured at the substation or calculated for the line section. A line section is that portion of a distribution circuit connected to a customer that is bounded by automatic sectionalizing devices or the end of the circuit.

2. The SGF, in aggregation with other generation on the distribution circuit, shall not contribute more than 10% to the circuit's maximum fault current at the point on the distribution feeder's (primary) voltage level that is nearest the point of interconnection.

3. The SGF, in aggregate with other generation on the distribution circuit, shall not cause any distribution protective devices and equipment (including, but not limited to, substation breakers, fused cutouts, and line reclosers), or interconnection customer IC equipment on the system to exceed 87.5% of the short circuit interrupting capability; nor shall the interconnection be permitted on a circuit where 87.5% of the short circuit interrupting capability is already exceeded.

4. For interconnections to the distribution primary voltage, use the table below, in this subdivision to determine the acceptable type of interconnection to a primary distribution circuit. This screen includes a review of the type of electrical service provided to the IC, including line configuration and the transformer connection, to limit the potential for creating over-voltages on the utility's distribution system due to a loss of ground during the operating time of any anti-islanding function.

Primary Distribution Line Type

Type of Interconnection to Primary Distribution Line

Result/Criteria

Three-phase, three wire

Three-phase, orsingle phasesingle-phase, phase-to-phase

Pass screen

Three-phase, four wire

Effectively-groundedthree phasethree-phase, or single-phase, line-to-neutral

Pass screen

5. If the small generating facility SGF is to be interconnected to a single-phase shared secondary, the aggregate generation capacity on the shared secondary, including the proposed SGF, shall not exceed 20 kW.

6. If the SGF is single-phase and is to be interconnected on a center tap neutral of a 240 volt service, its addition shall not create an imbalance between the two sides of the 240 volt service of more than 20% of the nameplate rating of the service transformer.

7. The SGF, in aggregate with generation interconnected to the transmission side of the substation transformer that feeds the distribution circuit where the SGF proposes to interconnect, shall not exceed 10 MW in an area where there are known, or posted, transient stability limitations to generating units located in the general electrical vicinity (e.g., within three or four transmission busses from the point of interconnection).

8. No construction of facilities by the utility on its own system shall be required to accommodate the SGF.

D. Screens for interconnections involving networks.

1. For interconnection of a small generating facility an SGF to the load side of spot network protectors serving more than a single customer, the SGF must utilize an inverter-based equipment package and, together with the aggregated other inverter-based generation, shall not exceed the smaller of 5.0% of a spot network's maximum load or 300 kW. For spot networks serving a single customer, the SGF must use an inverter-based equipment package and either meet the requirements above of this subdivision, or use a protection scheme, or operate the generator so as not to exceed on-site load or otherwise prevent nuisance operation of the spot network protectors.

2. For interconnection of an SGF to the load side of area network protectors, the SGF must utilize an inverter-based equipment package and, together with the aggregated other inverter-based generation, shall not exceed the smaller of 10% of an area network's minimum load, or 500 kW.

3. If the SGF is single-phase, the IC's load, net of generation on each phase, shall not create an imbalance between the phases of a polyphase service, or if applicable, between each leg of single-phase service.

4. For interconnection of an SGF to a distribution circuit in an area where there are known or posted transient stability limitations to generating units located in the general electrical vicinity (e.g., within three or four transmission busses from the point of interconnection), the SGF, in aggregate with generation interconnected to the transmission side of the substation transformer that feeds the distribution circuit, shall not exceed the following limits:

a. For a distribution circuit that supplies only secondary voltage networks, 30% of the distribution circuit's load.

b. For a distribution circuit not exclusively supplying secondary networks, 10 MW.

5. For interconnection of an SGF to the line side of network protectors:

a. For a distribution circuit that supplies only secondary networks, the interconnection fails the screen.

b. For a distribution circuit not exclusively supplying secondary networks, the interconnections shall be evaluated in accordance with 20VAC5-314-60 C.

6. No construction of facilities by the utility on its own system shall be required to accommodate the SGF.

7. To the extent any new IEEE standards conflict with this chapter, in particular IEEE 1547, Standard for Interconnection and Interoperability of Distributed Energy Resources with Associated Electric Power Systems Interfaces, 2018, the new standards shall apply. In addition, utility consent shall not be unreasonably withheld from an SGF interconnecting to a spot or area network provided the SGF utilizes a protection scheme that will prevent any power export from the IC's site, including inadvertent export under fault conditions, and otherwise prevent nuisance operation of the network protectors.

E. If the interconnection passes the screens, the interconnection request shall be approved and the utility will shall provide the interconnection customer IC an executable interconnection agreement SGIA within five 10 business days after the determination.

F. If the interconnection fails any screens, but the utility determines that the small generating facility SGF may nevertheless be interconnected consistent with safety, reliability, and power quality standards, the utility shall provide the IC an executable interconnection agreement SGIA within five 10 business days after the determination.

G. If the interconnection fails any screens, but the utility does not or cannot determine from the initial review that the SGF may nevertheless be interconnected consistent with safety, reliability, and power quality standards, unless the IC is willing to consider minor modifications or further study, the utility shall provide the IC with the opportunity to attend a customer options meeting.

H. G. If the interconnection fails any screen and the utility determines that the interconnection cannot be approved without (i) minor modifications at minimal cost; (ii) a supplemental review or other additional studies or actions; or modifications or installations at (iii) incurring significant cost to address safety, reliability, or power quality problems, the utility shall notify the IC and provide copies of the data and analyses underlying its conclusion within five 10 business days after that determination. Within 10 business days of the determination, the utility shall offer to convene a customer options meeting to review possible IC facility modifications, or the screen analysis and related results, to determine what further steps are needed to permit the SGF to be connected safely and reliably. At the time of notification of the utility's determination, or at the customer options meeting, the utility shall:

1. Offer to perform facility modifications or minor modifications to the utility system (e.g., changing meters, fuses, and relay settings) and provide an estimate of the cost to make such modifications to the utility system. If the IC agrees to pay for the modifications to the utility's electric system, the utility shall provide the IC with an SGIA within 10 business days after the customer options meeting;

2. Offer to perform a supplemental review if the utility concludes that the supplemental review might determine that the SGF could continue to qualify for interconnection pursuant to the Level 2 process, in accordance with subsection H of this section and provide the IC with information on the studies potentially required to be performed under the supplemental review, and an estimate of the costs and time timing of such review; or

3. Offer Obtain the IC's agreement to continue evaluating the interconnection request, but under the Level 3 interconnection process.

I. H. Supplemental review. If a supplemental review is offered to the interconnection customer IC and the IC agrees to the supplemental review, the utility shall, within 10 business days of the request, provide to the IC an appropriate supplemental review agreement. To maintain its position in the utility's interconnection queue, the IC must execute the supplemental review agreement and return it to the utility, along with a deposit for the estimated cost of the supplemental review, within 15 business days after receipt of the agreement. If the IC fails to return the executed supplemental review agreement along with the deposit within 15 business days after receipt, the interconnection request shall be deemed withdrawn, and the IC shall lose its place in the utility's interconnection queue.

The IC shall be responsible for the utility's actual costs of conducting the supplemental review. The IC shall pay any review costs that exceed the deposit within 30 business days of receipt of the invoice or resolution of any dispute. If the deposit exceeds the invoiced costs, the utility will shall return such excess within 30 business days of the invoice without interest.

Within 10 30 business days following receipt of the supplemental review agreement and deposit, the utility will determine if the SGF can be interconnected safely and reliably.

1. If so, and if the supplemental review reveals that no modifications are required to the IC's interconnection facilities, or to the system, or to an affected system, the utility shall forward an executable SGIA to the interconnection customer IC within five 10 business days after the determination.

2. If so, and modifications are required to the IC's interconnection facilities that to allow the SGF to be interconnected consistent with safety, reliability, and power quality standards under these procedures in this chapter, the utility shall forward an executable SGIA to the IC within five 10 business days after confirmation that the IC has agreed to make the necessary changes at the IC's cost.

3. If so, and minor modifications to the utility system are required to allow the SGF to be interconnected consistent with safety, reliability, and power quality standards under these procedures in this chapter, the utility shall, within 10 business days after the determination, forward an executable SGIA to the IC that requires the IC to pay the costs of such system modifications prior to interconnection.

4. If not, the interconnection request will be elevated to the Level 3 interconnection process.

Interconnection may occur when, as may be required under the applicable subdivisions subdivision 1, 2, or 3 of this subsection, the SGIA is fully executed and returned to the utility, the IC has made required payments to the utility, and required modifications are complete. If subdivision I 4 of this section subsection is applicable, interconnection shall occur in accordance with the Level 3 interconnection process.

J. I. Small generating facilities of 500 kW or less. For an SGF of 500 kW or less, the requirements in this section shall be deemed satisfied when: (i) an Interconnection Request Form as required under 20VAC5-314-40 B is properly completed and all of the certifications and acknowledgements acknowledgments required in Sections 5, 6, and 7 of the Interconnection Request Form are affixed, and (ii) the IC and the utility have exchanged appropriate written commitments to effect the necessary installations and modifications to the SGF and the utility system. The timing of such Such commitments shall follow the timing prescribed in this section.

20VAC5-314-70. Level 3 interconnection process.

A. The Level 3 interconnection process shall be used by an interconnection customer IC proposing to interconnect a small generating facility an SGF with the utility system if the SGF is no larger than 20 MW and does not pass or qualify for the Level 1 or Level 2 interconnection processes. As needed, a scoping meeting, feasibility study, system impact study, and facilities study shall precede the preparation of a Small Generator Interconnection Agreement an SGIA (Schedule 6 10 of 20VAC5-314-170). Any of the studies may be combined by mutual, written agreement of the parties along with payment of applicable interconnection study deposit, set forth in Schedule 6 of 20VAC5-314-170. Such agreement for a combined study shall, at a minimum, include milestones for completion. The combined study timeframes and fees shall not exceed the aggregate timeframes and fees of the individual studies as specified in this section.To maintain its position in the utility's interconnection queue, the IC must execute the agreement for combined study, return it to the utility, and pay the interconnection request study deposit set forth in Schedule 6 of 20VAC5-314-170 within 15 business days after receipt of the agreement. If the IC fails to return the executed agreement for combined study or make the full payment of the interconnection request study deposit within 15 business days after receipt of the agreement, the interconnection request shall be deemed withdrawn, and the interconnection request shall lose its place in the utility's interconnection queue. ]

B. Scoping meeting.

1. The purpose of the scoping meeting is to discuss the interconnection request and the utility's preliminary interdependency determination. The parties shall discuss the studies potentially required to safely and reliably interconnect the IC to the utility's system, including the cost responsibilities for the studies.

1. 2. A scoping meeting will shall be held within no later than 10 business days after the Interconnection Request Form is deemed complete, or as otherwise mutually agreed to in writing by the parties. The utility and the IC shall bring to the meeting personnel, including system engineers and other all resources as may be reasonably required to accomplish the purpose of the meeting, such as system engineers and other personnel.

2. The purpose of the scoping meeting is to discuss the interconnection request. The parties shall discuss the studies and the cost responsibilities for the studies.

3. The scoping meeting may be omitted by mutual, written agreement of the parties.

C. Feasibility study.

1. If the parties agree that a feasibility study should be performed, the utility shall provide the IC with a feasibility study agreement Feasibility Study Agreement (Schedule 7 of 20VAC5-314-170), including an outline of the scope of the feasibility study and an estimate of the cost to perform the study, no later than five 10 business days after the scoping meeting or five 10 business days after the decision is made to not have a scoping meeting and otherwise pursuant to subsection D of this section.

If the parties agree to not perform a feasibility study, the utility shall provide the IC a system impact study agreement System Impact Study Agreement (Schedule 8 of 20VAC5-314-170) including an outline of the scope of the study and an estimate of the cost to perform the study no later than five 10 business days after the scoping meeting, or five business days after the decision is made to not have a scoping meeting.

2. To maintain its position in the utility's interconnection queue, the IC must execute the feasibility study agreement and Feasibility Study Agreement, return it to the utility along with the deposit for the feasibility study, and pay the interconnection request study deposit set forth in Schedule 6 of 20VAC5-314-170 within 15 business days after receipt of the agreement. If the IC fails to return the executed feasibility study agreement along with the Feasibility Study Agreement or make the full payment of the interconnection request study deposit within 15 business days after receipt of the agreement, the interconnection request shall be deemed withdrawn and the interconnection request shall lose its place in the utility's interconnection queue.

3. A feasibility study shall identify any potential adverse system impacts that would result from the interconnection of the SGF.

4. A deposit of no more than 50% of the estimated feasibility study costs or earnest money of $1,000 may be required from the interconnection customer. a. Study costs shall be the utility's actual incremental costs and will be invoiced to the IC after the study is completed and delivered and will include a summary of professional time. b. The IC shall pay any study costs that exceed the deposit without interest within 30 calendar days on receipt of the invoice or resolution of any dispute. If the deposit exceeds the invoiced fees, the utility shall refund such excess within 30 calendar days of the invoice without interest 4. Feasibility study costs will be deducted from the interconnection request study deposit pursuant to Schedule 7 of 20VAC5-314-170.

5. The feasibility study shall be based on the technical information provided by the IC in the Interconnection Request Form, as may be modified as the result of the scoping meeting. The utility reserves the right to request additional technical information from the IC as may reasonably become necessary consistent with Good Utility Practice during the course of the feasibility study and as designated in accordance with the standard small generator interconnection procedures. All modification modifications made to the interconnection request shall be made in writing to the utility. If the interconnection customer modifies IC submits a modification to its interconnection request in writing and the utility determines the modification is not a material modification, the time to complete the feasibility study may be extended by mutual, written agreement of the parties.

6. In performing the feasibility study, the utility shall rely, to the extent reasonably practicable, on recent studies. The IC shall not be charged for such existing studies; however, the IC shall be responsible for charges associated with any new study or modifications to existing studies that are reasonably necessary to perform the feasibility study.

7. The feasibility study report shall provide the following analyses for the purpose of identifying any potential adverse system impacts that would result from the interconnection of the SGF:

a. Initial identification of any circuit breaker short circuit capability limits exceeded;

b. Initial identification of any thermal overload or voltage limit violations;

c. Initial review of grounding requirements and electric system protection; and

d. Description and estimated cost of facilities and estimated construction time required to interconnect the SGF and to address the identified short circuit and power flow issues.

8. The feasibility study shall model the impact of the SGF for all purposes identified in the Interconnection Request Form in order to avoid the further expense and interruption of operation for reexamination of feasibility and impacts if the IC later changes the purpose for which the SGF is being installed.

9. The feasibility study shall include a determination of the feasibility of all potential points of interconnection, for an SGF at the specified site as requested by the IC and shall be at the IC's cost.

10. A feasibility study report shall be prepared and transmitted to the IC within 30 business days of the utility's receipt of the complete executed feasibility study agreement Feasibility Study Agreement and required deposit.

11. If the feasibility study shows no potential for adverse system impacts, then within five 10 business days of the completion of the study, the utility shall send the IC either an executable Small Generator Interconnection Agreement SGIA (Schedule 5, 10 of 20VAC5-314-170) or a facilities study agreement Facilities Study Agreement (Schedule 9 of 20VAC5-314-170), including an outline of the scope of the facilities study and an estimate of the cost to perform the study.

12. If the feasibility study shows potential for adverse system impacts, the review process shall proceed to the system impact study.

D. System impact study.

1. No later than five 10 business days after the parties agree that a system impact study should be performed, the utility shall provide the IC a system impact study agreement System Impact Study Agreement (Schedule 8 of 20VAC5-314-170), including an outline of the scope of the system impact study and an estimate of the cost to perform the study.

2. To maintain its position in the utility's interconnection queue, the IC must execute the system impact study agreement and System Impact Study Agreement, return it to the utility along with the, and if applicable, pay the interconnection request study deposit for the system impact study set forth in Schedule 6 of 20VAC5-314-170 within 15 business days after receipt of the agreement. If the IC fails to return the executed system impact study agreement along with the System Impact Study Agreement or make the full payment of the applicable interconnection request study deposit within 15 business days after receipt of the agreement, the interconnection request shall be deemed withdrawn, and the interconnection request shall lose its place in the utility's interconnection queue.

3. A deposit equal to the estimated cost of a system impact study may be required from the IC.

a. Study cost shall be the utility's actual incremental costs and will be invoiced to the IC after the study is completed and delivered and will include a summary of professional time.

b. The IC shall pay any study costs that exceed the deposit within 30 calendar days on receipt of the invoice or resolution of any dispute. If the deposit exceeds the invoiced fees, the utility shall refund the excess within 30 calendar days of the invoice without interest

3. System impact study costs will be deducted from the interconnection request study deposit pursuant to Schedule 8 of 20VAC5-314-170.

4. A system impact study shall identify and detail the electric system impacts that would result if the SGF were interconnected without project modifications or electric system modifications, focusing on the including addressing any adverse electric system impacts identified in the feasibility study, or in the scoping meeting. A system impact study shall evaluate the impact of the proposed interconnection on the reliability of the electric system.

5. A system impact study will be based upon the results of the feasibility study, if applicable, and the technical information provided by the interconnection customer IC in the interconnection request. The utility reserves the right to request additional technical information from the IC as may reasonably become necessary consistent with Good Utility Practice during the course of the system impact study. If the IC modifies its designated point of interconnection, or interconnection request, or the technical information provided therein in the connection request, the time to complete the system impact study may be extended by written, mutual agreement.

6. A system impact study shall consist of a study of the potentially impacted transmission and distribution systems, a short circuit analysis, a stability analysis, a power flow analysis, voltage drop and flicker studies, grounding reviews, distribution load flow study, analysis of equipment interrupting ratings, protection coordination study, communications study, and impacts on electric system operation, as necessary. A system impact study shall state the assumptions upon which it is based, state the results of the analyses, and provide the requirement or potential impediments to providing the requested interconnection service, including a preliminary indication of the cost and length of time that would be necessary to correct any problems identified in those analyses and implement the interconnection. A system impact study shall provide a list of facilities and modifications that would be required as a result of the interconnection along with estimates of cost responsibility and time to construct. If arranged with the utility prior to the utility preparing the system impact study agreement System Impact Study Agreement, the system impact study may, at the IC's cost, include one or more alternatives to the point of interconnection; however, such alternative points must be on the same distribution circuit as the point of interconnection the IC specified as the proposed point of interconnection and the SGF must be at the same site.

7. Affected systems may participate in the preparation of a system impact study, with a division of costs among such entities as they may agree. All affected systems shall be afforded an opportunity to review and comment upon a system impact study that covers potential adverse system impacts on their electric systems, and the utility has 20 additional business days to complete a system impact study requiring review by affected systems.

8. If the utility uses a queuing procedure for sorting or prioritizing projects and their associated cost responsibilities for any required network upgrades, the system impact study shall consider all generating facilities (and, and with respect to clause iii below of this subdivision, any identified upgrades associated with such higher queued interconnection) interconnection) that, on the date the system impact study is commenced are: (i) directly interconnected with the utility system; or (ii) interconnected with affected systems and may have an impact on the proposed interconnection; and (iii) have a pending higher queued interconnection request to interconnect with the utility system.

9. A system impact study, if required, shall be completed and the results transmitted to the IC within 45 business days after an agreement the System Impact Study Agreement is signed by the parties, or in accordance with the utility's queuing procedures.

10. If the system impact study shows that facility modifications are needed to accommodate the SGF, then within five 10 business days following transmittal of the system impact study report, the utility shall send the IC a facilities study agreement Facilities Study Agreement (Schedule 9 of 20VAC5-314-170), including an outline of the scope of the study and an estimate of the cost to perform the study.

E. Facilities study.

1. The facilities study shall specify and estimate the cost of the equipment, engineering, procurement, and construction work needed to implement the conclusion of the feasibility and/or impact study or system impact study and to allow the SGF to be interconnected and operate safely and reliably.

2. To maintain its position in the utility's interconnection queue, the IC must execute the facilities study agreement Facilities Study Agreement and return it to the utility along with a completed Facilities Study Information Form (Schedule 5, 20VAC5-314-170) and deposit for the facilities studyand, if applicable, pay the interconnection request study deposit set forth in Schedule 6 of 20VAC5-314-170 ] within 30 business days after receipt of the agreement, unless an extension has been agreed to in writing with the utility. Otherwise, the interconnection request shall be deemed withdrawn, and the interconnection request shall lose its place in the utility's interconnection queue.

3. A deposit equal to the estimated cost of a facilities study may be required from the IC.

a. Study cost shall be the utility's actual incremental costs and will be invoiced to the IC after the study is completed and delivered and will include a summary of professional time.

b. The IC shall pay any study costs that exceed the deposit within 30 calendar days after receipt of the invoice or resolution of any dispute. If the deposit exceeds the invoiced fees, the utility shall refund the excess within 30 calendar days of the invoice without interest

3. Facilities study costs will be deducted from the interconnection request deposit pursuant to Schedule 9 of 20VAC5-314-170.

4. Design for any required customer's interconnection facilities, attachment facilities, and/or or upgrades shall be performed under the facilities study. The utility may contract with consultants to perform activities required under the facilities study. The IC and the utility may agree in writing to allow the IC to separately arrange for the design of some of the customer's interconnection facilities. In such cases, facilities design will be reviewed and/or or modified prior to acceptance by the utility, under the provisions of the facilities study. If the parties agree to separately arrange for design and construction, and provided security and confidentiality requirements can be met, the utility shall make sufficient information available to the IC in accordance with confidentiality and critical infrastructure requirements, to permit the IC to obtain an independent design and cost estimate for any necessary facilities.

5. The facilities study shall identify (i) the electrical switching configuration of the equipment, including, without limitation, transformer, switchgear, meters, and other station equipment,; (ii) the nature and estimated cost of the attachment facilities and distribution upgrades necessary to accomplish the interconnection,; and (iii) an estimate of the time required to complete the construction and installation of such facilities.

6. The utility may propose to group facilities required for more than one IC in order to minimize facilities costs through economies of scale, but any IC may require direct the installation of utility to install those facilities required for its only the IC's own small generating facility SGF if it pays the costs of those facilities.

7. In cases where system upgrades are required, the utility shall transmit the facilities study report within 45 business days after receipt of the complete facilities study agreement, Facilities Study Information Form, and the deposit completed Facilities Study Agreement. In cases where no system upgrades are necessary, and the required facilities are limited to customer's the IC's interconnection facilities and attachment facilities only, the utility shall transmit the facilities study report within 30 business days after receipt of the complete facilities study agreement, Facilities Study Information Form and the deposit completed Facilities Study Agreement.

F. Construction planning meeting.

1. Within 15 business days of receipt of the report for the final study (i.e., the facilities study or, if applicable, a combined study that satisfies all study requirements), the IC shall request a construction planning meeting where failure to comply shall result in the interconnection request being deemed withdrawn. The construction planning meeting request shall be in writing and shall include the IC's reasonably requested date for completion of the construction of the customer's interconnection facilities and upgrades.

2. The construction planning meeting shall be scheduled within 15 business days of the request from the IC as stated in subdivision F 1 of this section, or as otherwise mutually agreed to in writing by the parties.

3. The purpose of the construction planning meeting is to identify the tasks for each party and discuss and determine the milestones for the construction of the system upgrades and attachment facilities. Agreed upon milestones shall be specific as to scope of action, responsible party, and dates of deliverables and shall be recorded in the SGIA (see Schedule 10 of 20VAC5-314-170) to be provided to the IC.

F. G. Small Generator Interconnection Agreement. 1. Within five No later than 10 business days after transmittal of the final study (i.e. the facilities study, or if applicable, a combined study that satisfies all study requirements) the construction planning meeting, the utility shall provide the interconnection customer IC an executable SGIA as set forth in 20VAC5-314-50D F ] (Schedule 6, 10 of 20VAC5-314-170).

2. After receiving the SGIA from the utility, the IC shall have 30 business days or another mutually agreeable deadline, to sign and return the SGIA. If the IC does not return the SGIA within the deadline, the interconnection request shall be deemed withdrawn and the IC shall lose its place in the utility's queue. After the SGIA is signed by the parties, the interconnection of the SGF shall proceed under the provisions of the SGIA.

20VAC5-314-80. Interconnection metering.

Any metering, including telemetering, necessitated by the use of the small generating facility SGF and any additional utility metering requested by the interconnection customer IC and agreed to in writing by the utility shall be provided by the utility at the IC's expense in accordance with commission requirements or the utility's specifications. The IC shall be responsible for the utility's reasonable and necessary cost for the purchase, installation, operation, maintenance, testing, repair, and replacement of metering and telemetering equipment.

20VAC5-314-90. Commissioning tests.

Commissioning tests of the interconnection customer's IC's installed equipment shall be performed pursuant to applicable codes and standards, including IEEE 1547.1 2005 "IEEE, Standard Conformance Test Procedures for Equipment Interconnecting Distributed Resources with Electric Power Systems, 2005." The utility shall be given at least five business days written notice, or notice as otherwise mutually agreed to in writing by the parties, of the tests to be performed, and the utility shall be allowed to be present to witness the commissioning tests. The utility shall not be compensated by the IC for witnessing commissioning tests.

