Title of Regulation: 18VAC50-22. Board for Contractors Regulations (amending 18VAC50-22-30 through 18VAC50-22-60, 18VAC50-22-260).

Statutory Authority: § 54.1-201 of the Code of Virginia.

Effective Date: January 1, 2018.

Agency Contact: Eric L. Olson, Executive Director, Board for Contractors, 9960 Mayland Drive, Suite 400, Richmond, VA 23233, telephone (804) 367-2785, FAX (866) 430-1033, or email contractors@dpor.virginia.gov.

Summary:

Pursuant to Chapter 527 of the 2016 Acts of Assembly, the amendments (i) add an exclusive specialty for businesses that perform, manage, or supervise the remediation of property formerly used to manufacture methamphetamine; (ii) establish the criteria to obtain and maintain the license specialty, including experience and examination requirements; and (iii) require that the remediation work is consistent with applicable remediation standards of other federal or state agencies.

Summary of Public Comments and Agency's Response: No public comments were received by the promulgating agency.

18VAC50-22-30. Definitions of specialty services.

The following words and terms when used in this chapter unless a different meaning is provided or is plainly required by the context shall have the following meanings:

"Accessibility services contracting" (Abbr: ASC) means the service that provides for all work in connection with the constructing, installing, altering, servicing, repairing, testing, or maintenance of wheelchair lifts, incline chairlifts, dumbwaiters with a capacity limit of 300 pounds, and private residence elevators in accordance with the Virginia Uniform Statewide Building Code (13VAC5-63). The EEC specialty may also perform this work. This specialty does not include work on limited use-limited application (LULA) elevators.

"Accessibility services contracting - LULA" (Abbr: ASL) means the service that provides for all work in connection with the constructing, installing, altering, servicing, repairing, testing, or maintenance of wheelchair lifts, incline chairlifts, dumbwaiters with a capacity limit of 300 pounds, private residence elevators, and limited use-limited application (LULA) elevators in accordance with the Virginia Uniform Statewide Building Code (13VAC5-63). The EEC specialty may also perform this work.

"Alternative energy system contracting" (Abbr: AES) means the service that provides for the installation, repair or improvement, from the customer's meter, of alternative energy generation systems, supplemental energy systems and associated equipment annexed to real property. This service does not include the installation of emergency generators powered by fossil fuels. No other classification or specialty service provides this function. This specialty does not provide for electrical, plumbing, gas fitting, or HVAC functions.

"Asbestos contracting" (Abbr: ASB) means the service that provides for the installation, removal, or encapsulation of asbestos containing materials annexed to real property. No other classification or specialty service provides for this function.

"Asphalt paving and sealcoating contracting" (Abbr: PAV) means the service that provides for the installation of asphalt paving or sealcoating, or both, on subdivision streets and adjacent intersections, driveways, parking lots, tennis courts, running tracks, and play areas, using materials and accessories common to the industry. This includes height adjustment of existing sewer manholes, storm drains, water valves, sewer cleanouts and drain grates, and all necessary excavation and grading. The H/H classification also provides for this function.

"Billboard/sign contracting" (Abbr: BSC) means the service that provides for the installation, repair, improvement, or dismantling of any billboard or structural sign permanently annexed to real property. H/H and CBC are the only other classifications that can perform this work except that a contractor in this specialty may connect or disconnect signs to existing electrical circuits. No trade related plumbing, electrical, or HVAC work is included in this function.

"Blast/explosive contracting" (Abbr: BEC) means the service that provides for the use of explosive charges for the repair, improvement, alteration, or demolition of any real property or any structure annexed to real property.

"Commercial improvement contracting" (Abbr: CIC) means the service that provides for repair or improvement to structures not defined as dwellings and townhouses in the USBC. The CBC classification also provides for this function. The CIC specialty does not provide for the construction of new buildings, accessory buildings, electrical, plumbing, HVAC, or gas work.

"Concrete contracting" (Abbr: CEM) means the service that provides for all work in connection with the processing, proportioning, batching, mixing, conveying, and placing of concrete composed of materials common to the concrete industry. This includes but is not limited to finishing, coloring, curing, repairing, testing, sawing, grinding, grouting, placing of film barriers, sealing, and waterproofing. Construction and assembling of forms, molds, slipforms, and pans, centering, and the use of rebar are also included. The CBC, RBC, and H/H classifications also provide for this function.