20VAC5-314-100. Disputes.

A. The parties agree to attempt to resolve all disputes arising out of the interconnection process according to the provisions of this section.

B. In the event of a dispute, either party shall provide the other party with a written notice of dispute. The notice shall describe in detail the nature of the dispute. The parties shall make a good faith effort to resolve the dispute informally within 10 business days.

C. If the dispute has not been resolved within 10 business days after receipt of the notice, either party may seek resolution assistance from the commission's Division of Energy Public Utility Regulation where the matter will be handled as an informal complaint.

Alternatively, the parties may, upon mutual agreement, seek resolution through the assistance of a dispute resolution service. The dispute resolution service will assist the parties in either resolving the dispute or in selecting an appropriate dispute resolution venue (e.g., mediation, settlement judge, early neutral evaluation, or technical expert) to assist the parties in resolving their dispute. Each party shall conduct all negotiations in good faith and shall be responsible for one-half of any costs paid to neutral third parties.

D. If the dispute remains unresolved, either party may petition the commission to handle the dispute as a formal complaint or may exercise whatever rights and remedies it may have in equity or law.

20VAC5-314-110. Confidential information.

A. Confidential information shall mean any confidential and/or or proprietary information provided by one party to the other party that is clearly marked or otherwise designated "Confidential." All design, operating specifications, and metering data provided by the IC shall be deemed confidential information regardless of whether it is clearly marked or otherwise designated as such.

B. Confidential information does not include information previously in the public domain, required to be publicly submitted or divulged by governmental authorities (after notice to the other party and after exhausting any opportunity to oppose such publication or release), or necessary to be divulged in an action to enforce an agreement between the parties. Each party receiving confidential information shall hold such information in confidence and shall not disclose it to any third party nor to the public without the prior written authorization from the party providing that information, except to fulfill obligations under agreements between the parties, or to fulfill legal or regulatory requirements.

1. Each party shall employ at least the same standard of care to protect confidential information obtained from the other party as it employs to protect its own confidential information.

2. Each party is entitled to equitable relief, by injunction or otherwise, to enforce its rights under this section to prevent the release of confidential information without bond or proof of damages, and may seek other remedies available at law or in equity for breach of this provision.

C. Notwithstanding anything in this chapter to the contrary, if the commission, during the course of an investigation or otherwise, requests information from one of the parties that is otherwise required to be maintained in confidence, the party shall provide the requested information to the commission, within the time provided for in the request for information. In providing the information to the commission, the party may request that the information be treated as confidential and nonpublic by the commission and that the information be withheld from public disclosure. Parties are prohibited from notifying the other party prior to the release of the confidential information to the commission. A party shall notify the other party when it is notified by the commission that a request to release confidential information has been received by the commission, at which time either party may respond to the commission before such information would be made public.

D. Once a project has been assigned a queue number in accordance with 20VAC5-314-38, the following information regarding the project shall not be deemed confidential:

1. Project IC company name;

2. Queue number;

3. Maximum generating capacity;

4. Location of the SGF; and

5. Date of the submission of the completed Interconnection Request Form.

20VAC5-314-120. Equal treatment.

The utility shall receive, process, and analyze all interconnection requests in a timely manner as set forth in this chapter. The utility shall use the same reasonable efforts in processing and analyzing interconnection requests from all Interconnection customers ICs, whether the SGF is owned or operated by the utility, its subsidiaries or affiliates, or others.

20VAC5-314-130. Record retention and reporting requirements.

A. The utility shall maintain, subject to audit, records for three years of (i) all interconnection requests received pursuant to this chapter, (ii) the times required to complete interconnection request approvals and disapprovals, and (iii) justification for the actions taken on the interconnection requests.

B. Each utility shall annually, on or before January 31,file submit ] a written reportwith to ] the commission staff that includes the utility's small generating facilities queue and a listing of those facilities interconnected during the preceding calendar year. This report shall include the following data for each SGF:

1. Queue number.

2. The physical address or geographic coordinates (latitude and longitude) of the SGF.

3. Fuel type.

4. The capacity of the SGF, in terms of megawatts.

5. The substation and transformer to which the project will be interconnected.

6. The feeder or circuit to which the project will be interconnected.

7. The date of submission of final completed Interconnection Request Form.

8. Interdependency status (e.g., Project A or Project B).

9. Status of the request in the interconnection process (e.g., SGIA executed, connected, canceled).

10. The date of final completed signed SGIA.

20VAC5-314-140. Coordination with affected systems.

The utility shall coordinate the conduct of any studies required to determine the impact of the small generating facility SGF on affected systems with affected system operators and, if possible, include those results (if available) in its applicable interconnection studies within the time frame timeframe specified in this chapter. The utility will include such affected system operators in all meetings held with the IC as required by this chapter. The IC shall cooperate with the utility in all matters related to the conduct of studies and the determination of modifications to affected systems. A utility that may be an affected system shall cooperate with the utility with which interconnection has been requested in all matters related to the conduct of studies and the determination of modifications to affected systems. The utility owning or operating the system to which the IC desires to interconnect shall not be held responsible or liable for any delays in the interconnection process attributable to the lack of information or cooperation from the owners or operators of affected systems.

20VAC5-314-150. Capacity of the small generating facility.

A. If the interconnection request is for an increase in capacity for an existing small generating facility SGF, the interconnection request shall be evaluated on the basis of the new total capacity of the SGF.

B. If the interconnection request is for aan SGF a facility ] that includes multiple energy production or storage devices at a site for which the interconnection customer IC seeks a single point of interconnection, the interconnection request shall be evaluated on the basis of the aggregate capacity of the multiple devices maximum generating capacity of theSGF facility ].

C. The interconnection request shall be evaluated using the maximum rated capacity of that the SGF is capable of injecting into the utility's electric system. However, if the maximum generating capacity that the SGF is capable of injecting into the utility's electric system is limited (e.g., through use of a control system, power relays, or other similar device settings or adjustments), then the IC must obtain the utility's agreement, with such agreement not to be unreasonably withheld, that the manner in which the IC proposes to implement such a limit will not adversely affect the safety and reliability of the utility's system. If the utility does not so agree, then the interconnection request must be withdrawn or revised to specify the maximum capacity that the SGF is capable of injecting into the utility's electric system without such limitations. Nothing in this section shall prevent a utility from considering an output higher than the limited output, if appropriate, when evaluating system protection impacts.

20VAC5-314-160. Insurance, liability, and indemnification.

A. For a small generating facility an SGF with a rated capacity not exceeding 10 kW, the IC, at its own expense, shall secure and maintain in effect during the term of the agreement, liability insurance with a combined single limit for bodily injury and property damage of not less than $100,000 for each occurrence.

For an SGF with a rated capacity exceeding 10 kW but not exceeding 500 kW, the IC, at its own expense, shall secure and maintain in effect during the term of the agreement, liability insurance with a combined single limit for bodily injury and property damage of not less than $300,000 for each occurrence.

For an SGF with a rated capacity exceeding 500 kW but not exceeding 2 MW, the IC, at its own expense, shall secure and maintain in effect during the term of the agreement, liability insurance with a combined single limit for bodily injury and property damage of not less than $2 million for each occurrence. Insurance coverage for an SGF with a rated capacity exceeding 2 MW shall be determined on a case-by-case basis and shall reflect the size of the installation and the potential for system damage.

An IC of sufficient creditworthiness, as determined by the utility, may propose to provide this insurance via a self-insurance program if it has a self-insurance program established in accordance with commercially acceptable risk management practices, and such a proposal shall not be reasonably rejected.

B. Certificates of insurance evidencing the requisite coverage and provision shall be furnished to the utility prior to the date of interconnection of the SGF, as required by the utility. The utility shall be permitted to periodically obtain proof of current insurance coverage from the IC in order to verify continuing proper liability insurance coverage. The IC will not be allowed utility reserves the right to refuse to commence or continue interconnected operations unless evidence is provided that required insurance coverage is in effect at all times.

C. Utility and IC liability to the other party for any loss, cost, claim, injury, liability, or expense, including reasonable attorney fees, relating to or arising from any act or omission pursuant to this chapter shall be limited to the amount of direct damage actually incurred. In no event shall either party be liable to the other party for any indirect, special, incidental, consequential, or punitive damages of any kind.

D. The utility and the IC shall at all times indemnify, defend, and save the other party harmless from any damages; losses; claims, including claims and actions relating to injury or death of any person or damage to property; demand; suits; recoveries; costs and expenses; court costs; attorney fees; and all other obligations by or to third parties arising out of or resulting from the other party's action or inaction of its obligations pursuant to this chapter on behalf of the indemnifying party, except in cases of gross negligence or intentional wrongdoing by the indemnified party.

20VAC5-314-165. Assignment; sale of an existing or proposed SGF.

A. At any time after an interconnection request has been submitted by the IC, the IC shall notify the utility of the pending sale of an existing or proposed SGF in writing. The IC shall provide the utility with information regarding whether the sale is a change of ownership of the SGF to a new legal entity or a change of control of the existing legal entity.

B. The IC shall promptly notify the utility of the final date of sale and transfer date of ownership in writing. The purchaser of the SGF shall confirm to the utility the final date of sale and transfer date of ownership in writing.

C. The interconnection agreement shall not survive the transfer of ownership of the SGF to a new legal entity owner. The new owner shall submit a new interconnection request along with a processing fee of $500 to the utility within 20 business days of the transfer of ownership. Where the IC has not executed an interconnection agreement, the utility may continue to study the IC under a pre-existing study agreement or may require the new owner to execute a new study agreement, though under either scenario the new owner would retain the existing queue position. Where an interconnection agreement has been executed and the SGF has been constructed, the utility shall not study or inspect the SGF unless the new owner's interconnection request indicates that a material modification has occurred or is proposed.

D. The interconnection agreement shall survive a change of control of the SGF's legal entity owner, where only the contact information in a study agreement or in the interconnection agreement must be modified. The new owner shall submit a new interconnection request along with a processing fee of $500 to the utility within 20 business days of the change of control and provide the new contact information. Where the IC has not executed an interconnection agreement, the utility may continue to study the IC under a pre-existing study agreement or may require the new owner to execute a new study agreement, though under either scenario the new owner would retain the existing queue position. Where an interconnection agreement has been executed and the SGF has been constructed, the utility shall not study or inspect the SGF unless the new owner's interconnection request indicates that a material modification has occurred or is proposed.

E. The IC shall have the right to assign the interconnection agreement, without the consent of the utility, for collateral security purposes to aid in providing financing for the SGF, provided that the IC will promptly notify the utility of any such assignment. Assignment shall not relieve a party of its obligations, nor shall a party's obligations be enlarged, in whole or in part, by reason thereof.

F. Any attempted assignment that violates this section is void and ineffective. ]

20VAC5-314-170. Schedules for Chapter 314.

The following schedules shall be used in the administration of this chapter.

Schedule 1

LEVEL 1 INTERCONNECTION REQUEST FORM FOR SMALL GENERATING FACILITY NOT EXCEEDING 500 kW

PURSUANT TO 20VAC5-314-40 OF THE COMMISSION'S REGULATIONS GOVERNING INTERCONNECTION OF SMALL ELECTRICAL GENERATORS, APPLICANT HEREBY GIVES NOTICE OF INTENT TO OPERATE A GENERATING FACILITY.

Section 1. Interconnection Customer Information

Name:____________________________________________________________

Mailing Address:____________________________________________________

City, State, Zip:_____________________________________________________

Street Address:_____________________________________________________

City, State, Zip:_____________________________________________________

Phone Number(s):___________________________________________________

Fax Number:______________________ Email:____________________________

 

Utility:_____________________________________________________________

Utility Account Number:______________________________

Competitive Service Provider:__________________________________________

CSP Account Number:______________________________

Proposed Interconnection Date:_______________________

Section 2. Processing Fee

The nonrefundable processing fee payable to the utility is $100.

Section 3. Small Generating Facility Information

SGF owner:_______________________________________________________

SGF operator:_____________________________________________________

Business relationship to applicant:______________________________________

Mailing address:___________________________________________________

City, State, Zip:____________________________________________________

SGF Address:_____________________________________________________

City, State, Zip:____________________________________________________

Phone Number(s):__________________________________________________

Fax Number:______________________ Email:__________________________

Fuel Type:_______________________________________________________

Generator Manufacturer and Model:____________________________________

Rated Capacity in kilowatts: AC:_________________________ DC:__________

Inverter Manufacturer and Model:______________________________________

Battery Backup: Yes_____ No_____

Facility schematic and equipment layout must be attached to this form.

Section 4. Information for Generators with an AC capacity in excess of 25 kW

Is the proposed generator inverter based? Yes_____ No_____

Generator Type: Inverter

Induction

Synchronous

Frequency:_____________ Hz; Number of phases: One___

Three___

Rated Capacity: DC _______ kW; AC apparent _________ kVA; AC real _______ kW;

Power factor ____________%; AC voltage _________; AC amperage___________

Facility schematic and equipment layout must be attached to this form.

Section 5. Vendor Certification

The SGF equipment is listed by Underwriters Laboratories to be in compliance with UL1741.

Signed (Vendor):_____________________________________ Date:____________

Name (printed):_______________________________________________________

Company:___________________________________________________________

Phone Number:_______________________________________________________

Mailing Address:______________________________________________________

City, State, Zip:_______________________________________________________

Section 6. Electrician Certification

The generator equipment has been installed in accordance with the manufacturer's specifications as well as all applicable provisions of the National Electrical Code.

Signed (Licensed Electrician):__________________________ Date:__________

Name (printed):____________________________________________________

License Number:_______________________ Phone Number:_______________

Mailing Address:___________________________________________________

City, State, Zip:____________________________________________________

Section 7. Applicant Signature

I hereby certify that, to the best of my knowledge, all of the information provided in this Request Form is true and correct.

Signature of Applicant:_____________________________________________

Date:________________________

Section 8. Utility Acknowledgement of Receipt

Signed:_______________________________________________________

Title:_________________________________________________________

Utility:________________________________________________________

Date:_________________________

Utility signature signifies only receipt of this form, in compliance with 20VAC5-314-40, the State Corporation Commission's Regulations Governing Interconnection of Small Electrical Generators.

Glossary of Terms

The following terms shall have the following meanings and apply to Schedules 2 through 9 of 20VAC5-314-170:

"Affected system" means an electric utility system other than that of the utility that may be affected by the proposed interconnection.

"Applicable laws and regulations" means all duly promulgated applicable federal, state, and local laws, regulations, rules, ordinances, codes, decrees, judgments, directives, or judicial or administrative orders; permits; and other duly authorized actions of any governmental authority.

"Attachment facilities" means the facilities and equipment owned, operated, and maintained by the utility that are built new in order to physically connect the customer's interconnection facilities to the utility system. Attachment facilities shall not include distribution upgrades or previously existing distribution and transmission facilities.

"Business day" means Monday through Friday, excluding state holidays.

"Calendar day" means Sunday through Saturday, including all holidays.

"Commission" means the Virginia State Corporation Commission.

"Customer's interconnection facilities" means all of the facilities and equipment owned, operated, and maintained by the interconnection customer, between the small generating facility and the point of interconnection necessary to physically and electrically interconnect the small generating facility to the utility system.

"Distribution system" means the utility's facilities and equipment generally delivering electricity to ultimate customers from substations supplied by higher voltages (usually at transmission level). For purposes of Schedules 2 through 9 of 20VAC5-314-170, all portions of the utility's transmission system regulated by the commission for which interconnections are not within Federal Energy Regulatory Commission jurisdiction are considered also to be subject to the Regulations Governing Interconnection of Small Electrical Generators (20VAC5-314).

"Distribution upgrades" means the additions, modifications, and enhancements made to the utility's distribution system on the utility's side of the point of interconnection necessary to ensure continued system reliability and power quality on the utility's distribution system caused by the interconnection of the small generating facility. Distribution upgrades do not include the network upgrades or the customer's interconnection facilities or the utility's attachment facilities.

"Facilities study" has the meaning ascribed to it in 20VAC5-314-70 E.

"Feasibility study" has the meaning ascribed to it in 20VAC5-314-70 C.

"Good Utility Practice" means any of the practices, methods, and acts engaged in or approved by a significant portion of the electric industry during the relevant time period, or any of the practices, methods, and acts that, in the exercise of reasonable judgment in light of the facts known at the time the decision was made, could have been expected to accomplish the desired result at a reasonable cost, consistent with good business practices, reliability, safety, and expedition. Good Utility Practice is not intended to be limited to the optimum practice, method, or act to the exclusion of all others, but rather to include practices, methods, or acts generally accepted in the region.

"Governmental authority" means any federal, state, local, or other governmental regulatory or administrative agency, court, commission, department, board, or other governmental subdivision or legislature, rulemaking board, tribunal, or other governmental authority having jurisdiction over the parties, their respective facilities, or the respective services they provide and exercising or entitled to exercise any administrative, executive, police, or taxing authority or power; "governmental authority" does not include the interconnection customer, the utility, or any affiliate thereof.

"Interconnection customer" or "IC" means any entity proposing to interconnect a new small generating facility with the utility system.

"Interconnection request" means the interconnection customer's request, in accordance with the Regulations Governing Interconnection of Small Electric Generators (20VAC5-314), to interconnect a new small generating facility or to increase the capacity of or make a material modification to the operating characteristics of an existing small generating facility that is interconnected with the utility system.

"Interdependent customer" or "interdependent project" means an interconnection customer or interconnection project whose upgrades to the utility system or attachment facilities are impacted by another earlier-queued generating facility as determined by the utility.

"Material modification" has the meaning ascribed to it in 20VAC5-314-39.

"Maximum generating capacity" means the maximum continuous electrical output of the small generating facility at any time as measured at the point of interconnection or the maximum kilowatts delivered to the utility during any metering period, whichever is greater. Requested maximum generating capacity will be specified by the IC in the interconnection request, and an approved maximum generating capacity will subsequently be included as a limitation in the interconnection agreement.

"Network upgrades" means additions, modifications, and upgrades to the utility's transmission system required to accommodate the interconnection with the small generating facility to the utility's system. Network upgrades do not include distribution upgrades.

"Party" means the utility or the interconnection customer.

"Point of interconnection" means the point where the customer's interconnection facilities connect physically and electrically with the utility's system.

[ "Processing fee" means a nonrefundable cost to administer or file an application. ]

"Queue number" refers to the number assigned by the utility that establishes a customer's interconnection request position in the study queue relative to all other valid interconnection requests. A lower queue number will be studied prior to a higher queue number, except in the case of interdependent projects. The queue number of each interconnection request shall be used to determine the cost responsibility for the upgrades necessary to accommodate the proposed interconnection.

"Small generating facility" or "SGF" means the interconnection customer's equipment used for the productionor storage for later injection ]of electricity, as identified in the interconnection request.

"System" or "utility system" means the distribution and transmission facilities owned, controlled, or operated by the utility that are used to deliver electricity.

"System impact study" has the meaning ascribed to it in 20VAC5-314-70 D.

"Transmission system" means the utility's facilities and equipment delivering electric energy to the distribution system, such facilities being operated at voltage levels above the utility's typical distribution system voltage levels.

"Utility" means the public utility company subject to regulation by the commission pursuant to Chapter 10 (§ 56-232 et seq.) of Title 56 of the Code of Virginia with regard to rates or service quality, to whose system the interconnection customer proposes to interconnect a small generating facility.

Schedule 2

Certification of Small Generator Equipment Packages

Small generating facility equipment proposed for use separately or packaged with other equipment in an interconnection system shall be considered certified for interconnected operation if (i) it has been tested in accordance with industry standards for continuous utility interactive operation in compliance with the appropriate codes and standards referenced below in this Schedule 2 by any Nationally Recognized Testing Laboratory (NRTL) recognized by the United States Occupational Safety and Health Administration to test and certify interconnection equipment pursuant to the relevant codes and standards listed in SGIP Schedule 3, of 20VAC5-314-170; (ii) it has been labeled and is publicly listed by such NRTL at the time of the interconnection application,; and (iii) such NRTL makes readily available for verification all test standards and procedures it utilized in performing such equipment certification, and, with consumer approval, the test data itself. The NRTL may make such information available on its website and by encouraging such information to be included in the manufacturer's literature accompanying the equipment.

The interconnection customer must verify that the intended use of the equipment falls within the use or uses for which the equipment was tested, labeled, and listed by the NRTL.

Certified equipment shall not require further type-test review, testing, or additional equipment to meet the requirements of this interconnection procedure; however, nothing herein in this Schedule 2 shall preclude the need for an on-site commissioning test by the parties to the interconnection nor follow up production testing by the NRTL.

If the certified equipment package includes only interface components (switchgear, inverters, or other interface devices), then an IC must show that the generator or other electric source being utilized with the equipment package is compatible with the equipment package and is consistent with the testing and listing specified for this type of interconnection equipment.

Provided the generator or electric source, when combined with the equipment package, is within the range of capabilities for which it was tested by the NRTL, and does not violate the interface components' labeling and listing performed by the NRTL, no further design review, testing, or additional equipment on the customer side of the point of interconnection shall be required to meet the requirements of this interconnection procedure.

An equipment package does not include equipment provided by the utility.

Schedule 3

Certification Codes and Standards

Attachment 3 of the FERC Small Generator Interconnection Procedures (SGIP) in 70 FR 34189 (June 13, 2005):

IEEE Std 1547 Standard for Interconnecting Distributed Resources with Electric Power Systems (including use of IEEE Std 1547.1 testing protocols to establish conformity)

UL 1741 Inverters, Converters, and Controllers for Use in Independent Power Systems

IEEE Std 929‑2000 IEEE Recommended Practice for Utility Interface of Photovoltaic (PV) Systems

NFPA 70 (2005), National Electrical Code

IEEE Std C37.90.1‑1989 (R1994), IEEE Standard Surge Withstand Capability (SWC) Tests for Protective Relays and Relay Systems

IEEE Std C37.90.2 (1995), IEEE Standard Withstand Capability of Relay Systems to Radiated Electromagnetic Interference from Transceivers

IEEE Std C37.108‑1989 (R2002), IEEE Guide for the Protection of Network Transformers

IEEE Std C57.12.44‑2000, IEEE Standard Requirements for Secondary Network Protectors

IEEE Std C62.41.2‑2002, IEEE Recommended Practice on Characterization of Surges in Low Voltage (1000V and Less) AC Power Circuits

IEEE Std C62.45‑1992 (R2002), IEEE Recommended Practice on Surge Testing for Equipment Connected to Low-Voltage (1000V and Less) AC Power Circuits

ANSI C84.1‑1995 Electric Power Systems and Equipment – Voltage Ratings (60 Hertz)

IEEE Std 100‑2000, IEEE Standard Dictionary of Electrical and Electronic Terms

NEMA MG 1‑1998, Motors and Small Resources, Revision 3

IEEE Std 519‑1992, IEEE Recommended Practices and Requirements for Harmonic Control in Electrical Power Systems

NEMA MG 1‑2003 (Rev 2004), Motors and Generators, Revision 1

Schedule 4

LEVELS 2 AND 3 INTERCONNECTION REQUEST FORM SMALL GENERATING FACILITY LESS THAN 20 MW

Section 1. Interconnection Customer Information

Name:_________________________________________________________

Contact person:__________________________________________________

Mailing address:_________________________________________________

City, State, Zip:__________________________________________________

Utility and account number:_________________________________________

Energy Service Provider and account number:__________________________

Facility address:_________________________________________________

Telephone (Day):________________ (Evening):________________________

Fax:__________________________ E-Mail:__________________________

Alternative contact information

Contact Name:__________________________________________________

Title:_________________________________________________________

Mailing Address:________________________________________________

City, State, Zip:__________________________________________________

Telephone (Day):________________ (Evening):________________________

Fax:__________________________ E-Mail:__________________________

Application is for: New Small Generating Facility______ Capacity addition____

If capacity addition to existing facility, please describe:
______________________________________________________________

The Small Generating Facility will supply: Interconnection Customer __ others __

Point of Interconnection:___________________________________________

Interconnection Customer's requested in-service date:____________________

Section 2. Processing Fee or Deposit

If the Interconnection Request is submitted as Level 2, the nonrefundable processing fee payable to the utility is $500.

If the Interconnection Request is submitted as Level 3, the Interconnection Customer shall submit to the Utility the deposit is $1,000, or 50% of the estimated cost of the Feasibility Study, whichever is less.

Section 3. Small Generating Facility Information

Data apply only to the small generating facility, not the interconnection facilities.