"Drug lab remediation contracting" (Abbr: DLR) means the service that provides for the cleanup, treatment, containment, or removal of hazardous substances at or in a property formerly used to manufacture methamphetamine or other drugs and may include demolition or disposal of structures or other property. No other classification or specialty provides for this function.

"Drywall contracting" (Abbr: DRY) means the service that provides for the installation, taping, and finishing of drywall, panels and assemblies of gypsum wallboard, sheathing, and cementitious board and the installation of studs made of sheet metal for the framing of ceilings and nonstructural partitioning. The CBC and RBC classifications and HIC and CIC specialties also provide for this function.

"Electronic/communication service contracting" (Abbr: ESC) means the service that provides for the installation, repair, improvement, or removal of electronic or communications systems annexed to real property including telephone wiring, computer cabling, sound systems, data links, data and network installation, television and cable TV wiring, antenna wiring, and fiber optics installation, all of which operate at 50 volts or less. A firm holding an ESC license is responsible for meeting all applicable tradesman licensure standards. The ELE classification also provides for this function.

"Elevator/escalator contracting" (Abbr: EEC) means the service that provides for the installation, repair, improvement, or removal of elevators or escalators permanently annexed to real property. A firm holding an EEC license is responsible for meeting all applicable individual license and certification regulations. No other classification or specialty service provides for this function.

"Environmental monitoring well contracting" (Abbr: EMW) means the service that provides for the construction of a well to monitor hazardous substances in the ground.

"Environmental specialties contracting" (Abbr: ENV) means the service that provides for installation, repair, removal, or improvement of pollution control and remediation devices. No other specialty provides for this function. This specialty does not provide for electrical, plumbing, gas fitting, or HVAC functions.

"Equipment/machinery contracting" (Abbr: EMC) means the service that provides for the installation or removal of equipment or machinery including but not limited to conveyors or heavy machinery. Boilers exempted by the Virginia Uniform Statewide Building Code (13VAC5-63) but regulated by the Department of Labor and Industry are also included in this specialty. This specialty does not provide for any electrical, plumbing, process piping, or HVAC functions.

"Farm improvement contracting" (Abbr: FIC) means the service that provides for the installation, repair, or improvement of a nonresidential farm building or structure, or nonresidential farm accessory-use structure, or additions thereto. The CBC classification also provides for this function. The FIC specialty does not provide for any electrical, plumbing, HVAC, or gas fitting functions.

"Finish carpentry contracting" (Abbr: FIN) means the service that provides for the installation, repair, and finishing of cabinets, sash casing, door casing, wooden flooring, baseboards, countertops, and other millwork. Finish carpentry does not include the installation of ceramic tile, marble, and artificial or cultured stone. The CBC and RBC classifications and HIC and CIC specialties also provide for this function.

"Fire alarm systems contracting" (Abbr: FAS) means the service that provides for the installation, repair, or improvement of fire alarm systems that operate at 50 volts or less. The ELE classification also provides for this function. A firm with an FAS license is responsible for meeting all applicable tradesman licensure standards.

"Fire sprinkler contracting" (Abbr: SPR) means the service that provides for the installation, repair, alteration, addition, testing, maintenance, inspection, improvement, or removal of sprinkler systems using water as a means of fire suppression when annexed to real property. This specialty does not provide for the installation, repair, or maintenance of other types of fire suppression systems. The PLB classification allows for the installation of systems permitted to be designed in accordance with the plumbing provisions of the USBC. This specialty may engage in the installation of backflow prevention devices in the fire sprinkler supply main and incidental to the sprinkler system installation when the installer has received formal vocational training approved by the board that included instruction in the installation of backflow prevention devices.

"Fire suppression contracting" (Abbr: FSP) means the service that provides for the installation, repair, improvement, or removal of fire suppression systems including but not limited to halon and other gas systems, dry chemical systems, and carbon dioxide systems annexed to real property. No other classification provides for this function. The FSP specialty does not provide for the installation, repair, or maintenance of water sprinkler systems.

"Flooring and floor covering contracting" (Abbr: FLR) means the service that provides for the installation, repair, improvement, or removal of materials that are common in the flooring industry. This includes, but is not limited to, wood and wood composite flooring, tack strips or other products used to secure carpet, vinyl and linoleum, ceramic, marble, stone, and all other types of tile, and includes the installation or replacement of subflooring, leveling products, or other materials necessary to facilitate the installation of the flooring or floor covering. This does not include the installation, repair, or removal of floor joists or other structural components of the flooring system. The CBC and RBC classifications and HIC and CIC specialties also provide for this function.

"Framing subcontractor" (Abbr: FRM) means the service which, while serving in the role of a subcontractor to a licensed prime contractor, provides for the construction, removal, repair, or improvement to any framing or rough carpentry necessary for the construction of framed structures, including the installation and repair of individual components of framing systems. The CBC and RBC classifications and HIC and CIC specialties also provide for this function.

"Gas fitting contracting" (Abbr: GFC) means the service that provides for the installation, repair, improvement, or removal of gas piping and appliances annexed to real property. A firm holding a GFC license is responsible for meeting all applicable individual (tradesman) licensure regulations.

"Glass and glazing contracting" (Abbr: GLZ) means the service that provides for the installation, assembly, repair, improvement, or removal of all makes and kinds of glass, glass work, mirrored glass, and glass substitute for glazing; executes the fabrication and glazing of frames, panels, sashes and doors; or installs these items in any structure. This specialty includes the installation of standard methods of weatherproofing, caulking, glazing, sealants, and adhesives. The CBC and RBC classifications and HIC and CIC specialties also provide for this function.

"Home improvement contracting" (Abbr: HIC) means the service that provides for repairs or improvements to dwellings and townhouses as defined in the USBC or structures annexed to those dwellings or townhouses as defined in the USBC. The RBC classification also provides for this function. The HIC specialty does not provide for electrical, plumbing, HVAC, or gas fitting functions. It does not include new construction functions beyond the existing building structure other than decks, patios, driveways, and utility out buildings that do not require a permit per the USBC.

"Industrialized building contracting" (Abbr: IBC) means the service that provides for the installation or removal of an industrialized building as defined in the Virginia Industrialized Building Safety Regulations (13VAC5-91). This classification covers foundation work in accordance with the provisions of the Virginia Uniform Statewide Building Code (13VAC5-63) and allows the licensee to complete internal tie-ins of plumbing, gas, electrical, and HVAC systems. It does not allow for installing additional plumbing, gas, electrical, or HVAC work such as installing the service meter, or installing the outside compressor for the HVAC system. The CBC and RBC classifications also provide for this function.

"Insulation and weather stripping contracting" (Abbr: INS) means the service that provides for the installation, repair, improvement, or removal of materials classified as insulating media used for the sole purpose of temperature control or sound control of residential and commercial buildings. It does not include the insulation of mechanical equipment and ancillary lines and piping. The CBC and RBC classifications and HIC and CIC specialties also provide for this function.

"Landscape irrigation contracting" (Abbr: ISC) means the service that provides for the installation, repair, improvement, or removal of irrigation sprinkler systems or outdoor sprinkler systems. The PLB and H/H classifications also provide for this function. This specialty may install backflow prevention devices incidental to work in this specialty when the installer has received formal vocational training approved by the board that included instruction in the installation of backflow prevention devices.

"Landscape service contracting" (Abbr: LSC) means the service that provides for the alteration or improvement of a land area not related to any other classification or service activity by means of excavation, clearing, grading, construction of retaining walls for landscaping purposes, or placement of landscaping timbers. This specialty may remove stumps and roots below grade. The CBC, RBC, and H/H classifications also provide for this function.

"Lead abatement contracting" (Abbr: LAC) means the service that provides for the removal or encapsulation of lead-containing materials annexed to real property. No other classification or specialty service provides for this function, except that the PLB and HVA classifications may provide this service incidental to work in those classifications.