Energy Source:___ Solar___ Wind___ Hydro___ Hydro Type:______________

Diesel___ Natural Gas___ Fuel Oil___ Other (describe)___________________

Prime Mover: Fuel Cell____ Recip Engine____ Gas Turb____ Steam Turb____ Microturbine____ PV____ Other (describe)_____________________________

Type of Generator: Synchronous_____ Induction_____ Inverter_____

Generator Nameplate Rating:________ kW ___ Generator Nameplate kVAR:______

Interconnection customer or customer-site load:__________kW

Typical reactive load:_________________

Maximum physical export capability requested:______________ kW

List components of the small generating facility equipment package that are currently certified:

Equipment

Certifying Entity

1.____________________________

1.____________________________

2.____________________________

2.____________________________

3.____________________________

3.____________________________

4.____________________________

4.____________________________

5.____________________________

5.____________________________

Is the prime mover compatible with the certified protective relay package?
Yes____No____

Generator (or solar collector)

Manufacturer, model name & number:_________________________________

Version Number:_________________________________________________

Nameplate Output Power Rating in kW: (Summer)_________ (Winter)______

Nameplate Output Power Rating in kVA: (Summer)________ (Winter)______

Individual Generator Power Factor

Rated Power Factor: Leading:_____________ Lagging:________________

Total number of generators in wind farm to be interconnected pursuant to this Interconnection Request: Elevation:_______ Single phase___ Three phase___

Inverter manufacturer, model name & number:__________________________

List of adjustable set points for the protective equipment or software:_________

Note: A completed power systems load flow data sheet must be supplied with the Interconnection Request.

Small Generating Facility Characteristic Data (for inverter-based machines)

Max design fault contribution current:______ Instantaneous___ or RMS_______

Harmonics characteristics:__________________________________________

Start-up requirements:_____________________________________________

Small Generating Facility Characteristic Data (for rotating machines)

RPM Frequency:_______________________________________________

Neutral Grounding Resistor (If Applicable):____________

Synchronous Generators:

Direct Axis Synchronous Reactance, Xd:_______ P.U.

Direct Axis Transient Reactance, X'd:___________ P.U.

Direct Axis Subtransient Reactance, X"d:______________ P.U.

Negative Sequence Reactance, X2:_________ P.U.

Zero Sequence Reactance, X0:____________ P.U.

KVA Base:___________________________

Field Volts:______________

Field Amperes:___________

Induction Generators:

Motoring Power (kW):______________

I2t or K (Heating Time Constant):______________

Rotor Resistance, Rr:______________

Stator Resistance, Rs:______________

Stator Reactance, Xs:______________

Rotor Reactance, Xr:______________

Magnetizing Reactance, Xm:_____________

Short Circuit Reactance, Xd"':______________

Exciting Current:______________

Temperature Rise:______________

Frame Size:______________

Design Letter:______________

Reactive Power Required In Vars (No Load):______________

Reactive Power Required In Vars (Full Load):______________

Total Rotating Inertia, H:_____________ Per Unit on kVA base

Excitation and Governor System Data for Synchronous Generators Only:

Provide appropriate IEEE model block diagram of excitation system, governor system and power system stabilizer (PSS) in accordance with the regional reliability council criteria. A PSS may be determined to be required by applicable studies. A copy of the manufacturer's block diagram may not be substituted.

Section 4. Customer's Interconnection Facilities Information

Will a transformer be used between the generator and the point of interconnection ? Yes ____No ____

Will the transformer be provided by the interconnection customer? Yes ____No ____

Transformer Data (If applicable, for interconnection customer-owned transformer):

Is the transformer: single phase_____ three phase____ Size: kVA_____

Transformer Impedance:_______% on __________kVA base

If Three Phase:

Transformer Primary:_____ Volts _____ Delta _____ Wye _____ Wye Grounded

Transformer Secondary:___ Volts _____ Delta _____ Wye _____ Wye Grounded

Transformer Tertiary:_____ Volts _____ Delta _____ Wye _____ Wye Grounded

 

Transformer Fuse Data (If applicable, for interconnection customer-owned fuse):

(Attach copy of fuse manufacturer's minimum melt and total clearing time-current curves)

Manufacturer:____________ Type:__________ Size:______ Speed:_______

 

Interconnecting Circuit Breaker (if applicable):

Manufacturer:____________________________ Type:__________

Load Rating (Amps):___ Interrupting Rating (Amps):___ Trip Speed (Cycles):___

Interconnection Protective Relays (If Applicable):

If microprocessor-controlled:

Manufacturer:__________________________ Type:____________________

Model No. ___________ Firmware ID:_______ Instruction Book No. _________

List of functions and adjustable setpoints for the protective equipment or software:

Setpoint Function

Minimum

Maximum

1.________________________________

____________

__________

2.________________________________

____________

__________

3.________________________________

____________

__________

4.________________________________

____________

__________

5.________________________________

____________

__________

6.________________________________

____________

__________

 

If Discrete Components:

(Enclose copy of any proposed time-overcurrent coordination curves)

Manufacturer:___________ Type:_______ Style/Catalog No.:______ Proposed Setting:______

Manufacturer:___________ Type:_______ Style/Catalog No.:______ Proposed Setting:______

Manufacturer:___________ Type:_______ Style/Catalog No.:______ Proposed Setting:______

Manufacturer:___________ Type:_______ Style/Catalog No.:______ Proposed Setting:______

Manufacturer:___________ Type:_______ Style/Catalog No.:______ Proposed Setting:______

 

Current Transformer Data (If applicable):

(Enclose copy of manufacturer's excitation and ratio correction curves)

Manufacturer:_________________________________________________

Type:_______ Accuracy Class:________ Proposed Ratio Connection:_____

Manufacturer:_________________________________________________

Type:_______ Accuracy Class:________ Proposed Ratio Connection:_____

Potential Transformer Data (If applicable):

Manufacturer:_________________________________________________

Type:________ Accuracy Class:_______ Proposed Ratio Connection:_____

Manufacturer:_________________________________________________

Type:________ Accuracy Class:_______ Proposed Ratio Connection:_____

Section 5. General Information

Enclose a copy of the site electrical one-line diagram showing the configuration of the small generating facility equipment, current and potential circuits, and protection and control schemes.

Enclose a copy of any site documentation that indicates the precise physical location of the proposed SGF (e.g., United States Geological Survey () topographic map or other diagram or documentation).

Describe the proposed location of the protective interface equipment on the property:____________________________________________________

Enclose a copy of any site documentation that describes and details the operation of the protection and control schemes. Is available documentation enclosed? Yes____ No____

Enclose copies of schematic drawings for all protection and control circuits, relay current circuits, relay potential circuits, and alarm/monitoring circuits (if applicable).

Are schematic drawings enclosed? Yes____ No____

Section 6. Interconnection Customer Signature

I hereby certify that, to the best of my knowledge, all the information provided in this Interconnection Request is true and correct.

Signature:_____________________________ Date:________________

Section 7. Utility Acknowledgement of Receipt

Signed:_____________________________________

Title:_______________________________________

Utility:______________________________________

Date:______________________________________

Utility signature signifies only receipt of this form, in compliance with 20VAC5-314-50 of the State Corporation Commission's Regulations Governing Interconnection of Small Electrical Generators.

GENERATING FACILITY PREAPPLICATION REPORT REQUEST FORM

 

Preamble and Instructions

 

An interconnection customer who requests a preapplication report must submit this preapplication report request by hand delivery, mail, email, or fax to the utility along with the nonrefundable fee of $500.

 

DISCLAIMER: Be aware that this preapplication report is simply a snapshot in time and is nonbinding. System conditions can and do change frequently.

 

 Check here if payment is enclosed. Fee is required for application to be considered complete.

 

Date:______________

 

Interconnection Customer Name (print):________________________________

________________________________________________________________

Contact Person:___________________________________________________

________________________________________________________________

Mailing Address:___________________________________________________

________________________________________________________________

City:___________________________State:___________Zip Code:__________

Telephone (Daytime):_________________

Email Address:____________________________________________________

 

Alternative Contact Information (e.g., system installation contractor or

coordinating company)

Name (print): ___________________________________

Role:_____________________________________________________________

Contact Person:____________________________________________________

_________________________________________________________________

Mailing Address:____________________________________________________

City:___________________________State:___________Zip Code:___________

Telephone (Daytime):_________________

Email Address:____________________________________________________

 

Facility Information:

1. Proposed facility location

Address (or cross-roads):_________________________________________

City:_____________________State:__________________Zip Code:_______

 

 Site map provided (Google, MapQuest, etc.)

 Grid coordinates - Latitude: __________ Longitude: ______________

 Pole or tower number if available:_____________________________

 

2. Primary energy source

Choose one:

Renewable

Nonrenewable

 Solar – Photovoltaic

 Solar – Thermal

 Biomass – Landfill Gas

 Biomass – Manure Digester Gas

 Biomass – Directed Biogas

 Biomass – Solid Waste

 Biomass – Sewage Digester Gas

 Biomass – Wood

 Biomass – Other (please specify)

 Hydro Power – Run of River

 Hydro Power – Storage

 Hydro Power – Tidal

 Hydro Power – Wave

 Wind

 Geothermal

 Battery

 Other (please specify)

 Fossil Fuel – Diesel

 Fossil Fuel – Natural Gas (not waste)

 Fossil Fuel – Oil

 Fossil Fuel – Coal

 Fossil Fuel – Other (please specify)

 Other (please specify)

 

3. Prime mover

Choose one:

 Photovoltaic (PV)

 Fuel Cell

 Reciprocating Engine

 Gas Turbine

 Steam Turbine

 Micro-Turbine

 Other, Including Combined Heat and Power (please specify)

 

4. Type of generator

Choose one:

 Inverter-Based Machine

 Induction

 Synchronous

 Other (please specify)

 

5. Generator/Storage Nameplate Capacity:   _____ kW

 

Maximum Generating Capacity requested:  _____ kWAC

 

(The maximum continuous electrical output of the generating facility at any time at a power factor of approximately unity as measured at the point of interconnection and the maximum kW delivered to the utility during any metering period.)

 

Storage Nameplate Energy:  ______kWh

 

6. Generator configuration: Single-phase            Three-phase

 

7. Interconnection configuration

 

 New generation

 Stand-alone

 Addition to existing commercial or industrial customer's delivery

Customer's electric utility account number:___________________

Customer's electric meter number:_________________________

Is Customer's kW load going to increase or decrease?

 No

 Yes, Details,

______________________________________________________________

 

Proposed point of interconnection on customer-side of utility meter   

______________________________________________________________

**OR**

 Addition to existing generation

 Stand-alone

 Addition to existing commercial or industrial customer's delivery

Customer's electric utility account number:

________________________________________________

Customer's electric meter number:

________________________________________________

Is Customer's kW load going to increase or decrease?

 No

 Yes, Details,____________________________________

Type of existing generation:__________________________

________________________________________________

________________________________________________

 

Size of existing generation:______________________ kWAC

Proposed point of interconnection on customer-side of utility meter

 

Additional comments

______________________________________________________________

Schedule 5

LEVELS 2 AND 3 FACILITIES STUDY INFORMATION FORM FOR SMALL GENERATING FACILITIES LESS THAN 20 MW

1. Provide a location plan and simplified one-line diagram of the plant and station facilities.

For staged projects, indicate future generation, future transmission circuits, and other major future facilities. On the one-line diagram, show (i) each generator, its electric connection configuration, and its generation capacity, (ii) the location and capacity of auxiliary power, and (iii) minimum load on CT/PT.

2. One set of metering is required for each generation connection to the new ring bus or existing utility station. Indicate the number of generation connections requiring a metering set:_____________________

3. Indicate whether an alternate source of auxiliary power will be available during CT/PT maintenance. Yes_______ No_______

4. Indicate whether a transfer bus on the generation side of the metering will require that each meter set be designed for the total plant generation. Indicate such on the one-line diagram.

5. State the type of control system or Programmable Logic Controller (PLC) that will be located at the small generating facility.

________________________________________________________________________________________________________________

6. State the protocol used by the control system or PLC. _____________________________________________________________________

7.Describe the operation sequence and timing of the protection scheme during disconnection and reconnection to the utility by the SGF.

8. Provide a 7.5-minute quadrangle map of the site. Indicate the plant, station, transmission line, and property lines.

9. State the physical dimensions of the proposed interconnection station.

______________________________________________________________________________________________________

10. State the bus length from generation to interconnection station.

______________________________________________________________________________________________________

11. Provide a diagram or description of the point of interconnection desired by the IC that is to be the point of interconnection in the system impact study report.

12. State the line length from interconnection station to utility system.

______________________________________________________________________________________________________

13. State the pole or tower number observed in the field affixed to the pole or tower leg. _____________________________________________

14. State the number of third party easements required for distribution or transmission lines.

______________________________________________________________________________________________________

15. Provide the following proposed schedule dates:

a. Date IC to begin construction:_________________________________________________

b. Date generator step-up transformers to receive back feed power:______________________

c. Date IC will test SGF:_______________________________________________________

d. Date IC will place SGF into commercial operation:_________________________________

LEVEL 1 INTERCONNECTION REQUEST FORM FOR SMALL GENERATING FACILITY NOT EXCEEDING 500 kW

PURSUANT TO 20VAC5-314-40, APPLICANT HEREBY GIVES NOTICE OF INTENT TO OPERATE A GENERATING FACILITY.

Section 1. Interconnection Customer Information

Name:____________________________________________________________

Mailing Address:____________________________________________________

City, State, Zip:_____________________________________________________

Street Address:_____________________________________________________

City, State, Zip:_____________________________________________________

Phone Number(s):___________________________________________________

Fax Number:______________________ Email:____________________________

Utility:_____________________________________________________________

Utility Account Number:______________________________

Competitive Service Provider:__________________________________________

CSP Account Number:______________________________

Proposed Interconnection Date:_______________________

 

This Interconnection Request Form is considered complete when the IC provides all applicable and correct information required in this Schedule 5 and complies with the processing fee in Section 2 of this Schedule.

 

An IC who requests a commission jurisdictional interconnection must submit this Interconnection Request Form by hand delivery, mail, email, or fax to the utility.

 

Section 2. Processing Fee

The nonrefundable processing fee payable to the utility is $100.

 

Section 3. Small Generating Facility Information

SGF Owner:_______________________________________________________

SGF Operator:_____________________________________________________

Business Relationship to Applicant:_____________________________________

Mailing Address:___________________________________________________

City, State, Zip:____________________________________________________

SGF Address:_____________________________________________________

City, State, Zip:____________________________________________________

Phone Number(s):__________________________________________________

Fax Number:______________________ Email:__________________________

Fuel Type:________________________________________________________

Generator Manufacturer and Model:____________________________________

Rated Capacity in Kilowatts: AC:_________________________ DC:__________

Inverter Manufacturer and Model:______________________________________

Battery Backup: Yes_____ No_____

Facility schematic and equipment layout must be attached to this form.

 

If not available prior to the completion of the Interconnection Request Form, the IC must provide an address for SGF that has been issued conforming to the 911 emergency response group for the area to the utility within 15 business days of issuance.

 

Section 4. Information for Generators with an AC Capacity in Excess of 25 kW

Is the proposed generator inverter based? Yes_____ No_____

Generator Type: Inverter

Induction

Synchronous

Frequency:__________ Hz; Number of Phases: One___

Three___

Rated Capacity: DC _______ kW; AC Apparent _______ kVA; AC Real _______ kW;

Power Factor ____________%; AC Voltage _________; AC Amperage___________

Facility schematic and equipment layout must be attached to this form.

 

Section 5. Site Control

Enclose a copy of the site control documentation. Any information appearing in public records may not be labeled confidential. (Confidential information is discussed in 20VAC5-314-110.) Site control may be demonstrated through:

1. Ownership of, a leasehold interest in, or a right to develop a site for the purpose of constructing the SGF;

2. An option to purchase or acquire a leasehold interest in a site for such purpose;

3. An exclusive or other business relationship between the IC and the entity having the right to sell, lease, or grant the IC the right to possess or occupy a site for such purpose; or

4. An existing permanent service metered account with the utility at the site and in the name of the IC.

 

Section 6. Vendor Certification

The SGF equipment is listed by Underwriters Laboratories to be in compliance with UL1741.

Signed (Vendor):_____________________________________ Date:____________

Name (Printed):____________________________________________________________

Company:___________________________________________________________

Phone Number:____________________________________________________________

Mailing Address:______________________________________________________

City, State, Zip:_______________________________________________________

 

Section 7. Electrician Certification

The generator equipment has been installed in accordance with the manufacturer's specifications as well as all applicable provisions of the National Electrical Code.

Signed (Licensed Electrician):__________________________ Date:__________

Name (printed):____________________________________________________

License Number:_______________________ Phone Number:_______________

Mailing Address:___________________________________________________

City, State, Zip:____________________________________________________

 

Section 8. Applicant Signature

I hereby certify that, to the best of my knowledge, all of the information provided in this Interconnection Request Form is true and correct.

Signature of Applicant:_____________________________________________

Date:________________________

 

Section 9. Utility Acknowledgment of Receipt

Signed:_______________________________________________________

Title:_________________________________________________________

Utility:________________________________________________________

Date:_________________________

Utility signature signifies only receipt of this form, in compliance with 20VAC5-314-40.

 

Schedule 6

SMALL GENERATOR INTERCONNECTION AGREEMENT (SGIA)

This Small Generator Interconnection Agreement ("Agreement") is made and entered into this ______ day of ____________, 20__, by __________________ (" Utility"), and _________________________________ ("Interconnection Customer") each hereinafter sometimes referred to individually as "Party" or both referred to collectively as the "Parties."

Utility Information

Utility:_________________________________________

Attention:______________________________________________

Address:______________________________________________

City, State, Zip:_________________________________________

Phone:_____________________ Fax:_______________________

Interconnection Customer Information

Interconnection Customer:__________________________________

Attention:_______________________________________________

Address:_______________________________________________

City, State, Zip:__________________________________________

Phone:_______________________ Fax:______________________

Interconnection Customer Application No:________________

In consideration of the mutual covenants set forth herein, the Parties agree as follows:

Article 1. Scope and Limitations of Agreement

1.1 This Agreement shall be used for all Interconnection Requests for generators in excess of 500 kW submitted pursuant to the Commission's Regulations Governing Interconnection of Small Electrical Generators, Chapter 314 of the Virginia Administrative Code.

1.2 This Agreement governs the terms and conditions under which the Interconnection Customer's ("IC") Small Generating Facility ("SGF") will interconnect with, and operate in parallel with, the utility system.

1.3 This Agreement does not constitute an agreement to purchase or deliver the Interconnection Customer's power. The purchase or delivery of power and other services, including station service or backup power, that the IC may require will be covered under separate agreements, possibly with other parties. The IC will be responsible for separately making all necessary arrangements (including scheduling) for delivery of electricity with the applicable utility and provider of transmission service.

1.4 Nothing in this Agreement is intended to affect any other agreement between the utility and the IC.

1.5 Responsibilities of the Parties

1.5.1 The Parties shall perform all obligations of this Agreement in accordance with all applicable laws and regulations, operating requirements, and Good Utility Practice.

1.5.2 The IC shall construct, interconnect, operate and maintain its SGF and construct, operate, and maintain its Customer's Interconnection Facilities in accordance with the applicable manufacturer's recommended maintenance schedule, in accordance with this Agreement, and with Good Utility Practice.

1.5.3 The utility shall construct, operate, and maintain its distribution and transmission system and attachment facilities in accordance with this Agreement, and with Good Utility Practice.

1.5.4 The IC agrees to construct its facilities in accordance with applicable specifications that meet or exceed those provided by the National Electrical Safety Code, the American National Standards Institute, IEEE, Underwriter's Laboratory, and operating requirements in effect at the time of construction and other applicable national and state codes and standards. The IC agrees to design, install, maintain, and operate its SGF so as to reasonably minimize the likelihood of a disturbance adversely affecting or impairing the system or equipment of the utility or affected systems and to otherwise maintain and operate its SGF in accordance with the specifications and certifications under which the SGF was initially installed and interconnected.

1.5.5 Each Party shall operate, maintain, repair, and inspect, and shall be fully responsible for the facilities that it now or subsequently may own unless otherwise specified in the Attachments to this Agreement. Each Party shall be responsible for the safe installation, maintenance, repair and condition of their respective lines and appurtenances on their respective sides of the point of change of ownership. The utility and the IC, as appropriate, shall provide Attachment Facilities and Customer's Interconnection Facilities that adequately protect the utility's personnel, and other persons from damage and injury. The allocation of responsibility for the design, installation, operation, maintenance and ownership of Attachment Facilities and Customer's Interconnection Facilities shall be delineated in the Attachments to this Agreement. The design, installation, operation, and maintenance of such facilities shall be the responsibility of the owner except as otherwise provided for in this Agreement.

1.5.6 The utility shall coordinate with all affected systems to support the interconnection.

1.6 Parallel operation obligations

Once the SGF has been authorized to commence parallel operation, the IC shall abide by all rules and procedures pertaining to the parallel operation of the SGF including, but not limited to the rules and procedures concerning the operation of generation set forth in the tariff.

1.7 Metering

The IC shall be responsible for the utility's reasonable and necessary cost for the purchase, installation, operation, maintenance, testing, repair, and replacement of metering and data acquisition equipment specified in Attachments 2 and 3 of this Agreement. The IC's metering (and data acquisition, as required) equipment shall conform to applicable industry rules and operating requirements.

1.8 Reactive power

1.8.1 The IC shall design its SGF to maintain a composite power delivery at continuous rated power output at the point of interconnection at a power factor within the range of 0.95 leading to 0.95 lagging, unless the utility has established different requirements that apply to all similarly situated generators in the control area on a comparable basis. The requirements of this paragraph shall not apply to wind generators.

1.8.2 The utility is required to pay the Interconnection Customer for reactive power that the IC provides or absorbs from the SGF when the utility requests the IC to operate its SGF outside the range specified in article 1.8.1. In addition, if the utility pays its own or affiliated generators for reactive power service within the specified range, it must similarly pay the IC.

1.8.3 Payments shall be in accordance with the IC's applicable rate schedule as may be in effect and accepted by the appropriate government authority. To the extent that no rate schedule is in effect at the time the Interconnection Customer is required to provide or absorb reactive power under this Agreement, the IC may expeditiously file such rate schedule with the appropriate government authority, and the utility agrees to support any request for waiver of any prior notice requirement of such authority in order to permit compensation to the IC from the time service commenced.

1.9 Capitalized terms used herein shall have the meanings specified in the definitions in Attachment 1 to Schedule 6 or in the body of this Agreement.

Article 2. Inspection, Testing, Authorization, and Right of Access

2.1 Equipment testing and inspection

2.1.1 The Interconnection Customer shall test and inspect its small generating facility and interconnection facilities prior to interconnection. The IC shall notify the utility of such activities no fewer than five business days (or as may be agreed to by the Parties) prior to such testing and inspection. Testing and inspection shall occur on a business day. The utility may, at its own expense, send qualified personnel to the SGF site to inspect the interconnection and observe the testing. The IC shall provide the utility a written test report when such testing and inspection is completed.

2.1.2 The utility shall provide the IC written acknowledgment that it has received the IC's written test report. Such written acknowledgment shall not be deemed to be or construed as any representation, assurance, guarantee, or warranty by the utility of the safety, durability, suitability, or reliability of the SGF or any associated control, protective, and safety devices owned or controlled by the IC or the quality of power produced by the SGF.

2.2 Authorization required prior to parallel operation

2.2.1 The utility shall use reasonable efforts to list applicable parallel operation requirements in Attachment 5 of this Agreement. Additionally, the utility shall notify the Interconnection Customer of any changes to these requirements as soon as they are known. The utility shall make reasonable efforts to cooperate with the IC in meeting requirements necessary for the IC to commence parallel operations by the in-service date.

2.2.2 The IC shall not operate its SGF in parallel with the utility's system without prior written authorization of the utility. The utility will provide such authorization once the utility receives notification that the IC has complied with all applicable parallel operation requirements. Such authorization shall not be unreasonably withheld, conditioned, or delayed.

2.3 Right of access

2.3.1 Upon reasonable notice, the utility may send a qualified person to the premises of the Interconnection Customer at or immediately before the time the SGF first produces energy to inspect the interconnection, and observe the commissioning of the SGF (including any required testing), startup, and operation for a period of up to three business days after initial start-up of the unit. In addition, the IC shall notify the utility at least five business days prior to conducting any on-site verification testing of the SGF.

2.3.2 Following the initial inspection process described above, at reasonable hours, and upon reasonable notice, or at any time without notice in the event of an emergency or hazardous condition, the utility shall have access to the Interconnection Customer's premises for any reasonable purpose in connection with the performance of the obligations imposed on it by this Agreement or if necessary to meet its legal obligation to provide service to its customers.

2.3.3 Each Party shall be responsible for its own costs associated with this article.

Article 3. Effective Date, Term, Termination, and Disconnection

3.1 Effective date

This Agreement shall become effective upon execution by the Parties. The utility shall promptly file this Agreement with the Commission's Division of Energy Regulation upon execution.

3.2 Term of Agreement

This Agreement shall remain in effect for a period of 10 years from the effective date or such other longer period as the Interconnection Customer may request and shall be automatically renewed for each successive one-year period thereafter, unless terminated earlier in accordance with article 3.3 of this Agreement.

3.3 Termination

No termination shall become effective until the Parties have complied with all applicable laws and regulations applicable to such termination, including the filing with the Commission's Division of Energy Regulation of a notice of termination of this Agreement.

3.3.1 The Interconnection Customer may terminate this Agreement at any time by giving the utility 20 business days written notice.

3.3.2 Either Party may terminate this Agreement after default pursuant to article 7.6.

3.3.3 Upon termination of this Agreement, the Small Generating Facility will be disconnected from the utility system. The termination of this Agreement shall not relieve either Party of its liabilities and obligations, owed or continuing at the time of the termination.

3.4 Temporary disconnection

Temporary disconnection shall continue only for so long as reasonably necessary under Good Utility Practice.

3.4.1 Emergency Conditions -- "Emergency Condition" shall mean a condition or situation: (i) that in the judgment of the Party making the claim is imminently likely to endanger life or property; or (ii) that, in the case of the utility, is imminently likely (as determined in a non-discriminatory manner) to cause a material adverse effect on the security of, or damage to the utility system, the Attachment Facilities or the electrical facilities of others to which the utility system is directly connected; or (iii) that, in the case of the Interconnection Customer, is imminently likely (as determined in a non-discriminatory manner) to cause a material adverse effect on the security of, or damage to, the Small Generating Facility or the Customer's Interconnection Facilities. Under emergency conditions, the utility may immediately suspend interconnection service and temporarily disconnect the SGF. The utility shall notify the IC promptly when it becomes aware of an emergency condition that may reasonably be expected to affect the IC's operation of the SGF. The IC shall notify the utility promptly when it becomes aware of an emergency condition that may reasonably be expected to affect the utility system or other affected systems. To the extent information is known, the notification shall describe the emergency condition, the extent of the damage or deficiency, the expected effect on the operation of both Parties' facilities and operations, its anticipated duration, and the necessary corrective action.

3.4.2 Routine maintenance, construction, and repair

The utility may interrupt interconnection service or curtail the output of the SGF and temporarily disconnect the SGF from the utility's system when necessary for routine maintenance, construction, and repairs on the utility system. The utility shall provide the IC with at least five business days notice prior to such interruption unless circumstances require shorter notice. The utility shall use reasonable efforts to coordinate such reduction or temporary disconnection with the IC.

3.4.3 Forced outages

During any forced outage, the utility may suspend interconnection service to effect immediate repairs on the utility system. The utility shall use reasonable efforts to provide the IC with prior notice. If prior notice is not given, the utility shall, upon request, provide the IC written documentation after the fact explaining the circumstances of the disconnection.

3.4.4 Adverse operating effects

The utility shall notify the IC as soon as practicable if, based on Good Utility Practice, operation of the SGF may cause disruption or deterioration of service to other customers served from the utility system or affected systems, or if operating the SGF could cause damage to the utility system or affected systems. Supporting documentation used to reach the decision to disconnect shall be provided to the IC upon request. If, after notice, the IC fails to remedy the adverse operating effect within a reasonable time, the utility may disconnect the SGF. The utility shall provide the IC with a five business day notice of such disconnection, unless the provisions of article 3.4.1 apply.

3.4.5 Modification of the Small Generating Facility

The Interconnection Customer must receive written authorization from the utility before making changes to the SGF or mode of operations that may have a material impact on the safety or reliability of the utility system or affected system. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the IC makes such modifications without the utility's prior written authorization, the latter shall have the right to temporarily disconnect the SGF.

3.4.6 Reconnection

The Parties shall cooperate with each other to restore the SGF, interconnection facilities, and the utility system to their normal operating state as soon as reasonably practicable following a temporary disconnection.

Article 4. Cost Responsibility for Customer's Interconnection Facilities, Attachment Facilities, and Distribution Upgrades

4.1 Customer's Interconnection Facilities

The IC shall be responsible for the costs associated with owning, operating, maintaining, repairing, and replacing the Customer's Interconnection Facilities.

4.2 Attachment Facilities

The IC shall pay for one-time and ongoing costs of installing, owning, operating, maintaining and replacing the attachment facilities itemized in Attachment 2 of this Agreement. The utility shall provide an estimated costfor the purchase and construction of the attachment facilities and provide a detailed itemization of such costs. Costs associated with attachment facilities may be shared with other entities that may benefit from such facilities by agreement of the IC, such other entities, and the utility.

4.3 Distribution upgrades

The utility shall design, procure, construct, install, and own the distribution upgrades described in Attachment 6 of this Agreement. The actual cost of the distribution upgrades shall be directly assigned to the IC. If the utility and the IC agree, the IC may construct distribution upgrades that are located on land owned by the IC.

Article 5. Transmission System

5.1 Transmission system upgrades

5.1.1 No portion of section 5.1 of this article 5 shall apply unless the interconnection of the Small Generating Facility requires transmission system upgrades.

5.1.2 The utility shall design, procure, construct, install, and own the transmission system upgrades described in Attachment 6 of this Agreement. If the utility and the Interconnection Customer agree, the IC may construct transmission system upgrades that are located on land owned by the IC. The costs of the transmission system upgrades shall be borne by the IC.

5.1.3 Notwithstanding any other provision of section 5.1 of article 5, in the event and to the extent an RTE has rules, tariffs, agreements, or procedures properly applying to transmission system upgrades, the provisions of section 5.2 of article 5 shall apply to such upgrades.

5.2 Regional Transmission Entities

Notwithstanding any other provision of this Agreement, if the utility's transmission system is under the control of an RTE and the RTE has rules, tariffs, agreements or procedures properly governing operation of the SGF, transmission of the output of the SGF, sale of the output of the SGF, system upgrades required for interconnection of the SGF, or other aspects of the interconnection and operation of the SGF, the IC and the utility shall comply with the applicable of such agreements, rules, tariffs, or procedures.

5.3 Rights under other agreements

Notwithstanding any other provision of this Agreement, nothing herein shall be construed as relinquishing or foreclosing any rights, including but not limited to firm transmission rights, capacity rights, transmission congestion rights, or transmission credits, that the IC shall be entitled to, now or in the future, under any other agreement or tariff as a result of, or otherwise associated with system upgrades, including the right to obtain cash reimbursements or transmission credits for transmission service that is not associated with the SGF.

Article 6. Billing, Payment, Milestones, and Financial Security

6.1 Billing and payment procedures and final accounting

6.1.1 The utility shall bill the IC for the design, engineering, construction, and procurement costs of attachment facilities and upgrades contemplated by this Agreement on a monthly basis, or as otherwise agreed by the Parties. The IC shall pay each bill within 30 calendar days of receipt, or as otherwise agreed to by the Parties.

6.1.2 Within 120 calendar days of completing the construction and installation of the attachment facilities and/or distribution upgrades described in the Attachments to this Agreement, the utility shall provide the IC with a final accounting report of any difference between (i) the IC's cost responsibility for the actual cost of such facilities or upgrades, and (ii) the IC's previous aggregate payments to the utility for such facilities or upgrades. If the IC's cost responsibility exceeds its previous aggregate payments, the utility shall invoice the IC for the amount due and the IC shall make payment to the utility within 30 calendar days. If the IC's previous aggregate payments exceed its cost responsibility under this Agreement, the utility shall refund to the IC an amount equal to the difference within 30 calendar days of the final accounting report.

6.2 Milestones

The Parties shall agree on milestones for which each Party is responsible and such milestone shall be listed in Attachment 4 of this Agreement. A Party's milestones obligations under this provision may be modified by agreement. If a Party anticipates that it will be unable to meet a milestone for any reason other than a Force Majeure event, it shall immediately (i) notify the other Party of the reason(s) for not meeting the milestone, and (ii) propose the earliest reasonable alternate date by which it can attain this and future milestones, and (iii) request appropriate amendments to Attachment 4. The Party affected by the failure to meet a milestone shall not withhold agreement to such an amendment unless it will suffer uncompensated economic or operational harm from the delay, attainment of the same milestone has previously been delayed, or it has reason to believe that the delay in meeting the milestone is intentional or unwarranted notwithstanding the circumstances explained by the Party proposing the amendment.

6.3 Financial security arrangements

At least 20 business days prior to the commencement of the design, procurement, installation, or construction of a discrete portion of the attachment facilities and distribution upgrades, the Interconnection Customer shall provide the utility, at the IC's option, a guarantee, a surety bond, letter of credit or other form of security that is reasonably acceptable to the utility and is consistent with the Uniform Commercial Code of the jurisdiction where the point of interconnection is located. Such security for payment shall be in an amount sufficient to cover the costs for designing, procuring, installing, and constructing the applicable portion of the attachment facilities and distribution upgrades and shall be reduced on a dollar-for-dollar basis for payments made to the utility under this Agreement during its term. In addition:

6.3.1 The guarantee must be made by an entity that meets the creditworthiness requirements of the utility, and contain terms and conditions that guarantee payment of any amount that may be due from the IC, up to an agreed-to maximum amount.

6.3.2 The letter of credit or surety bond must be issued by a financial institution or insured reasonably acceptable to the utility and must specify a reasonable expiration date.

Article 7. Assignment, Liability, Indemnity, Force Majeure, Consequential Damages, and Default

7.1 Assignment

This Agreement may be assigned by either Party upon 15 business days prior written notice and opportunity to object by the other Party; provided that:

7.1.1 Either Party may assign this Agreement without the consent of the other Party to any affiliate of the assigning Party with an equal or greater credit rating and with the legal authority and operational ability to satisfy the obligations of the assigning Party under this Agreement;

7.1.2 The Interconnection Customer shall have the right to assign this Agreement, without the consent of the utility, for collateral security purposes to aid in providing financing for the SGF, provided that the IC will promptly notify the utility of any such assignment.

7.1.3 Any attempted assignment that violates this article is void and ineffective.

Assignment shall not relieve a Party of its obligations, nor shall a Party's obligations be enlarged, in whole or in part, by reason thereof. An assignee is responsible for meeting the same financial, credit, and insurance obligations as the IC. Where required, consent to assignment will not be unreasonably withheld, conditioned or delayed.

7.2 Limitation of liability

Each Party's liability to the other Party for any loss, cost, claim, injury, liability, or expense, including reasonable attorney's fees, relating to or arising from any act or omission in its performance of this Agreement, shall be limited to the amount of direct damage actually incurred. In no event shall either Party be liable to the other Party for any indirect, special, consequential, or punitive damages, except as authorized by this Agreement.

7.3 Indemnity

7.3.1 This provision protects each Party from liability incurred to third parties as a result of carrying out the provisions of this Agreement. Liability under this provision is exempt from the general limitations on liability found in article 7.2.

7.3.2 The Parties shall at all times indemnify, defend, and hold the other Party harmless from, any and all damages, losses, claims, including claims and actions relating to injury to or death of any person or damage to property, demand, suits, recoveries, costs and expenses, court costs, attorney fees, and all other obligations by or to third parties, arising out of or resulting from the other Party's action or failure to meet its obligations under this Agreement on behalf of the indemnifying Party, except in cases of gross negligence or intentional wrongdoing by the indemnified Party.

7.3.3 If an indemnified Party is entitled to indemnification under this article as a result of a claim by a third party, and the indemnifying Party fails, after notice and reasonable opportunity to proceed under this article, to assume the defense of such claim, such indemnified person may at the expense of the indemnifying Party contest, settle or consent to the entry of any judgment with respect to, or pay in full, such claim.

7.3.4 If an indemnifying Party is obligated to indemnify and hold any indemnified person harmless under this article, the amount owing to the indemnified person shall be the amount of such indemnified person's actual loss, net of any insurance or other recovery.

7.3.5 Promptly after receipt by an indemnified person of any claim or notice of the commencement of any action or administrative or legal proceeding or small generator investigation as to which the indemnity provided for in this article may apply, the indemnified person shall notify the indemnifying Party of such fact. Any failure of or delay in such notification shall not affect a Party's indemnification obligation unless such failure or delay is materially prejudicial to the indemnifying party.

7.4 Consequential damages

Other than as expressly provided for in this Agreement, neither Party shall be liable under any provision of this Agreement for any losses, damages, costs or expenses for any special, indirect, incidental, consequential, or punitive damages, including but not limited to loss of profit or revenue, loss of the use of equipment, cost of capital, cost of temporary equipment or services, whether based in whole or in part in contract, in tort, including negligence, strict liability, or any other theory of liability; provided that damages for which a Party may be liable to the other Party under another agreement will not be considered to be special, indirect, incidental, or consequential damages hereunder.

7.5 Force Majeure

7.5.1 As used in this article, a Force Majeure event means "any act of God, labor disturbance, act of the public enemy, war, insurrection, riot, fire, storm or flood, explosion, breakage or accident to machinery or equipment, any order, regulation or restriction imposed by governmental, military or lawfully established civilian authorities, or any other cause beyond a Party's control. A Force Majeure event does not include an act of negligence or intentional wrongdoing."

7.5.2 If a Force Majeure event prevents a Party from fulfilling any obligations under this Agreement, the Party affected by the Force Majeure event ("Affected Party") shall promptly notify the other Party, either in writing or via the telephone, of the existence of the Force Majeure event. The notification must specify in reasonable detail the circumstances of the Force Majeure event, its expected duration, and the steps that the Affected Party is taking to mitigate the effects of the event on its performance. The Affected Party shall keep the other Party informed on a continuing basis of developments relating to the Force Majeure event until the event ends. The Affected Party will be entitled to suspend or modify its performance of obligations under this Agreement (other than the obligation to make payments) only to the extent that the effect of the Force Majeure event cannot be mitigated by the use of reasonable efforts. The Affected Party will use reasonable efforts to resume its performance as soon as possible.

7.6 Default

7.6.1 No default shall exist where such failure to discharge an obligation (other than the payment of money) is the result of a Force Majeure event as defined in this Small Generator Interconnection Agreement or the result of an act or omission of the other Party. Upon a default, the Nondefaulting Party shall give written notice of such default to the Defaulting Party. Except as provided in article 7.6.2, the Defaulting Party shall have 60 calendar days from receipt of the default notice within which to cure the default; however, if the default is not capable of cure within 60 calendar days, the Defaulting Party shall commence the cure within 20 calendar days after notice and continuously and diligently complete the cure within six months from receipt of the default notice; and, if cured within such time, the default specified in such notice shall cease to exist.

7.6.2 If a default is not cured as provided in this article, or if a default is not capable of being cured within the period provided for herein, the Nondefaulting Party shall have the right to terminate this Agreement by written notice at any time until cure occurs, and be relieved of any further obligation hereunder and, whether or not that Party terminates this Agreement, to recover from the Defaulting Party all amounts due hereunder, plus all other damages and remedies to which it is entitled at law or in equity. The provisions of this article will survive termination of this Agreement.

Article 8. Insurance

8.1 The Interconnection Customer shall, at its own expense, maintain in force general liability insurance without any exclusion for liabilities related to the interconnection undertaken pursuant to this Agreement. The amount of such insurance shall be in accordance with 20VAC5-314-160 of the Commission's Regulations Governing the Interconnection of Small Electrical Generators. The IC shall obtain additional insurance only if necessary as a function of owning and operating a generating facility. Insurance shall be obtained from an insurance provider authorized to do business in the State of Virginia. Certification that such insurance is in effect shall be provided upon request of the utility, except that the IC shall show proof of insurance to the utility no later than 10 business days prior to the anticipated commercial operation date of the SGF. An IC of sufficient creditworthiness may propose to self-insure for such liabilities, and such a proposal shall not be unreasonably rejected.

8.2 The utility agrees to maintain general liability insurance or self insurance consistent with the utility's commercial practice. Such insurance or self-insurance shall not exclude coverage for the utility's liabilities undertaken pursuant to this Agreement.

8.3 The Parties further agree to notify each other whenever an accident or incident occurs resulting in any injuries or damages that are included within the scope of coverage of such insurance, whether or not such coverage is sought.

Article 9. Confidentiality

9.1 Confidential information shall mean any confidential and/or proprietary information provided by one Party to the other Party that is clearly marked or otherwise designated "Confidential." For purposes of this Agreement all design, operating specifications, and metering data provided by the Interconnection Customer shall be deemed confidential information regardless of whether it is clearly marked or otherwise designated as such.

9.2 Confidential information does not include information previously in the public domain, required to be publicly submitted or divulged by governmental authorities (after notice to the other Party and after exhausting any opportunity to oppose such publication or release), or necessary to be divulged in an action to enforce this Agreement. Each Party receiving confidential information shall hold such information in confidence and shall not disclose it to any third party nor to the public without the prior written authorization from the Party providing that information, except to fulfill obligations under this Agreement, or to fulfill legal or regulatory requirements.

9.2.1 Each Party shall employ at least the same standard of care to protect confidential information obtained from the other Party as it employs to protect its own confidential information.

9.2.2 Each Party is entitled to equitable relief, by injunction or otherwise, to enforce its rights under this provision to prevent the release of confidential information without bond or proof of damages, and may seek other remedies available at law or in equity for breach of this provision.

9.3 Notwithstanding anything in this Agreement to the contrary, if the Virginia State Corporation Commission ("Commission"), during the course of an investigation or otherwise, requests information from one of the Parties that is otherwise required to be maintained in confidence, the Party shall provide the requested information to the Commission, within the time provided for in the request for information. In providing the information to the Commission, the Party may request that the information be treated as confidential and nonpublic by the Commission and that the information be withheld from public disclosure. Parties are prohibited from notifying the other Party prior to the release of the confidential information to the Commission. A Party shall notify the other Party when it is notified by the Commission that a request to release confidential information has been received by the Commission, at which time either Party may respond to the Commission before such information would be made public.

Article 10. Disputes

10.1 The Parties agree to attempt to resolve all disputes arising out of the interconnection process according to the provisions of this article.

10.2 In the event of a dispute, either Party shall provide the other Party with a written Notice of Dispute. Such Notice shall describe in detail the nature of the dispute. The Parties shall make a good faith effort to resolve the dispute informally within 10 business days.

10.3 If the dispute has not been resolved within 10 business days after receipt of the Notice, either Party may seek resolution assistance from the Commission's Division of Energy Regulation where the matter will be handled as an informal complaint.

Alternatively, either Party may, upon mutual agreement, seek resolution through the assistance of a dispute resolution service. The dispute resolution service will assist the Parties in either resolving the dispute or in selecting an appropriate dispute resolution venue (e.g., mediation, settlement judge, early neutral evaluation, or technical expert) to assist the Parties in resolving their dispute. Each Party shall conduct all negotiations in good faith and shall be responsible for one-half of any costs paid to neutral third parties.

10.4 If the dispute remains unresolved either Party maypetition the Commission to handle the dispute as a formal complaint or may exercise whatever rights and remedies it may have in equity or law consistent with the terms of this Agreement.

Article 11. Taxes

11.1 The Parties agree to follow all applicable tax laws and regulations

11.2 Each Party shall cooperate with the other to maintain the other Party's tax status. Nothing in this Agreement is intended to adversely affect the utility's tax exempt status with respect to the issuance of bonds including, but not limited to, local furnishing bonds.

Article 12. Miscellaneous

12.1 Governing law, regulatory authority, and rules

The validity, interpretation and enforcement of this Agreement and each of its provisions shall be governed by the laws of the State of Virginia without regard to its conflicts of law principles. This Agreement is subject to all applicable laws and regulations. Each Party expressly reserves the right to seek changes in, appeal, or otherwise contest any laws, orders, or regulations of a governmental authority.

12.2 Amendment

The Parties may amend this Agreement by a written instrument duly executed by both Parties.

12.3 No third-party beneficiaries

This Agreement is not intended to and does not create rights, remedies, or benefits of any character whatsoever in favor of any persons, corporations, associations, or entities other than the Parties, and the obligations herein assumed are solely for the use and benefit of the Parties, their successors in interest and where permitted, their assigns.

12.4 Waiver

12.4.1 The failure of a Party to this Agreement to insist, on any occasion, upon strict performance of any provision of this Agreement will not be considered a waiver of any obligation, right, or duty of, or imposed upon, such Party.

12.4.2 Any waiver at any time by either Party of its rights with respect to this Agreement shall not be deemed to be a continuing waiver or a waiver with respect to any other failure to comply with any other obligation, right, or duty of this Agreement. Termination or default of this Agreement for any reason by the Interconnection Customer shall not constitute a waiver of the IC's legal rights to obtain an interconnection from the utility. Any waiver of this Agreement shall, if requested, be provided in writing.

12.5 Entire Agreement

This Agreement, including all Attachments, constitutes the entire agreement between the Parties with reference to the subject matter hereof, and supersedes all prior and contemporaneous understandings or agreements, oral or written, between the Parties with respect to the subject matter of this Agreement. There are no other agreements, representations, warranties, or covenants which constitute any part of the consideration for, or any condition to, either Party's compliance with its obligations under this Agreement.

12.6 Multiple counterparts

This Agreement may be executed in two or more counterparts, each of which is deemed an original but all constitute one and the same instrument.

12.7 No partnership

This Agreement shall not be interpreted or construed to create an association, joint venture, agency relationship, or partnership between the Parties or to impose any partnership obligation or partnership liability upon either Party. Neither Party shall have any right, power or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.

12.8 Severability

If any provision or portion of this Agreement shall for any reason be held or adjudged to be invalid or illegal or unenforceable by any court of competent jurisdiction or other governmental authority, (i) such portion or provision shall be deemed separate and independent, (ii) the Parties shall negotiate in good faith to restore insofar as practicable the benefits to each Party that were affected by such ruling, and (iii) the remainder of this Agreement shall remain in full force and effect.

12.9 Environmental releases

Each Party shall notify the other Party, first orally and then in writing, of the release of any hazardous substances, any asbestos or lead abatement activities, or any type of remediation activities related to the Small Generating Facility, the customer's interconnection facilities, or attachment facilities, each of which may reasonably be expected to affect the other Party. The notifying Party shall (i) provide the notice as soon as practicable, provided such Party makes a good faith effort to provide the notice no later than 24 hours after such Party becomes aware of the occurrence, and (ii) promptly furnish to the other Party copies of any publicly available reports filed with any governmental authorities addressing such events.

12.10 Subcontractors

Nothing in this Agreement shall prevent a Party from utilizing the services of any subcontractor as it deems appropriate to perform its obligations under this Agreement; however, each Party shall require its subcontractors to comply with all applicable terms and conditions of this Agreement in providing such services and each Party shall remain primarily liable to the other Party for the performance of such subcontractor.

12.10.1 The creation of any subcontract relationship shall not relieve the hiring Party of any of its obligations under this Agreement. The hiring Party shall be fully responsible to the other Party for the acts or omissions of any subcontractor the hiring Party hires as if no subcontract had been made; however, in no event shall the utility be liable for the actions or inactions of the IC or its subcontractors with respect to obligations of the IC under this Agreement. Any applicable obligation imposed by this Agreement upon the hiring Party shall be equally binding upon, and shall be construed as having application to, any subcontractor of such Party.

12.10.2 The obligations under this article will not be limited in any way by any limitation of subcontractor's insurance.

12.11 Reservation of rights

The utility shall have the right to make a unilateral filing with the Commission to modify this Agreement with respect to any rates, terms and conditions, charges, classifications of service, rule or regulation.

Article 13. Notices

13.1 General

Unless otherwise provided in this Agreement, any written notice, demand, or request required or authorized in connection with this Agreement ("Notice") shall be deemed properly given if delivered in person, delivered by recognized national courier service, or sent by first class mail, postage prepaid, to the person specified below:

If to the Interconnection Customer:

Interconnection Customer:____________________________________

Attention:_________________________________________________

Address:_________________________________________________

City, State, Zip:____________________________________________

Phone:___________________________ Fax:____________________

If to the Utility:

Utility:___________________________________________

Attention:_________________________________________________

Address:_________________________________________________

City, State, Zip:____________________________________________

Phone:___________________________ Fax:____________________

13.2 Billing and payment

Billings and payments shall be sent to the addresses set out below:

If to the Interconnection Customer:

Interconnection Customer:_____________________________________

Attention:__________________________________________________

Address:__________________________________________________

City, State, Zip:______________________________________________

If to the Utility:

Utility:___________________________________________

Attention:__________________________________________________

Address:__________________________________________________

City, State, Zip:_____________________________________________

13.3 Alternative forms of notice

Any notice or request required or permitted to be given by either Party to the other and not required by this Agreement to be given in writing may be so given by telephone, facsimile or e-mail to the telephone numbers and email addresses set out below:

If to the Interconnection Customer:

Interconnection Customer:_______________________________________

Attention:____________________________________________________

Address:____________________________________________________

City, State, Zip:_______________________________________________

Phone:___________________________ Fax:_______________________

If to the Utility:

Utility:___________________________________________

Attention:____________________________________________________

Address:____________________________________________________

City, State, Zip:_______________________________________________

Phone:___________________________ Fax:_______________________

13.4 Designated operating representative

The Parties may also designate operating representatives to conduct the communications which may be necessary or convenient for the administration of this Agreement. This person will also serve as the point of contact with respect to operations and maintenance of the Party's facilities.

Interconnection Customer's Operating Representative:

Interconnection Customer:_______________________________________

Attention:____________________________________________________

Address:____________________________________________________

City, State, Zip:_______________________________________________

Phone:___________________________ Fax:_______________________

Utility's Operating Representative:

Utility:___________________________________________

Attention:____________________________________________________

Address:____________________________________________________

City, State, Zip:_______________________________________________

Phone:___________________________ Fax:_______________________

13.5 Changes to the notice information

Either Party may change this information by giving five business days written notice prior to the effective date of the change.

Article 14. Signatures

IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed by their respective duly authorized representatives.

For the Utility

Name:_______________________________________________________

Title:________________________________________________________

Date:_____________________

For the Interconnection Customer

Name:______________________________________________________

Title:________________________________________________________

Date:_____________________

Attachment 1 to

Schedule 6

Glossary of Terms

"Affected system" means an electric utility system other than that of the utility that may be affected by the proposed interconnection.

"Affected system operator" means an entity that operates an affected system or, if the affected system is under the operational control of an independent system operator or a Regional Transmission Entity, such independent entity.

"Applicable laws and regulations" means all duly promulgated applicable federal, state and local laws, regulations, rules, ordinances, codes, decrees, judgments, directives, or judicial or administrative orders, permits and other duly authorized actions of any governmental authority.

"Attachment facilities" means the facilities and equipment owned, operated, and maintained by the utility that are built new in order to physically connect the customer's interconnection facilities to the utility system. Attachment facilities shall not include distribution upgrades or previously existing distribution and transmission facilities.

"Business day" means Monday through Friday, excluding federal holidays.

"Certified" has the meaning ascribed to it in Schedule 2 of Chapter 314 (20VAC5-314) of the Virginia Administrative Code.

"Commission" means the Virginia State Corporation Commission.

"Competitive service provider" means any entity, other than the utility, supplying electric energy service to the Interconnection Customer.

"Customer's interconnection facilities" means all the facilities and equipment owned, operated and maintained by the Interconnection Customer, between the Small Generating Facility and the point of interconnection necessary to physically and electrically interconnect the Small Generating Facility to the utility system.

"Default" means the failure of a breaching Party to cure its breach under the Small Generator Interconnection Agreement.

"Distribution system" means the utility's facilities and equipment generally delivering electricity to ultimate customers from substations supplied by higher voltages (usually at transmission level). For purposes of this Agreement, all portions of the utility's transmission system regulated by the Commission for which interconnections are not within Federal Energy Regulatory Commission jurisdiction are considered also to be subject to Commission regulations.

"Distribution upgrades" means the additions, modifications, and upgrades to the utility's distribution system at or beyond the point of interconnection necessary to abate problems on the utility's distribution system caused by the interconnection of the Small Generating Facility. Distribution upgrades do not include customer's interconnection facilities or attachment facilities.

"Facilities study" has the meaning ascribed to it in the commission's regulations governing the interconnection of small generating facilities at 20VAC5-314-70 E.

"Feasibility study" has the meaning ascribed to it in the commission's regulations governing the interconnection of small generating facilities at 20VAC5-314-70 C.

"FERC" means the Federal Energy Regulatory Commission.

"Good Utility Practice" means any of the practices, methods and acts engaged in or approved by a significant portion of the electric industry during the relevant time period, or any of the practices, methods and acts which, in the exercise of reasonable judgment in light of the facts known at the time the decision was made, could have been expected to accomplish the desired result at a reasonable cost consistent with good business practices, reliability, safety and expedition. Good Utility Practice is not intended to be limited to the optimum practice, method, or act to the exclusion of all others, but rather to be acceptable practices, methods, or acts generally accepted in the region.

"Governmental authority" means any federal, state, local or other governmental regulatory or administrative agency, court, commission, department, board, or other governmental subdivision, legislature, rulemaking board, tribunal, or other governmental authority having jurisdiction over the Parties, their respective facilities, or the respective services they provide, and exercising or entitled to exercise any administrative, executive, police, or taxing authority or power; provided that such term does not include the Interconnection Customer, the utility, or a utility affiliate.

"Interconnection Customer" or "IC" means any entity proposing to interconnect a new Small Generating Facility with the utility system.

"Interconnection request" means the IC's request, in accordance with Chapter 314 (20VAC5-314) of the Virginia Administrative Code, to interconnect a new Small Generating Facility, or to increase the capacity of, or make a material modification to the operating characteristics of, an existing Small Generating Facility that is interconnected with the utility system.

"Interconnection studies" means the studies conducted by the utility, or a third party agreed to by the utility and the Interconnection Customer, in order to determine the interaction of the Small Generating Facility with the utility system and the affected systems in order to specify any modifications to the Small Generating Facility or the electric systems studied to ensure safe and reliable operation of the Small Generating Facility in parallel with the utility system.

"Material modification" means a modification that has a material impact on the cost or timing of any Interconnection Request with a later queue priority date.

"Operating requirements" means any operating and technical requirements that may be applicable due to regional transmission entity, independent system operator, control area, or the utility's requirements, including those set forth in the Small Generator Interconnection Agreement.

"Party" or "Parties" means the utility, the Interconnection Customer or both.

"Point of interconnection" means the point where the customer's interconnection facilities connect to the utility system.

"Regional Transmission Entity" or "RTE" shall refer to an entity having the management and control of a utility's transmission system as further set forth in § 56-579 of the Code of Virginia.

"Small Generating Facility" or "generator" or "SGF" means the Interconnection Customer's equipment for the production of electricity identified in the Interconnection Request.

"Small Generator Interconnection Agreement" or "SGIA" means the agreement between the utility and the Interconnection Customer as set forth in Schedule 6 of Chapter 314 (20VAC5-314) of the Virginia Administrative Code.

"Supplemental review" has the meaning ascribed to it in the Commission's regulations governing the interconnection of small generating facilities at 20VAC5-314-70 I.

"System" or "utility system" means the distribution and transmission facilities owned, controlled, or operated by the utility that are used to deliver electricity.

"System impact study" has the meaning ascribed to it in the Commission's regulations governing the interconnection of small generating facilities at 20VAC5-314-70 D.

"Tariff" means the rates, terms and conditions filed by the utility with the Commission for the purpose of providing Commission-regulated electric service to retail customers.

"Transmission system" means the utility's facilities and equipment delivering electric energy to the distribution system, such facilities usually being operated at voltages above the utility's typical distribution system voltages.

"Utility" means the public utility company subject to regulation by the Commission pursuant to Chapter 10 (§ 56-232 et seq.) of Title 56 of the Code of Virginia with regard to rates and/or service quality to which the Interconnection Customer proposes to interconnect a Small Generating Facility.

Attachment 2 to

Schedule 6

Description and Costs of the Small Generating Facility, Customer's Interconnection Facilities, Attachment Facilities and Metering Equipment

The following shall be provided in this exhibit:

1. An itemization of the major equipment components owned by the Interconnection Customer and the utility, including components of the Small Generating Facility, the customer's interconnection facilities, attachment facilities, and metering equipment. Such itemization shall identify the owner of each item listed.

2. The utility's estimated itemized cost of its attachment facilities and its metering equipment.

3. The utility's estimated cost of its annual operation and maintenance expenses associated with attachment facilities and metering equipment to be charged to the Interconnection Customer.

Attachment 3 to

Schedule 6

One-line Diagram Depicting the Small Generating Facility, Customer's Interconnection Facilities, Attachment Facilities, Metering Equipment, and Distribution Upgrades

(Diagram and description to be provided by Interconnection Customer unless the utility elects to prepare this schedule. If this schedule is prepared by the utility, the IC shall provide a one-line diagram of the SGF and IC's interconnection facilities for the utility to use as a data source for preparing this schedule.)

Attachment 4 to

Schedule 6

Milestones

In-Service Date:___________________

Critical milestones and responsibility as agreed to by the Parties:

Milestone/Date

Responsible Party

(1)___________________________

___________________________

(2)___________________________

___________________________

(3)___________________________

___________________________

(4)___________________________

___________________________

(5)___________________________

___________________________

(6)___________________________

___________________________

(7)___________________________

___________________________

(8)___________________________

___________________________

(9)___________________________

___________________________

(10)__________________________

___________________________

 

Agreed to by:

For the Utility__________________ Date__________

For the Transmission Owner (If Applicable)_____________ Date__________

For the Interconnection Customer____________________ Date__________

Attachment 5 to

Schedule 6

Additional Operating Requirements for the Utility System and Affected Systems Needed to Support the Interconnection Customer's Needs

The utility shall provide requirements that must be met by the Interconnection Customer prior to initiating parallel operation with the utility system.

Attachment 6 to

Schedule 6

Utility's Description of its Distribution and Transmission Upgrades and Estimate of Upgrade Costs

The utility shall provide the following in this attachment:

1. An itemized list of the upgrades required to be constructed by the utility prior to interconnection of the Small Generating Facility, with transmission and distribution related upgrades shown separately.

2. An estimate of the cost of each item listed pursuant to item 1.

3. An estimate of annual operation and maintenance expenses associated with such upgrades that are to be charged to the Interconnection Customer, shown separately for transmission and distribution related items.

LEVELS 2 AND 3 INTERCONNECTION REQUEST FORM FOR SMALL GENERATING FACILITY

Section 1. Interconnection Customer Information

Name:_________________________________________________________

Contact person:_________________________________________________

Mailing address:_________________________________________________

City, State, Zip:__________________________________________________

Telephone (Day):________________ (Evening):________________________

Fax:__________________________ Email:___________________________

Alternative contact information

Contact Name:__________________________________________________

Title:__________________________________________________________

Mailing Address:_________________________________________________

City, State, Zip:__________________________________________________

Telephone (Day):________________ (Evening):________________________

Fax:__________________________ Email:___________________________

 

Application is for: New Small Generating Facility______ Capacity addition_____

If capacity addition to existing facility, please describe:

________________________________________________________________

The Small Generating Facility will supply: Interconnection Customer __ Others __

Point of Interconnection:_____________________________________________

Interconnection Customer's requested in-service date:____________________

 

This Interconnection Request Form is considered complete when the Interconnection Customer provides all applicable and correct information required in this Schedule 6 and complies with the processing fee in Section 2 of this Schedule.

An Interconnection Customer who requests a commission jurisdictional interconnection must submit this Interconnection Request Form by hand delivery, mail, email, or fax to the utility.

 

Request for:

 

Level 2 Process ____

Level 3 Process ____

Standby Generator / Closed Transition ____

 

Section 2. Processing Fee and Deposit

If the interconnection request is submitted as Level 2, the nonrefundable processing fee payable to the utility is $1,000.

 

If the interconnection request is submitted as Level 3, the IC shall submit to the utility: a. The nonrefundable processing fee of $1,000. b. An interconnection request study deposit of $10,000 plus $1.00 per kWAC  , pursuant to 20VAC5-314-38. a nonrefundable processing fee of $1,000. Upon being designated by the Utility as a Project A or if the IC elects to proceed with the Project B, Level 3 Interconnection Customers shall also be obligated to submit an interconnection request study deposit of $10,000 plus $1.00 per kWAC.

 

An IC transferring from the Level 1 process shall pay the nonrefundable processing fee of $1,000 minus any previously paid Level 1 processing fee

 

An IC transferring from the Level 2 to the Level 3 process shall not be required to pay an additional $1,000 processing fee. ]

 

If the SGF is a standby generating facility, the interconnection requestshall be designated a Project A and the IC shall be obligated to submit an interconnection request ] study depositis of ] $5,000in conjunction with the initial study agreement as provided for in 20VAC5-314-38 and 20VAC5-314-70 ].

 

If the interconnection request is submitted solely due to a transfer of ownership or change of control of the SGF, the nonrefundable processing fee is $500.

 

Section 3. Small Generating Facility Information

Data apply only to the small generating facility, not the interconnection facilities.

 

SGF Location (if different from information listed in Section 1 of this Schedule):

 

Site Address: ____________________________________________________________

City, State, Zip: __________________________________________________________

Utility and Account Number: _________________________________________________

Energy Service Provider and Account Number: __________________________________

If not available prior to the completion of the Interconnection Request Form, the Interconnection Customer must provide an address for SGF that has been issued conforming to the 911 emergency response group for the area to the utility within 15 business days of issuance.

 

Primary energy source

 

Choose one:

Renewable

Nonrenewable

 Solar – Photovoltaic

 Solar – Thermal

 Biomass – Landfill Gas

 Biomass – Manure DigesterGas

 Biomass – Directed Biogas

 Biomass – Solid Waste

 Biomass – Sewage Digester Gas

 Biomass – Wood

 Biomass – Other (please specify)

 Hydro Power – Run of River

 Hydro Power – Storage

 HydroPower – Tidal

 Hydro Power – Wave

 Wind

 Geothermal

 Battery

 Other (please specify)

 Fossil Fuel – Diesel

 Fossil Fuel – Natural Gas (not waste)

 Fossil Fuel – Oil

 Fossil Fuel – Coal

 Fossil Fuel – Other (please specify)

 Other (please specify)

 

Prime mover

 

Choose one:

 Photovoltaic (PV)

 Fuel Cell

 Reciprocating Engine

 Gas Turbine

 Steam Turbine

 Micro-Turbine

 Other, including Combined Heat and Power (please specify)

 

Type of generator

Choose one:

 Inverter-Based Machine

 Induction

 Synchronous

 Other (please specify)

 

Additional comments

__________________________________________________________________________________________________________________________________________________________________________________________________________

 

Is the SGF located in utility's service area?

          Yes _____   No _____        If No, please provide name of local provider:______

 

Generator nameplate rating:________ kW ___ Generator nameplate kVAR:_______

 

Interconnection customer or customer-site load:__________kW

 

Typical reactive load:_________________

 

Maximum generating capacity requested:______________ kWAC

 

List components of the small generating facility equipment package that are currently certified:

 

Equipment                                             Certifying Entity

1.____________________________          1.____________________________

2.____________________________          2.____________________________

3.____________________________          3.____________________________

4.____________________________          4.____________________________

5.____________________________          5.____________________________

 

Is the prime mover compatible with the certified protective relay package?

Yes____No____

 

Generator (or solar collector)

Manufacturer, Model Name, and Number:_________________________________

Version Number:_________________________________________________

 

Nameplate Output Power Rating in kW: (Summer)_________ (Winter)______

Nameplate Output Power Rating in kVA: (Summer)________ (Winter)______

 

Individual Generator Power Factor

Rated Power Factor: Leading:_____________ Lagging:________________

 

Total number of generators in wind farm to be interconnected pursuant to this interconnection request: Elevation:_______ Single Phase___ Three Phase___

 

Inverter Manufacturer, Model Name, and Number:__________________________

 

List of adjustable set points for the protective equipment or software:_________

 

Note: A completed power systems load flow data sheet must be supplied with the interconnection request.

 

Small Generating Facility Characteristic Data (for inverter-based machines)

Max design fault contribution current:______ Instantaneous___ or RMS_______

Harmonics characteristics:__________________________________________

Start-up requirements:_____________________________________________

 

Small Generating Facility Characteristic Data (for rotating machines)

RPM Frequency:_______________________________________________

Neutral Grounding Resistor (if applicable):____________

Synchronous Generators:

 

Direct Axis Synchronous Reactance, Xd:_______ P.U.

Direct Axis Transient Reactance, Xd:___________ P.U.

Direct Axis Subtransient Reactance, Xd:______________ P.U.

Negative Sequence Reactance, X2:_________ P.U.

Zero Sequence Reactance, X0:____________ P.U.

KVA Base:___________________________

Field Volts:______________

Field Amperes:___________

 

Induction Generators:

Motoring Power (kW):______________

I2t or K (Heating Time Constant):______________

Rotor Resistance, Rr:______________

Stator Resistance, Rs:______________

Stator Reactance, Xs:______________

Rotor Reactance, Xr:______________

Magnetizing Reactance, Xm:_____________

Short Circuit Reactance, Xd:______________

Exciting Current:______________

Temperature Rise:______________

Frame Size:______________

Design Letter:______________

Reactive Power Required In Vars (No Load):______________

Reactive Power Required In Vars (Full Load):______________

Total Rotating Inertia, H:_____________ Per Unit on kVA base

 

Excitation and Governor System Data for Synchronous Generators Only:

Provide appropriate IEEE model block diagram of excitation system, governor system, and power system stabilizer (PSS) in accordance with the regional reliability council criteria. A PSS may be determined to be required by applicable studies. A copy of the manufacturer's block diagram may not be substituted.

 

Section 4. Customer's Interconnection Facilities Information

Will a transformer be used between the generator and the point of interconnection?

Yes ____No ____

Will the transformer be provided by the IC? Yes ____No ____

 

Transformer Data (If applicable, for IC-owned transformer):

Is the transformer: Single Phase_____ Three Phase____ Size: kVA_____

Transformer Impedance:_______% on __________kVA base

 

If Three Phase:

Transformer Primary:_____ Volts _____ Delta _____ Wye _____ Wye Grounded

Transformer Secondary:___ Volts _____ Delta _____ Wye _____ Wye Grounded

Transformer Tertiary:_____ Volts _____ Delta _____ Wye _____ Wye Grounded

 

Transformer Fuse Data (if applicable, for IC-owned fuse):

(Attach copy of fuse manufacturer's minimum melt and total clearing time-current curves.)

Manufacturer:____________ Type:__________ Size:______ Speed:_______

 

Interconnecting Circuit Breaker (if applicable):

Manufacturer:____________________________ Type:__________

Load Rating (amps):___ Interrupting Rating (amps):___ Trip Speed (cycles):___

Interconnection Protective Relays (if applicable):

 

If Microprocessor-Controlled:

Manufacturer:__________________________ Type:____________________

Model No. ___________ Firmware ID:_______ Instruction Book No. _________

List of functions and adjustable setpoints for the protective equipment or software:

 

Setpoint Function                                   Minimum                           Maximum

1.________________________________         ____________          __________

2.________________________________         ____________          __________

3.________________________________         ____________          __________

4.________________________________         ____________          __________

5.________________________________         ____________          __________

6.________________________________         ____________          __________

 

If Discrete Components:

(Enclose copy of any proposed time-overcurrent coordination curves.)

 

Manufacturer:___________ Type:_______ Style/Catalog No.:______ Proposed Setting:______

Manufacturer:___________ Type:_______ Style/Catalog No.:______ Proposed Setting:______

Manufacturer:___________ Type:_______ Style/Catalog No.:______ Proposed Setting:______

Manufacturer:___________ Type:_______ Style/Catalog No.:______ Proposed Setting:______

Manufacturer:___________ Type:_______ Style/Catalog No.:______ Proposed Setting:______

 

Current Transformer Data (if applicable):

(Enclose copy of manufacturer's excitation and ratio correction curves.)

Manufacturer:_________________________________________________

Type:_______ Accuracy Class:________ Proposed Ratio Connection:_____

Manufacturer:_________________________________________________

Type:_______ Accuracy Class:________ Proposed Ratio Connection:_____

 

Potential Transformer Data (if applicable):

Manufacturer:_________________________________________________

Type:________ Accuracy Class:_______ Proposed Ratio Connection:_____

Manufacturer:_________________________________________________

Type:________ Accuracy Class:_______ Proposed Ratio Connection:_____

 

Section 5. General Information

Enclose a copy of the site electrical one-line diagram showing the configuration of the small generating facility equipment, current and potential circuits, and protection and control schemes.

Enclose a copy of any site documentation that indicates the precise physical location of the proposed SGF (e.g., United States Geological Survey topographic map or other diagram or documentation).

Describe the proposed location of the protective interface equipment on the property:____________________________________________________

Enclose a copy of any site documentation that describes and details the operation of the protection and control schemes. Is available documentation enclosed? Yes___ No____

Enclose copies of schematic drawings for all protection and control circuits, relay current circuits, relay potential circuits, and alarm or monitoring circuits (if applicable).

Are schematic drawings enclosed? Yes____ No____

 

Section 6. Site Control

Enclose a copy of the site control documentation. Any information appearing in public records may not be labeled confidential. (Confidential information is discussed in 20VAC5-314-110.) Site control may be demonstrated through:

1. Ownership of, a leasehold interest in, or a right to develop a site for the purpose of constructing the SGF;

2. An option to purchase or acquire a leasehold interest in a site for such purpose;

3. An exclusive or other business relationship between the IC and the entity having the right to sell, lease, or grant the IC the right to possess or occupy a site for such purpose; or

4. An existing permanent service metered account with the utility at the site and in the name of the IC.

 

Section 7. Interconnection Customer Signature

I hereby certify that, to the best of my knowledge, all the information provided in this interconnection request is true and correct.

Signature:_____________________________ Date:________________

 

Section 8. Utility Acknowledgment of Receipt

Signed:_____________________________________

Title:_______________________________________

Utility:______________________________________

Date:______________________________________

Utility signature signifies only receipt of this form, in compliance with 20VAC5-314-50.

Schedule 7

LEVEL 3 FEASIBILITY STUDY AGREEMENT FOR SMALL GENERATING FACILITIES

 

This Agreement is made and entered into this _____day of ________20___ by and between_____________________________________________________________, a ____________________________organized and existing under the laws of the state of __________________________________________, ("Interconnection Customer,") and ____________________________________, a________________existing under the laws of the state of____________________________________, ("Utility"). Interconnection Customer and Utility each may be referred to as a "Party" or collectively as the "Parties."

RECITALS

WHEREAS, Interconnection Customer is proposing to develop an SGF or generating capacity addition to an existing SGF consistent with the interconnection request completed by Interconnection Customer on_________________________; and

WHEREAS, Interconnection Customer desires to interconnect the SGF with the Utility's system; and

WHEREAS, Interconnection Customer has requested the Utility to perform a feasibility study to assess the feasibility of interconnecting the proposed SGF with the Utility's system, and of any affected systems;

NOW, THEREFORE, in consideration of and subject to the mutual covenants contained in this Agreement the Parties agreed as follows:

1.0 The terms defined in Schedule 1 of 20VAC5-314-170 shall apply to this Schedule 7 of 20VAC 5-314-170.

2.0 The Interconnection Customer elects and the Utility shall cause to be performed an interconnection feasibility study consistent with the standard small generator interconnection procedures.

3.0 The scope of the feasibility study shall be subject to the assumptions set forth in Attachment A to this Agreement.

4.0 Feasibility study costs will be deducted from the interconnection request study deposit, as set forth in Schedule 6 of 20VAC5-314-170.

4.1 Study cost shall be the Utility's actual incremental costs and will be invoiced to the Interconnection Customer no later than 60 business days after the study is completed and delivered and will include a summary of professional time.Actual study costs may be reconciled during the final accounting process described in Article 6 of the Interconnection Agreement, as applicable. ]

4.2 The Interconnection Customer shall pay any study costs that exceed the deposit within 20 business days after receipt of the invoice or resolution of any dispute. If the deposit exceeds the invoiced fees, the Utility shall refund the excess within 20 business days of the invoice without interest unless additional studies are required.

5.0 The feasibility study shall be based on the technical information provided by the Interconnection Customer in the interconnection request, as may be modified as the result of the scoping meeting. The Utility reserves the right to request additional technical information from the Interconnection Customer as may reasonably become necessary consistent with Good Utility Practice during the course of the feasibility study and as designated in accordance with the standard small generator interconnection procedures. If the information requested by the Utility is not provided by the Interconnection Customer within a reasonable timeframe to be identified by the Utility in writing, the Utility shall provide the Interconnection Customer written notice providing an opportunity to cure such failure by the close of business on the 10th business day following the posted date of such notice, where failure to provide the information requested within this period shall result in the study being terminated and the interconnection request being deemed withdrawn. The period of time for the Utility to complete the feasibility study shall be tolled during any period that the Utility has requested information in writing from the Interconnection Customer necessary to complete the study and such request is outstanding.

6.0 In performing the study, the Utility shall rely, to the extent reasonably practicable, on recent studies. The Interconnection Customer shall not be charged for such existing studies; however, the Interconnection Customer shall be responsible for charges associated with any new study or modifications to existing studies that are reasonably necessary to perform the feasibility study.

7.0 The feasibility study report shall provide the following analyses for the purpose of identifying any potential adverse system impacts that would result from the interconnection of the SGF as proposed:

7.1 Initial identification of any circuit breaker short circuit capability limits exceeded as a result of the interconnection;

7.2 Initial identification of any thermal overload or voltage limit violations resulting from the interconnection;

7.3 Initial review of grounding requirements and electric system protection; and

7.4 Description and nonbinding estimated cost of facilities required to interconnect the proposed SGF and to address the identified short circuit and power flow issues.

8.0 The feasibility study shall model the impact of the SGF for all purposes identified in the Interconnection Request Form in order to avoid the further expense and interruption of operation for reexamination of feasibility and impacts if the Interconnection Customer later changes the purpose for which the SGF is being installed.

9.0 The study shall include the feasibility of all potential points of interconnection as requested by the Interconnection Customer and at the Interconnection Customer's cost.

10.0 A feasibility study report shall be prepared and transmitted to the Interconnection Customer within 30 business days of the Utility's receipt of the complete executed feasibility study agreement and required deposit.

11.0 If the feasibility study shows no potential for adverse system impacts, then within 10 business days, the Utility shall send the Interconnection Customer either an executable Small Generator Interconnection Agreement (Schedule 10 of 20VAC5-314-170) or a Facilities Study Agreement, including an outline of the scope of the study.

12.0 If the feasibility study shows potential for adverse system impacts, the review process shall proceed to the system impact study.

13.0 Governing law, regulatory authority, and rules. The validity, interpretation, and enforcement of this Agreement and each of its provisions shall be governed by the laws of the Commonwealth of Virginia, without regard to its conflicts of law principles. This Agreement is subject to all applicable laws and regulations. Each Party expressly reserves the right to seek changes in, appeal, or otherwise contest any laws, orders, or regulations of a governmental authority.

14.0 Amendment. The Parties may amend this Agreement by a written instrument duly executed by both Parties.

15.0 No third-party beneficiaries. This Agreement is not intended to and does not create rights, remedies, or benefits of any character whatsoever in favor of any persons, corporations, associations, or entities other than the Parties, and the obligations in this Agreement assumed are solely for the use and benefit of the Parties, their successors in interest and where permitted, their assigns.

16.0 Waiver.

16.1 The failure of a Party to this Agreement to insist, on any occasion, upon strict performance of any provision of this Agreement will not be considered a waiver of any obligation, right, or duty of or duty imposed upon such Party.

16.2 Any waiver at any time by either Party of its rights with respect to this Agreement shall not be deemed a continuing waiver or a waiver with respect to any other failure to comply with any other obligation, right, or duty of this Agreement. Termination or default of this Agreement for any reason by an Interconnection Customer shall not constitute a waiver of the Interconnection Customer's legal rights to obtain an interconnection from the Utility. Any waiver of this Agreement shall, if requested, be provided in writing.

17.0 Entire agreement. This Agreement, including all attachments, constitutes the entire agreement between the Parties with reference to the subject matter hereof and supersedes all prior and contemporaneous understandings or agreements, oral or written, between the Parties with respect to the subject matter of this Agreement. There are no other agreements, representations, warranties, or covenants that constitute any part of the consideration for, or any condition to, either Party's compliance with its obligations under this Agreement.

18.0 Multiple counterparts. This Agreement may be executed in two or more counterparts, each of which is deemed an original but all constitute one and the same instrument.

19.0 No partnership. This Agreement shall not be interpreted or construed to create an association, joint venture, agency relationship, or partnership between the Parties or to impose any partnership obligation or partnership liability upon either Party. Neither Party shall have any right, power, or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.

20.0 Severability. If any provision or portion of this Agreement shall for any reason be held or adjudged to be invalid or illegal or unenforceable by any court of competent jurisdiction or other governmental authority, (i) such portion or provision shall be deemed separate and independent, (ii) the Parties shall negotiate in good faith to restore insofar as practicable the benefits to each Party that were affected by such ruling, and (iii) the remainder of this Agreement shall remain in full force and effect.

21.0 Subcontractors. Nothing in this Agreement shall prevent a Party from utilizing the services of any subcontractor as it deems appropriate to perform its obligations under this Agreement; however, each Party shall require its subcontractors to comply with all applicable terms and conditions of this Agreement in providing such services and each Party shall remain primarily liable to the other Party for the performance of such subcontractor.

21.1 The creation of any subcontract relationship shall not relieve the hiring Party of any of its obligations under this Agreement. The hiring Party shall be fully responsible to the other Party for the acts or omissions of any subcontractor the hiring Party hires as if no subcontract had been made; provided that in no event shall the Utility be liable for the actions or inactions of the Interconnection Customer or its subcontractors with respect to obligations of the Interconnection Customer under this Agreement. Any applicable obligation imposed by this Agreement upon the hiring Party shall be equally binding upon and shall be construed as having application to any subcontractor of such Party.

21.2 The obligations under this Section 21.0 of this Agreement will not be limited in any way by any limitation of subcontractor's insurance.

22.0 Reservation of rights. The Utility shall have the right to make a unilateral filing with the State Corporation Commission to modify this Agreement with respect to any rates, terms, and conditions, charges, or classifications of service, and the Interconnection Customer shall have the right to make a unilateral filing with the State Corporation Commission to modify this Agreement; provided that each Party shall have the right to protest any such filing by the other Party and to participate fully in any proceeding before the State Corporation Commission in which such modifications may be considered. Nothing in this Agreement shall limit the rights of the Parties except to the extent that the Parties otherwise agree as provided in this Agreement.

IN WITNESS WHEREOF, the Parties have caused this Agreement to be duly executed by their duly authorized officers or agents on the day and year of this Agreement.

 

(Insert name of Utility)                             (Insert name of Interconnection Customer)

________________________________          ________________________________

 

Signed: _________________________           Signed:__________________________

 

Name (Printed):                                      Name (Printed):

________________________________                                         _________________

 

Title: ___________________________  Title: ____________________________

 

Attachment A to Schedule 7

Feasibility Study Agreement

Assumptions Used in Conducting the Feasibility Study

The feasibility study will be based upon the information set forth in the interconnection request and agreed upon in the scoping meeting held on _____________________:

1. Designation of point of interconnection and configuration to be studied.

 

 

2. Designation of alternative points of interconnection and configuration.

 

 Questions 1 and 2 are to be completed by the Interconnection Customer. Any other assumptions are to be provided by the Interconnection Customer and the Utility.

_____________________________________________________________

_____________________________________________________________

 

Schedule 8

LEVEL 3 SYSTEM IMPACT STUDY AGREEMENT FOR SMALL GENERATING FACILITIES

 

This Agreement is made and entered into this _____day of___________________20_______by and between______________________ ____________________________________________________________________, a ___________________________ organized and existing under the laws of the state of__________________________________________, ("Interconnection Customer,") and__________________________________________, a_________________existing under the laws of the state of________, ("Utility"). Interconnection Customer and Utility each may be referred to as a "Party," or collectively as the "Parties."

RECITALS

WHEREAS, the Interconnection Customer is proposing to develop an SGF or generating capacity addition to an existing SGF consistent with the interconnection request completed by the Interconnection Customer on______________________; and

WHEREAS, the Interconnection Customer desires to interconnect the SGF with the Utility's system; and

WHEREAS, the Utility has completed a feasibility study and provided the results of said study to the Interconnection Customer (This recital to be omitted if the Parties have agreed to forgo the feasibility study.); and

WHEREAS, the Interconnection Customer has requested the Utility to perform a system impact study to assess the impact of interconnecting the SGF with the Utility's system, and of any affected systems;

NOW, THEREFORE, in consideration of and subject to the mutual covenants contained in this Agreement the Parties agreed as follows:

1.0 The terms defined in Schedule 1 of 20VAC5-314-170 shall apply to this Schedule 8 of 20VAC 5-314-170.

2.0 The Interconnection Customer elects and the Utility shall cause to be performed a system impact study consistent with the standard small generator interconnection procedures.

3.0 System impact study costs will be deducted from the interconnection request study deposit as set forth in Schedule 6 of 20VAC5-314-170.

3.1 Study cost shall be the Utility's actual incremental costs and will be invoiced to the Interconnection Customer no later than 60 business days after the study is completed and delivered and will include a summary of professional time.Actual study costs may be reconciled during the final accounting process described in Article 6 of the Interconnection Agreement, as applicable. ]

3.2 The Interconnection Customer shall pay any study costs that exceed the deposit within 20 business days after receipt of the invoice or resolution of any dispute. If the deposit exceeds the invoiced fees, the Utility shall refund the excess within 20 business days of the invoice without interest unless additional studies are required.

4.0 A system impact study shall identify and detail the electric system impacts that would result if the SGF were interconnected without project modifications or electric system modifications, focusing on the adverse electric system impacts identified in the feasibility study or in the scoping meeting. A system impact study shall evaluate the impact of the proposed interconnection on the reliability of the electric system.

5.0 A system impact study will be based upon the results of the feasibility study and the technical information provided by Interconnection Customer in the interconnection request. The Utility reserves the right to request additional technical information from the Interconnection Customer as may reasonably become necessary consistent with Good Utility Practice during the course of the system impact study. If the information requested by the Utility is not provided by the Interconnection Customer within a reasonable timeframe to be identified by the Utility in writing, the Utility shall provide the Interconnection Customer written notice providing an opportunity to cure such failure by the close of business on the 10th business day following the posted date of such notice, where failure to provide the information requested within this period shall result in the study being terminated, and the interconnection request being deemed withdrawn. The period of time for the Utility to complete the system impact study shall be tolled during any period that the Utility has requested information in writing from the Interconnection Customer necessary to complete the study and such request is outstanding.

6.0 A system impact study shall consist of a study of the potentially impacted transmission and distribution systems, a short circuit analysis, a stability analysis, a power flow analysis, voltage drop and flicker studies, grounding reviews, distribution load flow study, analysis of equipment interrupting ratings, protection coordination study, and impacts on electric system operation, as necessary. A system impact study shall state the assumptions upon which it is based, state the results of the analyses, and provide the requirement or potential impediments to providing the requested interconnection service, including a preliminary indication of the cost and length of time that would be necessary to correct any problems identified in those analyses and implement the interconnection. A system impact study shall provide a list of facilities and modifications that would be required as a result of the interconnection along with estimates of cost responsibility and time to construct. If arranged with the Utility prior to the Utility preparing the system impact study agreement, the system impact study may, at the Interconnection Customer's cost, include one or more alternatives to the point of interconnection; however, such alternative points must be on the same distribution circuit as the point of interconnection the Interconnection Customer specified as the proposed point of interconnection.

7.0 Affected systems may participate in the preparation of a system impact study, with a division of costs among such entities as they may agree. All affected systems shall be afforded an opportunity to review and comment upon a system impact study that covers potential adverse system impacts on their electric systems, and the Utility has 20 additional business days to complete a system impact study requiring review by affected systems.

8.0 If the Utility uses a queuing procedure for sorting or prioritizing projects and associated cost responsibilities for any required network upgrades, the system impact study shall consider all generating facilities (and with respect to Section 8.3 of this Agreement, any identified upgrades associated with such higher queued interconnection) that, on the date the system impact study is commenced:

8.1 Are directly interconnected with the Utility's system; or

8.2 Are interconnected with affected systems and may have an impact on the proposed interconnection; and

8.3 Have a pending higher queued interconnection request to interconnect with the Utility's system.

9.0 A system impact study, if required, shall be completed and the results transmitted to the Interconnection Customer within 45 business days after this Agreement is signed by the Parties or in accordance with the Utility's queuing procedures.

10.0 If the system impact study shows that facility modifications are needed to accommodate the SGF, then within 10 business days following transmittal of the system impact study report, the Utility shall send the Interconnection Customer a Facilities Study Agreement, including an outline of the scope of the study.

11.0 Governing law, regulatory authority, and rules. The validity, interpretation, and enforcement of this Agreement and each of its provisions shall be governed by the laws of the Commonwealth of Virginia, without regard to its conflicts of law principles. This Agreement is subject to all applicable laws and regulations. Each Party expressly reserves the right to seek changes in, appeal, or otherwise contest any laws, orders, or regulations of a governmental authority.

12.0 Amendment. The Parties may amend this Agreement by a written instrument duly executed by both Parties.

13.0 No third-party beneficiaries. This Agreement is not intended to and does not create rights, remedies, or benefits of any character whatsoever in favor of any persons, corporations, associations, or entities other than the Parties, and the obligations pursuant to this Agreement assumed are solely for the use and benefit of the Parties, their successors in interest, and where permitted, their assigns.

14.0 Waiver.

14.1 The failure of a Party to this Agreement to insist, on any occasion, upon strict performance of any provision of this Agreement will not be considered a waiver of any obligation, right, or duty of or duty imposed upon such Party.

14.2 Any waiver at any time by either Party of its rights with respect to this Agreement shall not be deemed a continuing waiver or a waiver with respect to any other failure to comply with any other obligation, right, or duty of this Agreement. Termination or default of this Agreement for any reason by Interconnection Customer shall not constitute a waiver of the Interconnection Customer's legal rights to obtain an interconnection from the Utility. Any waiver of this Agreement shall if requested, be provided in writing.

15.0 Entire agreement. This Agreement, including all attachments, constitutes the entire agreement between the Parties with reference to the subject matter hereof and supersedes all prior and contemporaneous understandings or agreements, oral or written, between the Parties with respect to the subject matter of this Agreement. There are no other agreements, representations, warranties, or covenants that constitute any part of the consideration for, or any condition to, either Party's compliance with its obligations under this Agreement.

16.0 Multiple counterparts. This Agreement may be executed in two or more counterparts, each of which is deemed an original but all constitute one and the same instrument.

17.0 No partnership. This Agreement shall not be interpreted or construed to create an association, joint venture, agency relationship, or partnership between the Parties or to impose any partnership obligation or partnership liability upon either Party. Neither Party shall have any right, power, or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.

18.0 Severability. If any provision or portion of this Agreement shall for any reason be held or adjudged to be invalid or illegal or unenforceable by any court of competent jurisdiction or other governmental authority, (i) such portion or provision shall be deemed separate and independent, (ii) the Parties shall negotiate in good faith to restore insofar as practicable the benefits to each Party that were affected by such ruling, and (iii) the remainder of this Agreement shall remain in full force and effect.

19.0 Subcontractors. Nothing in this Agreement shall prevent a Party from utilizing the services of any subcontractor as it deems appropriate to perform its obligations under this Agreement; however, each Party shall require its subcontractors to comply with all applicable terms and conditions of this Agreement in providing such services, and each Party shall remain primarily liable to the other Party for the performance of such subcontractor.

19.1 The creation of any subcontract relationship shall not relieve the hiring Party of any of its obligations under this Agreement. The hiring Party shall be fully responsible to the other Party for the acts or omissions of any subcontractor the hiring Party hires as if no subcontract had been made; provided that in no event shall the Utility be liable for the actions or inactions of the Interconnection Customer or its subcontractors with respect to obligations of the Interconnection Customer under this Agreement. Any applicable obligation imposed by this Agreement upon the hiring Party shall be equally binding upon and shall be construed as having application to any subcontractor of such Party.

19.2 The obligations under this Section 19.0 of this Agreement will not be limited in any way by any limitation of subcontractor's insurance.

20.0 Reservation of rights. The Utility shall have the right to make a unilateral filing with the State Corporation Commission to modify this Agreement with respect to any rates, terms and conditions, charges, or classifications of service, and the Interconnection Customer shall have the right to make a unilateral filing with the State Corporation Commission to modify this Agreement; provided that each Party shall have the right to protest any such filing by the other Party and to participate fully in any proceeding before the State Corporation Commission in which such modifications may be considered. Nothing in this Agreement shall limit the rights of the Parties except to the extent that the Parties otherwise agree as provided in this Agreement.

IN WITNESS THEREOF, the Parties have caused this Agreement to be duly executed by their duly authorized officers or agents on the day and year of this Agreement.

 

(Insert name of Utility)                             (Insert name of Interconnection Customer)

___________________________________________________________________

 

Signed: _________________________  Signed: ____________________________

 

Name (Printed):                                      Name (Printed):

__________________________________          ______________________________

 

Title: ______________________________       Title: __________________________

Schedule 9

LEVEL 3 FACILITIES STUDY AGREEMENT FOR SMALL GENERATING FACILITIES

 

This Agreement is made and entered into this _____day of______________20___ by and between________________________________________________________, a ____________________________organized and existing under the laws of the state of____________________________________________, ("Interconnection Customer,") and________________________________________________________________, a__________________existing under the laws of the state of____________________________________________________________, ("Utility"). Interconnection Customer and Utility each may be referred to as a "Party," or collectively as the "Parties."

RECITALS

WHEREAS, the Interconnection Customer is proposing to develop an SGF or generating capacity addition to an existing SGF consistent with the interconnection request completed by the Interconnection Customer on______________________; and

WHEREAS, the Interconnection Customer desires to interconnect the SGF with the Utility's system; and

WHEREAS, the Utility has completed a system impact study and provided the results of the study to the Interconnection Customer; and

WHEREAS, the Interconnection Customer has requested the Utility to perform a facilities study to specify and estimate the cost of the equipment, engineering, procurement, and construction work needed to implement the conclusions of the system impact study in accordance with Good Utility Practice to physically and electrically connect the SGF with the Utility's system.

NOW, THEREFORE, in consideration of and subject to the mutual covenants contained in this Agreement the Parties agreed as follows:

1.0 The terms defined in Schedule 1 of 20VAC5-314-170 shall apply to this Schedule 9 of 20VAC 5-314-170.

2.0 The Interconnection Customer elects and the Utility shall cause a facilities study consistent with the standard small generator interconnection procedures.

3.0 The scope of the facilities study shall be subject to data provided in Attachment A to this Agreement.

4.0 The facilities study shall specify and estimate the cost of the equipment, engineering, procurement, and construction work needed to implement the conclusions of the feasibility study or system impact study and to allow the SGF to be interconnected and operate safely and reliably.

5.0 Facilities study costs will be deducted from the interconnection request study deposit, as set forth in Schedule 6 of 20VAC5-314-170.

5.1 Study cost shall be the Utility's actual incremental costs and will be invoiced to the Interconnection Customer no later than 60 business days after the study is completed and delivered and will include a summary of professional time.Actual study costs may be reconciled during the final accounting process described in Article 6 of the Interconnection Agreement, as applicable. ]

5.2 The Interconnection Customer shall pay any study costs that exceed the deposit within 20 business days on receipt of the invoice or resolution of any dispute. If the deposit exceeds the invoiced fees, the Utility shall refund the excess within 20 business days of the invoice without interest.

6.0 Design for any required customer's interconnection facilities, attachment facilities, or distribution upgrades shall be performed under the facilities study. The Utility may contract with consultants to perform activities required under the facilities study. The Interconnection Customer and the Utility may agree to allow the Interconnection Customer to separately arrange for the design of some of the customer's interconnection facilities. In such cases, facilities design will be reviewed or modified prior to acceptance by the Utility, under the provisions of the facilities study. If the Parties agree to separately arrange for design and construction, and provided security and confidentiality requirements can be met, the Utility shall make sufficient information available to the Interconnection Customer in accordance with confidentiality and critical infrastructure requirements, to permit the Interconnection Customer to obtain an independent design and cost estimate for any necessary facilities.

7.0 The facilities study shall also identify (i) the electrical switching configuration of the equipment, including transformer, switchgear, meters, and other station equipment; (ii) the nature and estimated cost of the attachment facilities and distribution upgrades necessary to accomplish the interconnection; and (iii) an estimate of the time required to complete the construction and installation of such facilities.

8.0 The Utility may propose to group facilities required for more than one Interconnection Customer in order to minimize facilities costs through economies of scale, but any Interconnection Customer may require the installation of facilities required for its own SGF if it is willing to pay the costs of those facilities.

9.0 In cases where system upgrades are required, the Utility shall transmit the facilities study report within 45 business days after receipt of the complete Facilities Study Agreement and the deposit. In cases where no system upgrades are necessary, and the required facilities are limited to customer's interconnection facilities and attachment facilities only, the Utility shall transmit the facilities study report within 30 business days after receipt of this Agreement and the deposit. The Utility reserves the right to request additional technical information from the Interconnection Customer as may reasonably become necessary consistent with Good Utility Practice during the course of the facilities study. If the information requested by the Utility is not provided by the Interconnection Customer within a reasonable timeframe to be identified by the Utility in writing, the Utility shall provide the Interconnection Customer written notice providing an opportunity to cure such failure by the close of business on the 10th business day following the posted date of such notice, where failure to provide the information requested within this period shall result in the study being terminated, and the interconnection request being deemed withdrawn. The period of time for the Utility to complete the facilities study shall be tolled during any period that the Utility has requested information in writing from the Interconnection Customer necessary to complete the study and such request is outstanding.

10.0 Governing law, regulatory authority, and rules. The validity, interpretation, and enforcement of this Agreement and each of its provisions shall be governed by the laws of the Commonwealth of Virginia, without regard to its conflicts of law principles. This Agreement is subject to all applicable laws and regulations. Each Party expressly reserves the right to seek changes in, appeal, or otherwise contest any laws, orders, or regulations of a governmental authority.

11.0 Amendment. The Parties may amend this Agreement by a written instrument duly executed by both Parties.

12.0 No third-party beneficiaries. This Agreement is not intended to and does not create rights, remedies, or benefits of any character whatsoever in favor of any persons, corporations, associations, or entities other than the Parties, and the obligations assumed in this Agreement are solely for the use and benefit of the Parties, their successors in interest and where permitted, their assigns.

13.0 Waiver.

13.1 The failure of a Party to this Agreement to insist, on any occasion, upon strict performance of any provision of this Agreement will not be considered a waiver of any obligation, right, or duty of or duty imposed upon such Party.

13.2 Any waiver at any time by either Party of its rights with respect to this Agreement shall not be deemed a continuing waiver or a waiver with respect to any other failure to comply with any other obligation, right, or duty of this Agreement. Termination or default of this Agreement for any reason by the Interconnection Customer shall not constitute a waiver of the Interconnection Customer's legal rights to obtain an interconnection from the Utility. Any waiver of this Agreement shall, if requested, be provided in writing.

14.0 Entire agreement. This Agreement, including all attachments, constitutes the entire agreement between the Parties with reference to the subject matter hereof and supersedes all prior and contemporaneous understandings or agreements, oral or written, between the Parties with respect to the subject matter of this Agreement. There are no other agreements, representations, warranties, or covenants that constitute any part of the consideration for, or any condition to, either Party's compliance with its obligations under this Agreement.

15.0 Multiple counterparts. This Agreement may be executed in two or more counterparts, each of which is deemed an original but all constitute one and the same instrument.

16.0 No partnership. This Agreement shall not be interpreted or construed to create an association, joint venture, agency relationship, or partnership between the Parties or to impose any partnership obligation or partnership liability upon either Party. Neither Party shall have any right, power, or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.

17.0 Severability. If any provision or portion of this Agreement shall for any reason be held or adjudged to be invalid or illegal or unenforceable by any court of competent jurisdiction or other governmental authority, (i) such portion or provision shall be deemed separate and independent, (ii) the Parties shall negotiate in good faith to restore insofar as practicable the benefits to each Party that were affected by such ruling, and (iii) the remainder of this Agreement shall remain in full force and effect.

18.0 Subcontractors. Nothing in this Agreement shall prevent a Party from utilizing the services of any subcontractor as it deems appropriate to perform its obligations under this Agreement; however, each Party shall require its subcontractors to comply with all applicable terms and conditions of this Agreement in providing such services, and each Party shall remain primarily liable to the other Party for the performance of such subcontractor.

18.1 The creation of any subcontract relationship shall not relieve the hiring Party of any of its obligations under this Agreement. The hiring Party shall be fully responsible to the other Party for the acts or omissions of any subcontractor the hiring Party hires as if no subcontract had been made; provided that in no event shall the Utility be liable for the actions or inactions of the Interconnection Customer or its subcontractors with respect to obligations of the Interconnection Customer under this Agreement. Any applicable obligation imposed by this Agreement upon the hiring Party shall be equally binding upon and shall be construed as having application to any subcontractor of such Party.

18.2 The obligations under this Section 18.0 of this Agreement will not be limited in any way by any limitation of subcontractor's insurance.

19.0 Reservation of rights. The Utility shall have the right to make a unilateral filing with the State Corporation Commission to modify this Agreement with respect to any rates, terms and conditions, charges, or classifications of service, and the Interconnection Customer shall have the right to make a unilateral filing with the State Corporation Commission to modify this Agreement; provided that each Party shall have the right to protest any such filing by the other Party and to participate fully in any proceeding before the State Corporation Commission in which such modifications may be considered. Nothing in this Agreement shall limit the rights of the Parties except to the extent that the Parties otherwise agree as provided in this Agreement.

IN WITNESS WHEREOF, the Parties have caused this Agreement to be duly executed by their duly authorized officers or agents on the day and year of this Agreement.

(Insert name of Utility)                             (Insert name of Interconnection Customer)

___________________________________  _________________________________

 

Signed______________________________  Signed___________________________

 

Name (Printed):                                                Name (Printed):____________________

___________________________________          ______________________________

Title_______________________________          Title___________________________

 

Attachment A to Schedule 9

Facilities Study Agreement

Data to Be Provided by the Interconnection Customer

with the Facilities Study Agreement

 

1. Provide a location plan and simplified one-line diagram of the plant and station facilities. For staged projects, indicate future generation, future transmission circuits, and other major future facilities. On the one-line diagram, show (i) each generator, its electric connection configuration, and its generation capacity; (ii) the location and capacity of auxiliary power; and (iii) minimum load on CT/PT.

 

2. One set of metering is required for each generation connection to the new ring bus or existing Utility station. Indicate the number of generation connections requiring a metering set:_______

 

3. Indicate whether an alternate source of auxiliary power will be available during CT/PT maintenance.
Yes_______ No_______

 

4. Indicate whether a transfer bus on the generation side of the metering will require that each meter set be designed for the total plant generation. Indicate such on the one-line diagram.

 

5. State the type of control system or programmable logic controller (PLC) that will be located at the SGF.

__________________________________________________________________________________________________________________________________________

 

6. State the protocol used by the control system or PLC. __________________________________________________________________________________________________________________________________________

 

7. Describe the operation sequence and timing of the protection scheme during disconnection and reconnection to the Utility by the SGF.

__________________________________________________________________________________________________________________________________________

 

8. Provide a 7.5-minute quadrangle map of the site. Indicate the plant, station, transmission line, and property lines.

 

9. State the physical dimensions of the proposed interconnection station.

__________________________________________________________________________________________________________________________________________

 

10. State the bus length from generation to interconnection station.

__________________________________________________________________________________________________________________________________________

 

11. Provide a diagram or description of the point of interconnection desired by the Interconnection Customer that is to be the point of interconnection in the system impact study report.

__________________________________________________________________________________________________________________________________________

 

12. State the line length from interconnection station to Utility system.

__________________________________________________________________________________________________________________________________________

 

13. State the pole or tower number observed in the field affixed to the pole or tower leg. ______________________________________________________________

 

14. State the number of third-party easements required for distribution or transmission lines.

__________________________________________________________________________________________________________________________________________

 

15. Provide the following proposed schedule dates:

a. Date Interconnection Customer to begin construction: ___________________

b. Date generator step-up transformers to receive back feed power: __________________

c. Date Interconnection Customer will test SGF: ______________________

d. Date Interconnection Customer will place SGF into commercial operation: ______________________

Schedule 10

 

SMALL GENERATOR INTERCONNECTION AGREEMENT (SGIA)

This Small Generator Interconnection Agreement ("Agreement") is made and entered into this ______ day of ____________, 20__, by __________________ ("Utility"), and _________________________________ ("Interconnection Customer" or "IC"), each sometimes referred to individually as "Party" or both referred to collectively as the "Parties."

 

Utility Information

Utility:________________________________________________

Attention:______________________________________________

Address:______________________________________________

City, State, Zip:_________________________________________

Phone:_____________________ Fax:_______________________

Interconnection Customer Information

Interconnection Customer:_________________________________

Attention:_______________________________________________

Site Address:____________________________________________

City, State, Zip:__________________________________________

Phone:_______________________ Fax:______________________

Interconnection Customer Application No:______________________

 

If not available prior to the completion of the Agreement, the Interconnection Customer must provide an address for the small generating facility ("small generating facility" or "SGF") that has been issued conforming to the 911 emergency response group for the area to the Utility within 15 business days of issuance.

 

In consideration of the mutual covenants set forth in this Agreement, the Parties agree as follows:

Article 1. Scope and Limitations of Agreement

1.1 This Agreement shall be used for all interconnection requests for generators in excess of 500 kW submitted pursuant to the Regulations Governing Interconnection of Small Electrical Generators (20VAC5-314).

1.2 This Agreement governs the terms and conditions under which the Interconnection Customer's small generating facility will interconnect with and operate in parallel with the Utility system.

1.3 This Agreement does not constitute an agreement to purchase or deliver the IC's power. The purchase or delivery of power and other services, including station service or backup power, that the IC may require will be covered under separate agreements, possibly with other parties. The IC will be responsible for separately making all necessary arrangements (including scheduling) for delivery of electricity with the applicable Utility and provider of transmission service.

1.4 Nothing in this Agreement is intended to affect any other agreement between the Utility and the IC.

1.5 Responsibilities of the Parties.

1.5.1 The Parties shall perform all obligations of this Agreement in accordance with all applicable laws and regulations, operating requirements, and Good Utility Practice.

1.5.2 The IC shall construct, interconnect, operate, and maintain its SGF and construct, operate, and maintain its customer's interconnection facilities in accordance with the applicable manufacturer's recommended maintenance schedule, all applicable operating requirements, and in accordance with this Agreement and with Good Utility Practice.

1.5.3 The Utility shall construct, operate, and maintain its distribution and transmission system and attachment facilities in accordance with this Agreement and with Good Utility Practice.

1.5.4 The IC agrees to construct its facilities in accordance with applicable specifications that meet or exceed those provided by the National Electrical Safety Code, American National Standards Institute, Institute of Electrical and Electronics Engineers (IEEE), Underwriter's Laboratory, and operating requirements in effect at the time of construction and other applicable national and state codes and standards. The IC agrees to design, install, maintain, and operate its SGF so as to reasonably minimize the likelihood of a disturbance adversely affecting or impairing the system or equipment of the Utility or affected systems and to otherwise maintain and operate its SGF in accordance with the specifications and certifications under which the SGF was initially installed and interconnected.

1.5.5 Each Party shall operate, maintain, repair, and inspect and shall be fully responsible for the facilities that it now or subsequently may own unless otherwise specified in the Attachments to this Agreement. Each Party shall be responsible for the safe installation, maintenance, repair, and condition of their respective lines and appurtenances on their respective sides of the point of change of ownership. The Utility and the IC, as appropriate, shall provide attachment facilities and customer's interconnection facilities that adequately protect the Utility's personnel and other persons from damage and injury. The allocation of responsibility for the design, installation, operation, maintenance, and ownership of attachment facilities and Interconnection Customer's interconnection facilities shall be delineated in the Attachments to this Agreement. The design, installation, operation, and maintenance of such facilities shall be the responsibility of the owner except as otherwise provided for in this Agreement.

1.5.6 The Utility shall coordinate with all affected systems to support the interconnection.

1.5.7 The IC shall ensure "frequency ride through" capability and "voltage ride through" capability of its SGF. At the discretion of the Utility, the IC shall enable these capabilities such that its SGF shall not disconnect automatically or instantaneously from the system or equipment of the Utility and any affected systems for a defined under-frequency or over-frequency condition or for an under-voltage or over-voltage condition. The defined conditions shall be in accordance with Good Utility Practice and consistent with any standards and guidelines that are applied to other generating facilities in the balancing authority area on a comparable basis. The SGF's protective equipment settings shall comply with the Utility's automatic load-shed program. The Utility shall review the protective equipment settings to confirm compliance with the automatic load-shed program. The term "ride through" as used in this Agreement shall mean the ability of an SGF to stay connected to and synchronized with the system or equipment of the Utility and any affected systems during system disturbances within a range of conditions, in accordance with Good Utility Practice and consistent with any standards and guidelines that are applied to other generating facilities in the balancing authority on a comparable basis. The term "frequency ride through" as used in this Agreement shall mean the ability of an SGF to stay connected to and synchronized with the system or equipment of the Utility and any affected systems during system disturbances within a range of under-frequency and over-frequency conditions, in accordance with Good Utility Practice and consistent with any standards and guidelines that are applied to other generating facilities in the balancing authority area on a comparable basis. The term "voltage ride through" as used in this Agreement shall mean the ability of an SGF to stay connected to and synchronized with the system or equipment of the Utility and any affected systems during system disturbances within a range of under-voltage and over-voltage conditions, in accordance with Good Utility Practice and consistent with any standards and guidelines that are applied to other generating facilities in the balancing authority area on a comparable basis.

1.5.8 The IC shall not operate the SGF in such a way that the SGF would exceed the maximum generating capacity.

1.6 Parallel operation obligations. Once the SGF has been authorized to commence parallel operation, the IC shall abide by all rules and procedures pertaining to the parallel operation of the SGF in the applicable control area, including (i) any rules and procedures concerning the operation of generation set forth in commission-approved tariffs or by the applicable system operator for the Utility's system and (ii) the operating requirements set forth in Attachment 5 of this Agreement.

1.7 Metering. The IC shall be responsible for the Utility's reasonable and necessary cost for the purchase, installation, operation, maintenance, testing, repair, and replacement of metering and data acquisition equipment specified in Attachments 2 and 3 of this Agreement. The IC's metering (and data acquisition, as required) equipment and reporting shall conform to applicable industry rules and operating requirements.

1.8 Reactive power.

1.8.1 The IC shall design its SGF to maintain a composite power delivery at continuous rated power output at the point of interconnection at a power factor within the range of 0.95 leading to 0.95 lagging, unless mutually agreed upon or the Utility has established different requirements that apply to all similarly situated generators in the control area on a comparable basis. The requirements of this article shall not apply to wind generators.

1.8.2 The Utility is required to pay the IC for reactive power that the IC provides or absorbs from the SGF when the Utility requests the IC to operate its SGF outside the range specified in Section 1.8.1 of this Agreement, unless mutually agreed upon by the Parties. In addition, if the Utility pays its own or affiliated generators for reactive power service within the specified range, it must similarly pay the IC.

1.8.3 Payments shall be in accordance with the IC's applicable rate schedule as may be in effect and accepted by the appropriate government authority. To the extent that no rate schedule is in effect at the time the IC is required to provide or absorb reactive power under this Agreement, the IC may expeditiously file such rate schedule with the appropriate government authority, and the Utility agrees to support any request for waiver of any prior notice requirement of such authority in order to permit compensation to the IC from the time service commenced.

1.9 Terms used in this Agreement shall have the meanings specified in the definitions in Attachment 1 of this Agreement.

Article 2. Inspection, Testing, Authorization, and Right of Access

2.1 Equipment testing and inspection.

2.1.1 The IC shall test and inspect its SGF and interconnection facilities prior to interconnection. The IC shall notify the Utility of such activities no fewer than 10 business days (or as may be agreed to by the Parties) prior to such testing and inspection. Testing and inspection shall occur on a business day, unless otherwise agreed to by the Parties. The Utility may, at its own expense, send qualified personnel to the SGF site to inspect the interconnection and observe the testing. The IC shall provide the Utility a written test report when such testing and inspection is completed.

2.1.2 The Utility shall provide the IC written acknowledgment that it has received the IC's written test report. Such written acknowledgment shall not be deemed to be or construed as any representation, assurance, guarantee, or warranty by the Utility of the safety, durability, suitability, or reliability of the SGF or any associated control, protective, and safety devices owned or controlled by the IC or the quality of power produced by the SGF.

2.1.3 In addition to the Utility's observation of this IC's testing and inspection of its SGF and interconnection facilities pursuant to this Agreement, the Utility may also require inspection and testing of interconnection facilities that can impact the integrity or safety of the Utility's system or otherwise cause adverse operating effects, as described in Section 3.4.4 of this Agreement and in accordance to Good Utility Practice. Such inspection and testing activities will be performed by the Utility or a third-party independent contractor approved by the Utility and at a time mutually agreed to with the IC and will be performed at the IC's expense. The scope of required inspection and testing will be consistent across similar types of generating facilities.

2.2 Authorization required prior to parallel operation.

2.2.1 The Utility shall make reasonable efforts to list applicable parallel operation requirements in Attachment 5 of this Agreement. Additionally, the Utility shall notify the IC of any changes to these requirements as soon as they are known. The Utility shall make reasonable efforts to cooperate with the IC in meeting requirements necessary for the IC to commence parallel operations by the in-service date.

2.2.2 The IC shall not operate its SGF in parallel with the Utility's system without prior written authorization of the Utility. The Utility will provide such authorization once the Utility receives notification that the IC has complied with all applicable parallel operation requirements. Such authorization shall not be unreasonably withheld, conditioned, or delayed.

2.3 Right of access.

2.3.1 Upon reasonable notice, the Utility may send a qualified person to the premises of the IC at or before the time the SGF first produces energy to inspect the interconnection, and observe the commissioning of the SGF (including any required testing), startup, and operation for a period of up to three business days after initial start-up of the unit. In addition, the IC shall notify the Utility at least five business days prior to conducting any on-site verification testing of the SGF.

2.3.2 Following the initial inspection process described in Section 2.3 of this Agreement at reasonable hours and upon reasonable notice or at any time without notice in the event of an emergency or hazardous condition, the Utility shall have access to the IC's premises for any reasonable purpose in connection with the performance of the obligations imposed on it by this Agreement or if necessary to meet its legal obligation to provide service to its customers.

2.3.3 Each Party shall be responsible for its own costs associated with this article.

Article 3. Effective Date, Term, Termination, and Disconnection

3.1 Effective date. This Agreement shall become effective upon execution by the Parties.The Utility shall promptly file this Agreement with the Division of Public Utility Regulation upon execution. ]

3.2 Term of agreement. This Agreement shall remain in effect for a period of 10 years from the effective date or such other longer period as the IC may request and shall be automatically renewed for each successive one-year period thereafter, unless terminated earlier in accordance with Section 3.3 of this Agreement.

3.3 Termination. No termination shall become effective until the Parties have complied with all laws and regulations applicable to such termination,including the filing with the Division of Public Utility Regulation of a notice of termination of this Agreement such as any local or Virginia Department of Environmental Quality decommissioning requirements ].

3.3.1 The IC may terminate this Agreement at any time by giving the Utility 20 business days written notice and physically and permanently disconnecting the SGF from the Utility's system.

3.3.2 The Utility may terminate this Agreement upon the IC's failure to timely make the payment required by Section 6.1 of this Agreement pursuant to the milestones specified in Attachment 4 to this Agreement, or to comply with the requirements of Section 7.1.2 or 7.1.3 of this Agreement.

3.3.3 Either Party may terminate this Agreement after default pursuant to Section 7.6 of this Agreement.

3.3.4 Upon termination of this Agreement, the small generating facility will be disconnected from the Utility system. The termination of this Agreement shall not relieve either Party of its liabilities and obligations, owed or continuing, at the time of the termination.

3.4 Temporary disconnection. Temporary disconnection shall continue only for so long as reasonably necessary under Good Utility Practice.

3.4.1 "Emergency conditions" means a condition or situation that (i) in the judgment of the Party making the claim is imminently likely to endanger life or property; (ii) in the case of the Utility, is imminently likely (as determined in a nondiscriminatory manner) to cause a material adverse effect on the security of or damage to the utility system, the attachment facilities, or the electrical facilities of others to which the utility system is directly connected; or (iii) in the case of the IC, is imminently likely (as determined in a nondiscriminatory manner) to cause a material adverse effect on the security of or damage to the SGF or the customer's interconnection facilities. Under emergency conditions, the Utility may immediately suspend interconnection service and temporarily disconnect the SGF. The Utility shall notify the IC promptly when it becomes aware of an emergency condition that may reasonably be expected to affect the IC's operation of the SGF. The IC shall notify the Utility promptly when it becomes aware of an emergency condition that may reasonably be expected to affect the utility system or other affected systems. To the extent information is known, the notification shall describe the emergency condition, the extent of the damage or deficiency, the expected effect on the operation of both Parties' facilities and operations, its anticipated duration, and the necessary corrective action.

3.4.2 Routine maintenance, construction, and repair. The Utility may interrupt interconnection service or curtail the output of the SGF and temporarily disconnect the SGF from the Utility's system when necessary for routine maintenance, construction, and repairs on the Utility system. The Utility shall provide the IC with at least five business days' notice prior to such interruption unless circumstances require shorter notice. The Utility shall use reasonable efforts to coordinate such reduction or temporary disconnection with the IC.

3.4.3 Forced outages. During any forced outage, the Utility may suspend interconnection service to effect immediate repairs on the Utility system. The Utility shall use reasonable efforts to provide the IC with prior notice. If prior notice is not given, the Utility shall, upon request, provide the IC written documentation after the fact explaining the circumstances of the disconnection.

3.4.4 Adverse operating effects. The Utility shall notify the IC as soon as practicable if based on Good Utility Practice, operation of the SGF may cause disruption or deterioration of service to other customers served from the Utility system or affected systems or if operating the SGF could cause damage to the Utility system or affected systems. Supporting documentation used to reach the decision to disconnect shall be provided to the IC upon request. If, after notice, the IC fails to remedy the adverse operating effect within a reasonable time, the Utility may disconnect the SGF. The Utility shall provide the IC with a five-business-day notice of such disconnection, unless the provisions of Section 3.4.1 of this Agreement apply.

3.4.5 Modification of the small generating facility. The IC must receive written authorization from the Utility before making changes to the SGF or mode of operations that may have a material impact on the safety or reliability of the utility system or affected system. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the IC makes such modifications without the Utility's prior written authorization, the latter shall have the right to temporarily disconnect the SGF.

3.4.6 Reconnection. The Parties shall cooperate with each other to restore the SGF, interconnection facilities, and the utility system to their normal operating state as soon as reasonably practicable following a temporary disconnection.

Article 4. Cost Responsibility for Interconnection Customer's Interconnection Facilities, Attachment Facilities, and Distribution Upgrades

4.1 Customer's interconnection facilities. The IC shall be responsible for the costs associated with owning, operating, maintaining, repairing, and replacing the customer's interconnection facilities.

4.2 Attachment facilities. The IC shall pay for one-time and ongoing costs of installing, owning, operating, maintaining, and replacing the attachment facilities itemized in Attachment 2 of this Agreement. The Utility shall provide an estimated cost for the purchase and construction of the attachment facilities and provide a detailed itemization of such costs. Costs associated with attachment facilities may be shared with other entities that may benefit from such facilities by agreement of the IC, such other entities, and the Utility.

4.3 Distribution upgrades. The Utility shall design, procure, construct, install, and own the distribution upgrades described in Attachment 6 of this Agreement. The actual cost of the distribution upgrades shall be directly assigned to the IC. If the Utility and the IC agree, the IC may construct distribution upgrades that are located on land owned by the IC.

Article 5. Transmission System

5.1 Transmission system upgrades.

5.1.1 No portion of Section 5.1 of this Agreement shall apply unless the interconnection of the SGF requires transmission system upgrades.

5.1.2 The Utility shall design, procure, construct, install, and own the transmission system upgrades described in Attachment 6 of this Agreement. If the Utility and the IC agree, the IC may construct transmission system upgrades that are located on land owned by the IC. The costs of the transmission system upgrades shall be borne by the IC.

5.1.3 Notwithstanding any other provision of Section 5.1 of Agreement, in the event and to the extent an RTE has rules, tariffs, agreements, or procedures properly applying to transmission system upgrades, the provisions of Section 5.2 of this Agreement shall apply to such upgrades.

5.2 Regional transmission entities. Notwithstanding any other provision of this Agreement, if the Utility's transmission system is under the control of an RTE and the RTE has rules, tariffs, agreements, or procedures properly governing operation of the SGF, transmission of the output of the SGF, sale of the output of the SGF, system upgrades required for interconnection of the SGF, or other aspects of the interconnection and operation of the SGF, the IC and the Utility shall comply with the applicable agreements, rules, tariffs, or procedures.

5.3 Rights under other agreements. Notwithstanding any other provision of this Agreement, nothing in this Agreement shall be construed as relinquishing or foreclosing any rights, including firm transmission rights, capacity rights, transmission congestion rights, or transmission credits, that the IC shall be entitled to now or in the future under any other agreement or tariff as a result of or otherwise associated with system upgrades, including the right to obtain cash reimbursements or transmission credits for transmission service that is not associated with the SGF.

Article 6. Billing, Payment, Milestones, and Financial Security

6.1 Billing and payment procedures and final accounting.The IC shall be responsible for pre-payment of all estimated Interconnection Facilities, Attachment Facilities, and Upgrade costs identified in Attachment 2 and Attachment 6 to this Agreement, or the provision of financial security, if acceptable to the Utility as provided for in Section 6.3. Payment or financial security must be received by close of business 30 business days after the date the SGIA is delivered to the IC for signature. Failure to comply with the requirements of this section after an opportunity to cure shall result in the interconnection request being deemed withdrawn. ] Within80 120 ] business days ofthe Utility ] completing the construction and installation of the attachment facilities or distribution upgrades described in the Attachments to this Agreement, the Utility shall provide the IC with a final accounting report of any difference between (i) the IC's cost responsibility for the actual cost of such facilities or upgrades and (ii) the IC's previous aggregate payments to the Utility for such facilities or upgrades.The Utility shall make reasonable efforts to meet the timeframe for issuance of the Final Accounting Report. If the Utility is unable to timely issue the Final Accounting Report, the Utility shall provide written notice to the IC explaining the reason or reasons for the delay and provide an estimated time by which it can issue the Final Accounting Report. ] If the IC's cost responsibility exceeds its previous aggregate payments, the Utility shall invoice the IC for the amount due, and the IC shall make payment to the Utility within 20 business days. If the IC's previous aggregate payments exceed its cost responsibility under this Agreement, the Utility shall refund to the IC an amount equal to the difference within 20 business days of the final accounting report.

6.2 Milestones. The Parties shall agree on milestones for which each Party is responsible, and such milestone shall be listed in Attachment 4 of this Agreement. A Party's milestones obligations may be modified by agreement. If a Party anticipates that it will be unable to meet a milestone for any reason other than a force majeure event, it shall immediately (i) notify the other Party of the reason for not meeting the milestone, (ii) propose the earliest reasonable alternate date by which it can attain this and future milestones, and (iii) request appropriate amendments to Attachment 4. The Party affected by the failure to meet a milestone shall not withhold agreement to such an amendment unless it will suffer uncompensated economic or operational harm from the delay, the delay will materially affect the schedule of another IC with subordinate queue position, attainment of the same milestone has previously been delayed, or it has reason to believe that the delay in meeting the milestone is intentional or unwarranted notwithstanding the circumstances explained by the Party proposing the amendment.

6.3 Financial security arrangements.At least 30 business days prior to the commencement of the design, procurement, installation, or construction of a discrete portion of the attachment facilities and distribution upgrades Within the timeframe provided for in Section 6.1], the ICshall may ] provide the Utility, at the IC's option,in lieu of prepayment, ] a guarantee, a surety bond, letter of credit, or other form of security that is reasonably acceptable to the Utility and is consistent with the Uniform Commercial Code ofthe jurisdiction where the point of interconnection is located Virginia ]. Such security for payment shall beaccepted prior to the Utility's commencement of the design, procurement, installation, or construction of a discrete portion of the attachment facilities and distribution upgrades and shall be ] in an amount sufficient to cover the costs for designing, procuring, installing, and constructing the applicable portion of the attachment facilities and distribution upgradesand. The IC's financial security under this provision ] shall be reduced on a dollar-for-dollar basis for payments made to the Utility under this Agreement during its termpursuant to the milestone schedule established in Appendix 4 ]. In addition:

6.3.1 The guarantee must be made by an entity that meets the creditworthiness requirements of the Utility and contain terms and conditions that guarantee payment of any amount that may be due from the IC, up to an agreed-to maximum amount.

6.3.2 The letter of credit or surety bond must be issued by a financial institution or insured reasonably acceptable to the Utility and must specify a reasonable expiration date.

Article 7. Assignment, Liability, Indemnity, Force Majeure, Consequential Damages, and Default

7.1 Assignment.

7.1.1 The IC shall notify the Utility of the pending sale of an existing SGF in writing. The IC shall provide the Utility with information regarding whether the sale is a change of ownership of the SGF to a new legal entity or a change of control of the existing legal entity.

7.1.2 The IC shall promptly notify the Utility of the final date of sale and transfer date of ownership in writing. The purchaser of the SGF shall confirm to the Utility the final date of sale and transfer date of ownership in writing.

7.1.3 This Agreement shall not survive the transfer of ownership of the SGF to a new legal entity owner. The new owner shall submit a new interconnection request along with a processing fee of $500 to the Utility within 20 business days of the transfer of ownership, ] or, if the facility has been constructed, ] the Utility's interconnection facilities shall be removed or disabled and the SGF disconnected from the Utility's system. The Utility shall not study or inspect the SGF unless the new owner's interconnection request indicates that a material modification has occurred or is proposed.

7.1.4 This Agreement shall survive a change of control of the SGF's legal entity owner, where only the contact information in the interconnection agreement must be modified. The new owner shall submit a new interconnection request along with a processing fee of $500 to the Utility within 20 business days of the change of control and provide the new contact information. The Utility shall not study or inspect the SGF unless the new owner's interconnection request indicates that a material modification has occurred or is proposed.

7.1.5 The IC shall have the right to assign this Agreement, without the consent of the Utility, for collateral security purposes to aid in providing financing for the SGF, provided that the IC will promptly notify the Utility of any such assignment. Assignment shall not relieve a Party of its obligations, nor shall a Party's obligations be enlarged, in whole or in part, by reason thereof.

7.1.6 Any attempted assignment that violates this article is void and ineffective.

7.2 Limitation of liability. Each Party's liability to the other Party for any loss, cost, claim, injury, liability, or expense, including reasonable attorney fees, relating to or arising from any act or omission in its performance of this Agreement shall be limited to the amount of direct damage actually incurred. In no event shall either Party be liable to the other Party for any indirect, special, incidental, consequential, or punitive damages of any kind, except as authorized by this Agreement.

7.3 Indemnity.

7.3.1 This provision protects each Party from liability incurred to third parties as a result of carrying out the provisions of this Agreement. Liability under this provision is exempt from the general limitations on liability found in Section 7.2 of this Agreement.

7.3.2 The Parties shall at all times indemnify, defend, and hold the other Party harmless from all damages; losses; claims, including claims and actions relating to injury to or death of any person or damage to property; demand; suits; recoveries; costs and expenses; court costs; attorney fees; and all other obligations by or to third parties arising out of or resulting from the other Party's action or failure to meet its obligations under this Agreement on behalf of the indemnifying Party, except in cases of gross negligence or intentional wrongdoing by the indemnified Party.

7.3.3 If an indemnified Party is entitled to indemnification under this Article 7 of this Agreement as a result of a claim by a third party, and the indemnifying Party fails, after notice and reasonable opportunity, to proceed under this Article 7 of this Agreement to assume the defense of such claim, such indemnified person may at the expense of the indemnifying Party contest, settle, or consent to the entry of any judgment with respect to, or pay in full, such claim.

7.3.4 If an indemnifying Party is obligated to indemnify and hold any indemnified person harmless under this Article 7 of this Agreement, the amount owing to the indemnified person shall be the amount of such indemnified person's actual loss, net of any insurance or other recovery.

7.3.5 Promptly after receipt by an indemnified person of any claim or notice of the commencement of any action or administrative or legal proceeding or small generator investigation as to which the indemnity provided for in this Article 7 of this Agreement may apply, the indemnified person shall notify the indemnifying Party of such fact. Any failure of or delay in such notification shall not affect a Party's indemnification obligation unless such failure or delay is materially prejudicial to the indemnifying Party.

7.4 Consequential damages. Other than as expressly provided for in this Agreement, neither Party shall be liable under any provision of this Agreement for any losses, damages, costs, or expenses for any special, indirect, incidental, consequential, or punitive damages, including loss of profit or revenue; loss of the use of equipment; cost of capital; cost of temporary equipment or services, whether based in whole or in part in contract; in tort, including negligence, strict liability; or any other theory of liability; provided that damages for which a Party may be liable to the other Party under another agreement will not be considered to be special, indirect, incidental, or consequential damages.

7.5 Force majeure.

7.5.1 As used in this article, "force majeure event" means any act of God; labor disturbance; act of the public enemy; war; insurrection; riot; fire; storm or flood; explosion; breakage or accident to machinery or equipment; any order, regulation, or restriction imposed by governmental, military, or lawfully established civilian authorities; or any other cause beyond a Party's control. A "force majeure event" does not include an act of negligence or intentional wrongdoing.

7.5.2 If a force majeure event prevents a Party from fulfilling any obligation under this Agreement, the Party affected by the force majeure event ("Affected Party") shall promptly notify the other Party, either in writing or via the telephone, of the existence of the force majeure event. The notification must specify in reasonable detail the circumstances of the force majeure event, its expected duration, and the steps that the Affected Party is taking to mitigate the effects of the event on its performance. The Affected Party shall keep the other Party informed on a continuing basis of developments relating to the force majeure event until the event ends. The Affected Party will be entitled to suspend or modify its performance of obligations under this Agreement (other than the obligation to make payments) only to the extent that the effect of the force majeure event cannot be mitigated by the use of reasonable efforts. The Affected Party will use reasonable efforts to resume its performance as soon as possible.

7.6 Default.

7.6.1 No default shall exist where such failure to discharge an obligation (other than the payment of money) is the result of a force majeure event as defined in this Agreement or the result of an act or omission of the other Party. Upon a default, the nondefaulting Party shall give written notice of such default to the defaulting Party. Except as provided in Section 7.6.2 of this Agreement, the defaulting Party shall have 40 business days from receipt of the default notice within which to cure the default; however, if the default is not capable of cure within 40 business days, the defaulting Party shall commence the cure within 10 business days after notice and continuously and diligently complete the cure within six months from receipt of the default notice, and if cured within such time, the default specified in such notice shall cease to exist.

7.6.2 If a default is not cured as provided in this Article 7 of this Agreement or if a default is not capable of being cured within the period provided for in this Article 7 of this Agreement, the nondefaulting Party shall have the right to terminate this Agreement by written notice at any time until cure occurs and be relieved of any further obligation in this Agreement, and whether or not that Party terminates this Agreement, to recover from the defaulting Party all amounts due pursuant to this Agreement, plus all other damages and remedies to which it is entitled at law or in equity. The provisions of this Article 7 of this Agreement will survive termination of this Agreement.

Article 8. Insurance

8.1 The IC shall, at its own expense, maintain in force general liability insurance without any exclusion for liabilities related to the interconnection undertaken pursuant to this Agreement. The amount of such insurance shall be in accordance with 20VAC5-314-160. The IC shall obtain additional insurance only if necessary as a function of owning and operating a generating facility. Insurance shall be obtained from an insurance provider authorized to conduct business in the Commonwealth of Virginia. Certification that such insurance is in effect shall be provided upon request of the Utility, except that the IC shall show proof of insurance to the Utility no later than 10 business days prior to the anticipated commercial operation date of the SGF. An IC of sufficient creditworthiness may propose to self-insure for such liabilities, and such a proposal shall not be unreasonably rejected.

8.2 The Utility agrees to maintain general liability insurance or self-insurance consistent with the Utility's commercial practice. Such insurance or self-insurance shall not exclude coverage for the Utility's liabilities undertaken pursuant to this Agreement.

8.3 The Parties further agree to notify each other whenever an accident or incident occurs resulting in any injuries or damages that are included within the scope of coverage of such insurance, whether or not such coverage is sought.

Article 9. Confidentiality

9.1 Confidential information shall mean any confidential or proprietary information provided by one Party to the other Party that is clearly marked or otherwise designated "Confidential." For purposes of this Agreement all design, operating specifications, and metering data provided by the IC shall be deemed confidential information regardless of whether it is clearly marked or otherwise designated as such.

9.2 Confidential information does not include information previously in the public domain, required to be publicly submitted or divulged by governmental authorities (after notice to the other Party and after exhausting any opportunity to oppose such publication or release), or necessary to be divulged in an action to enforce this Agreement. Each Party receiving confidential information shall hold such information in confidence and shall not disclose it to any third party or the public without the prior written authorization from the Party providing that information, except to fulfill obligations under this Agreement or to fulfill legal or regulatory requirements.

9.2.1 Each Party shall employ at least the same standard of care to protect confidential information obtained from the other Party as it employs to protect its own confidential information.

9.2.2 Each Party is entitled to equitable relief, by injunction or otherwise, to enforce its rights under this provision to prevent the release of confidential information without bond or proof of damages and may seek other remedies available at law or in equity for breach of this provision.

9.3 Notwithstanding anything in this Agreement to the contrary, if the Virginia State Corporation Commission ("Commission"), during the course of an investigation or otherwise, requests information from one of the Parties that is otherwise required to be maintained in confidence, the Party shall provide the requested information to the commission, within the time provided for in the request for information. In providing the information to the commission, the Party may request that the information be treated as confidential and nonpublic by the commission and that the information be withheld from public disclosure. Parties are prohibited from notifying the other Party prior to the release of the confidential information to the commission. A Party shall notify the other Party when it is notified by the commission that a request to release confidential information has been received by the commission, at which time either Party may respond to the commission before such information would be made public.

Article 10. Disputes

10.1 The Parties agree to attempt to resolve all disputes arising out of the interconnection process according to the provisions of this Article 10 of this Agreement.

10.2 In the event of a dispute, either Party shall provide the other Party with a written notice of dispute. Such notice shall describe in detail the nature of the dispute. The Parties shall make a good faith effort to resolve the dispute informally within 10 business days.

10.3 If the dispute has not been resolved within 10 business days after receipt of the notice, either Party may seek resolution assistance from the Division of Public Utility Regulation where the matter will be handled as an informal complaint.

Alternatively, either Party may, upon mutual agreement, seek resolution through the assistance of a dispute resolution service. The dispute resolution service will assist the Parties in either resolving the dispute or in selecting an appropriate dispute resolution venue (e.g., mediation, settlement judge, early neutral evaluation, or technical expert) to assist the Parties in resolving their dispute. Each Party shall conduct all negotiations in good faith and shall be responsible for one-half of any costs paid to neutral third parties.

10.4 If the dispute remains unresolved, either Party maypetition the commission to handle the dispute as a formal complaint or may exercise whatever rights and remedies it may have in equity or law consistent with the terms of this Agreement.

Article 11. Taxes

11.1 The Parties agree to follow all applicable tax laws and regulations.

11.2 Each Party shall cooperate with the other to maintain the other Party's tax status. Nothing in this Agreement is intended to adversely affect the Utility's tax exempt status with respect to the issuance of bonds including local furnishing bonds.

Article 12. Miscellaneous

12.1 Governing law, regulatory authority, and rules. The validity, interpretation, and enforcement of this Agreement and each of its provisions shall be governed by the laws of the Commonwealth of Virginia without regard to its conflicts of law principles. This Agreement is subject to all applicable laws and regulations. Each Party expressly reserves the right to seek changes in, appeal, or otherwise contest any laws, orders, or regulations of a governmental authority.

12.2 Amendment. The Parties may amend this Agreement by a written instrument duly executed by both Parties.

12.3 No third-party beneficiaries. This Agreement is not intended to and does not create rights, remedies, or benefits of any character whatsoever in favor of any persons, corporations, associations, or entities other than the Parties, and the obligations in this Agreement assumed are solely for the use and benefit of the Parties, their successors in interest, and where permitted, their assigns.

12.4 Waiver.

12.4.1 The failure of a Party to this Agreement to insist, on any occasion, upon strict performance of any provision of this Agreement will not be considered a waiver of any obligation, right, or duty of or duty imposed upon such Party.

12.4.2 Any waiver at any time by either Party of its rights with respect to this Agreement shall not be deemed to be a continuing waiver or a waiver with respect to any other failure to comply with any other obligation, right, or duty of this Agreement. Termination or default of this Agreement for any reason by the IC shall not constitute a waiver of the IC's legal rights to obtain an interconnection from the Utility. Any waiver of this Agreement shall, if requested, be provided in writing.

12.5 Entire agreement. This Agreement, including all Attachments to this Agreement, constitutes the entire agreement between the Parties with reference to the subject matter hereof and supersedes all prior and contemporaneous understandings or agreements, oral or written, between the Parties with respect to the subject matter of this Agreement. There are no other agreements, representations, warranties, or covenants that constitute any part of the consideration for, or any condition to, either Party's compliance with its obligations under this Agreement.

12.6 Multiple counterparts. This Agreement may be executed in two or more counterparts, each of which is deemed an original but all constitute one and the same instrument.

12.7 No partnership. This Agreement shall not be interpreted or construed to create an association, joint venture, agency relationship, or partnership between the Parties or to impose any partnership obligation or partnership liability upon either Party. Neither Party shall have any right, power, or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.

12.8 Severability. If any provision or portion of this Agreement shall for any reason be held or adjudged to be invalid or illegal or unenforceable by any court of competent jurisdiction or other governmental authority, (i) such portion or provision shall be deemed separate and independent, (ii) the Parties shall negotiate in good faith to restore insofar as practicable the benefits to each Party that were affected by such ruling, and (iii) the remainder of this Agreement shall remain in full force and effect.

12.9 Environmental releases. Each Party shall notify the other Party, first orally and then in writing, of the release of any hazardous substances, any asbestos or lead abatement activities, or any type of remediation activities related to the SGF, the customer's interconnection facilities, or attachment facilities, each of which may reasonably be expected to affect the other Party. The notifying Party shall (i) provide the notice as soon as practicable, provided such Party makes a good faith effort to provide the notice no later than 24 hours after such Party becomes aware of the occurrence, and (ii) promptly furnish to the other Party copies of any publicly available reports filed with any governmental authorities addressing such events.

12.10 Subcontractors. Nothing in this Agreement shall prevent a Party from utilizing the services of any subcontractor as it deems appropriate to perform its obligations under this Agreement; however, each Party shall require its subcontractors to comply with all applicable terms and conditions of this Agreement in providing such services, and each Party shall remain primarily liable to the other Party for the performance of such subcontractor.

12.10.1 The creation of any subcontract relationship shall not relieve the hiring Party of any of its obligations under this Agreement. The hiring Party shall be fully responsible to the other Party for the acts or omissions of any subcontractor the hiring Party hires as if no subcontract had been made; however, in no event shall the Utility be liable for the actions or inactions of the IC or its subcontractors with respect to obligations of the IC under this Agreement. Any applicable obligation imposed by this Agreement upon the hiring Party shall be equally binding upon and shall be construed as having application to any subcontractor of such Party.

12.10.2 The obligations under this article will not be limited in any way by any limitation of subcontractor's insurance.

12.11 Reservation of rights. The Utility shall have the right to make a unilateral filing with the commission to modify this Agreement with respect to any rates, terms and conditions, charges, classifications of service, rule, or regulation, and the IC shall have the right to make a unilateral filing with the commission to modify this Agreement; provided that each Party shall have the right to protest any such filing by the other Party and to participate fully in any proceeding before the commission in which such modifications may be considered. Nothing in this Agreement shall limit the rights of the Parties except to the extent that the Parties otherwise agree as provided in this Agreement.

Article 13. Notices

13.1 General. Unless otherwise provided in this Agreement, any written notice, demand, or request required or authorized in connection with this Agreement shall be deemed properly given if delivered in person, delivered by recognized national courier service, or sent by first class mail, postage prepaid, to the person listed:

If to the Interconnection Customer:

Interconnection Customer:____________________________________

Attention:_________________________________________________

Address:_________________________________________________

City, State, Zip:____________________________________________

Phone:___________________________ Fax:____________________

If to the Utility:

Utility:___________________________________________

Attention:_________________________________________________

Address:_________________________________________________

City, State, Zip:____________________________________________

Phone:___________________________ Fax:____________________

13.2 Billing and payment.

Billings and payments shall be sent to the addresses listed:

If to the Interconnection Customer:

Interconnection Customer:_____________________________________

Attention:__________________________________________________

Address:__________________________________________________

City, State, Zip:______________________________________________

If to the Utility:

Utility:___________________________________________

Attention:__________________________________________________

Address:__________________________________________________

City, State, Zip:_____________________________________________

13.3 Alternative forms of notice. Any notice or request required or permitted to be given by either Party to the other and not required by this Agreement to be given in writing may be so given by telephone, facsimile, or email to the telephone numbers and email addresses listed:

If to the Interconnection Customer:

Interconnection Customer:_______________________________________

Attention:____________________________________________________

Address:____________________________________________________

City, State, Zip:_______________________________________________

Phone:___________________________ Fax:_______________________

If to the Utility:

Utility:___________________________________________

Attention:____________________________________________________

Address:____________________________________________________

City, State, Zip:_______________________________________________

Phone:___________________________ Fax:_______________________

13.4 Designated operating representative. The Parties may also designate operating representatives to conduct the communications that may be necessary or convenient for the administration of this Agreement. This person will also serve as the point of contact with respect to operations and maintenance of the Party's facilities.

Interconnection Customer's Operating Representative:

Interconnection Customer:_______________________________________

Attention:____________________________________________________

Address:____________________________________________________

City, State, Zip:_______________________________________________

Phone:___________________________ Fax:_______________________

Utility's Operating Representative:

Utility:___________________________________________

Attention:____________________________________________________

Address:____________________________________________________

City, State, Zip:_______________________________________________

Phone:___________________________ Fax:_______________________

13.5 Changes to the notice information. Either Party may change this information by giving five business days' written notice prior to the effective date of the change.

Article 14. Signatures

IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed by their respective duly authorized representatives.

For the Utility

Name:_______________________________________________________

Title:________________________________________________________

Date:_____________________

For the Affected System Utility

Name:_______________________________________________________

Title:________________________________________________________

Date:______________________ ]

For the Interconnection Customer

Name:______________________________________________________

Title:________________________________________________________

Date:_____________________

Attachment 1 to Schedule 10

Glossary of Terms

The following terms when used in Schedule 10 of 20VAC5-314-170 will have the following meanings:

"Affected system" means an electric utility system other than that of the Utility that may be affected by the proposed interconnection.

"Affected system operator" means an entity that operates an affected system, or if the affected system is under the operational control of an independent system operator or a regional transmission entity, such independent entity.

"Applicable laws and regulations" means all duly promulgated applicable federal, state, and local laws, regulations, rules, ordinances, codes, decrees, judgments, directives, or judicial or administrative orders; permits; and other duly authorized actions of any governmental authority.

"Attachment facilities" means the facilities and equipment owned, operated, and maintained by the Utility that are built new in order to physically connect the customer's interconnection facilities to the Utility system. Attachment facilities shall not include distribution upgrades or previously existing distribution and transmission facilities.

"Balancing authority" means the responsible entity that integrates resource plans ahead of time, maintains load-interchange-generation balance within a balancing authority area, and supports interconnection frequency in real time.

"Balancing authority area" means the collection of generation, transmission, and loads within the metered boundaries of the balancing authority. The balancing authority maintains load-resource balance within this area.

"Business day" means Monday through Friday, excluding federal holidays.

"Calendar day" means Sunday through Saturday, including all holidays.

"Certified" has the meaning ascribed to it in Schedule 2 of 20VAC5-314-170.

"Commission" means the Virginia State Corporation Commission.

"Customer's interconnection facilities" means all the facilities and equipment owned, operated and maintained by the IC, between the SGF and the point of interconnection necessary to physically and electrically interconnect the SGF to the utility system.

"Default" means the failure of a breaching Party to cure its breach under the Small Generator Interconnection Agreement.

"Distribution system" means the Utility's facilities and equipment generally delivering electricity to ultimate customers from substations supplied by higher voltages (usually at transmission level). For purposes of this Agreement, all portions of the Utility's transmission system regulated by the commission for which interconnections are not within Federal Energy Regulatory Commission jurisdiction are considered also to be subject to commission regulations.

"Distribution upgrades" means the additions, modifications, and enhancements made to the Utility's distribution system on the Utility's side of the point of interconnection necessary to ensure continued system reliability and power quality on the Utility's distribution system caused by the interconnection of the small generating facility. Distribution upgrades do not include network upgrades or the customer's interconnection facilities or the Utility's attachment facilities.

"Facilities study" has the meaning ascribed to it in 20VAC5-314-70 E.

"Feasibility study" has the meaning ascribed to it in 20VAC5-314-70 C.

"FERC" means the Federal Energy Regulatory Commission.

"Good Utility Practice" means any of the practices, methods, and acts engaged in or approved by a significant portion of the electric industry during the relevant time period, or any of the practices, methods, and acts that, in the exercise of reasonable judgment in light of the facts known at the time the decision was made, could have been expected to accomplish the desired result at a reasonable cost, consistent with good business practices, reliability, safety, and expedition. Good Utility Practice is not intended to be limited to the optimum practice, method, or act to the exclusion of all others but rather to include practices, methods, or acts generally accepted in the region.

"Governmental authority" means any federal, state, local, or other governmental regulatory or administrative agency, court, commission, department, board, or other governmental subdivision or legislature or rulemaking board, tribunal, or other governmental authority having jurisdiction over the Parties, their respective facilities, or the respective services they provide and exercising or entitled to exercise any administrative, executive, police, or taxing authority or power; provided that such term does not include the IC, the Utility, or a Utility affiliate.

"Interconnection Customer" or "IC" means any entity proposing to interconnect a new SGF with the utility system.

"Interconnection request" means the IC's request, in accordance with the Regulations Governing Interconnection of Small Electrical Generators (20VAC5-314), to interconnect a new small generating facility or to increase the capacity of or make a material modification to the operating characteristics of an existing small generating facility that is interconnected with the Utility system.

"Interconnection studies" means the studies conducted by the Utility or a third party agreed to by the Utility and the IC in order to determine the interaction of the SGF with the Utility system and the affected systems in order to specify any modifications to the SGF or the electric systems studied to ensure safe and reliable operation of the SGF in parallel with the Utility system.

"Material modification" has the meaning ascribed to it in 20VAC5-314-39.

"Maximum generating capacity" means the maximum continuous electrical output of the SGF at any time as measured at the point of interconnection or the maximum kW delivered to the Utility during any metering period, whichever is greater. Requested maximum generating capacity will be specified by the IC in the interconnection request and an approved maximum generating capacity will subsequently be included as a limitation in the interconnection agreement.

"Network upgrades" means additions, modifications, and enhancements to the Utility's transmission system that are required in order to accommodate the interconnection of the small generating facility with the Utility's system. Network upgrades do not include distribution system upgrades.

"Operating requirements" means any operating and technical requirements that may be applicable due to regional transmission entity, independent system operator, control area, or the Utility's requirements, including those set forth in this Small Generator Interconnection Agreement.

"Party" means the Utility or the IC.

"Point of interconnection" means the point where the customer's interconnection facilities connect physically and electrically to the Utility system.

[ "Processing fee" means a nonrefundable cost to administer or file an application. ]

"Queue number" refers to the number assigned by the Utility that establishes a customer's interconnection request's position in the study queue relative to all other valid interconnection requests. A lower queue number will be studied prior to a higher queue number, except in the case of interdependent projects. The queue number of each interconnection request shall be used to determine the cost responsibility for the upgrades necessary to accommodate the interconnection.

"Queue position" means the order of a valid interconnection request relative to all other pending valid interconnection request based on queue number.

"Regional Transmission Entity" or "RTE" shall refer to an entity having the management and control of a Utility's transmission system as further set forth in § 56-579 of the Code of Virginia.

"Small generating facility" or "generating facility" or "generator" or "SGF" means the IC's equipment used for the productionor storage for later injection ] of electricity, as identified in the interconnection request.

"Small Generator Interconnection Agreement" or "SGIA" means the agreement between the Utility and the IC as set forth in this Schedule 10 of 20VAC5-314-170.

"Supplemental review" has the meaning ascribed to it in 20VAC5-314-60 H.

"System" or "Utility system" means the distribution and transmission facilities owned, controlled, or operated by the Utility that are used to deliver electricity.

"System impact study" has the meaning ascribed to it in 20VAC5-314-70 D.

"Tariff" means the rates, terms, and conditions filed by the Utility with the commission for the purpose of providing commission-regulated electric service to retail customers.

"Transmission system" means the Utility's facilities and equipment delivering electric energy to the distribution system; such facilities usually being operated at voltage levels above the Utility's typical distribution system voltage levels.

"Utility" means the public utility company subject to regulation by the Commission pursuant to Chapter 10 (§ 56-232 et seq.) of Title 56 of the Code of Virginia with regard to rates or service quality to whose system the IC proposes to interconnect a small generating facility.

Attachment 2 to Schedule 10

Description and Costs of the Small Generating Facility, Customer's Interconnection Facilities, Attachment Facilities, and Metering Equipment

The following shall be provided in this exhibit:

1. An itemization of the major equipment components owned by the IC and the Utility, including components of the SGF, the customer's interconnection facilities, attachment facilities, and metering equipment. Such itemization shall identify the owner of each item listed.

2. The Utility's estimated itemized cost of its attachment facilities and its metering equipment.

3. The Utility's estimated cost of its annual operation and maintenance expenses associated with attachment facilities and metering equipment to be charged to the IC.

Attachment 3 to Schedule 10

One-line Diagram Depicting the Small Generating Facility, Customer's Interconnection Facilities, Attachment Facilities, Metering Equipment, and Distribution Upgrades

(Diagram and description to be provided by IC unless the Utility elects to prepare this schedule. If this schedule is prepared by the Utility, the IC shall provide a one-line diagram of the SGF and IC's interconnection facilities for the Utility to use as a data source for preparing this schedule.)

Attachment 4 to Schedule 10

Milestones

In-Service Date:___________________

Critical milestones and responsibility as agreed to by the Parties:

Milestone/Date

Responsible Party

(1)___________________________

___________________________

(2)___________________________

___________________________

(3)___________________________

___________________________

(4)___________________________

___________________________

(5)___________________________

___________________________

(6)___________________________

___________________________

(7)___________________________

___________________________

(8)___________________________

___________________________

(9)___________________________

___________________________

(10)__________________________

___________________________

 

Agreed to by:

For the Utility__________________ Date__________

For the Transmission Owner (if applicable)_____________ Date__________

For the Interconnection Customer____________________ Date__________

Attachment 5 to Schedule 10

Additional Operating Requirements for the Utility System and Affected Systems Needed to Support the Interconnection Customer's Needs

The Utility shall provide requirements that must be met by the IC prior to initiating parallel operation with the utility system.

Attachment 6 to Schedule 10

Utility's Description of its Distribution and Transmission Upgrades and Estimate of Upgrade Costs

The Utility shall provide the following in this attachment:

1. An itemized list of the upgrades required to be constructed by the Utility prior to interconnection of the SGF, with transmission and distribution related upgrades shown separately.

2. An estimate of the cost of each item listed pursuant to Item 1 of this Attachment.

3. An estimate of annual operation and maintenance expenses associated with such upgrades that are to be charged to the IC, shown separately for transmission and distribution related items.

DOCUMENTS INCORPORATED BY REFERENCE (20VAC5-314)

IEEE Standard for Interconnecting Distributed Resources with Electric Power Systems, The Institute of Electrical and Electronics Engineers, Inc., Standard 1547, July 28, 2003

IEEE Standard for Interconnection and Interoperability of Distributed Energy Resources with Associated Electric Power Systems Interfaces, The Institute of Electrical and Electronics Engineers, Inc., Standard 1547, 2018.

IEEE Standard Conformance Test Procedures for Equipment Interconnecting Distributed Resources with Electric Power Systems, The Institute of Electrical and Electronics Engineers, Inc., Standard 1547.1, July 1, 2005.

VA.R. Doc. No. R20-5389; Filed July 29, 2020, 3:34 p.m.