"Liquefied petroleum gas contracting" (Abbr: LPG) means the service that includes the installation, maintenance, extension, alteration, or removal of all piping, fixtures, appliances, and appurtenances used in transporting, storing, or utilizing liquefied petroleum gas. This excludes hot water heaters, boilers, and central heating systems that require an HVA or PLB license. The GFC specialty also provides for this function. A firm holding an LPG license is responsible for meeting all applicable individual license and certification regulations.

"Manufactured home contracting" (Abbr: MHC) means the service that provides for the installation or removal of a manufactured home as defined in the Virginia Manufactured Home Safety Regulations (13VAC5-95). This classification does not cover foundation work; however, it does allow installation of piers covered under HUD regulations. It does allow a licensee to do internal tie-ins of plumbing, gas, electrical, or HVAC equipment. It does not allow for installing additional plumbing, gas, electrical, or HVAC work such as installing the service meter or installing the outside compressor for the HVAC system. No other specialty provides for this function.

"Marine facility contracting" (Abbr: MCC) means the service that provides for the construction, repair, improvement, or removal of any structure the purpose of which is to provide access to, impede, or alter a body of surface water. The CBC and H/H classifications also provide for this function. The MCC specialty does not provide for the construction of accessory structures or electrical, HVAC, or plumbing functions.

"Masonry contracting" (Abbr: BRK) means the service that includes the installation of brick, concrete block, stone, marble, slate, or other units and products common to the masonry industry, including mortarless type masonry products. This includes installation of grout, caulking, tuck pointing, sand blasting, mortar washing, parging, and cleaning and welding of reinforcement steel related to masonry construction. The CBC and RBC classifications and the HIC and CIC specialties also provide for this function.

"Natural gas fitting provider contracting" (Abbr: NGF) means the service that provides for the incidental repair, testing, or removal of natural gas piping or fitting annexed to real property. This does not include new installation of gas piping for hot water heaters, boilers, central heating systems, or other natural gas equipment that requires an HVA or PLB license. The GFC specialty also provides for this function. A firm holding an NGF license is responsible for meeting all applicable individual license and certification regulations.

"Painting and wallcovering contracting" (Abbr: PTC) means the service that provides for the application of materials common to the painting and decorating industry for protective or decorative purposes, the installation of surface coverings such as vinyls, wall papers, and cloth fabrics. This includes surface preparation, caulking, sanding, and cleaning preparatory to painting or coverings and includes both interior and exterior surfaces. The CBC and RBC classifications and the HIC and CIC specialties also provide for this function.

"Radon mitigation contracting" (Abbr: RMC) means the service that provides for additions, repairs or improvements to buildings or structures, for the purpose of mitigating or preventing the effects of radon gas. No electrical, plumbing, gas fitting, or HVAC functions are provided by this specialty.

"Recreational facility contracting" (Abbr: RFC) means the service that provides for the construction, repair, or improvement of any recreational facility, excluding paving and the construction of buildings, plumbing, electrical, and HVAC functions. The CBC classification also provides for this function.

"Refrigeration contracting" (Abbr: REF) means the service that provides for installation, repair, or removal of any refrigeration equipment (excluding HVAC equipment). No electrical, plumbing, gas fitting, or HVAC functions are provided by this specialty. This specialty is intended for those contractors who repair or install coolers, refrigerated casework, ice-making machines, drinking fountains, cold room equipment, and similar hermetic refrigeration equipment. The HVA classification also provides for this function.

"Roofing contracting" (Abbr: ROC) means the service that provides for the installation, repair, removal, or improvement of materials common to the industry that form a watertight, weather resistant surface for roofs and decks. This includes roofing system components when installed in conjunction with a roofing project, application of dampproofing or waterproofing, and installation of roof insulation panels and other roof insulation systems above roof deck. The CBC and RBC classifications and the HIC and CIC specialties also provide for this function.

"Sewage disposal systems contracting" (Abbr: SDS) means the service that provides for the installation, repair, improvement, or removal of septic tanks, septic systems, and other onsite sewage disposal systems annexed to real property.

"Steel erection contracting" (Abbr: STL) means the service that provides for the fabrication and erection of structural steel shapes and plates, regardless of shape or size, to be used as structural members, or tanks, including any related riveting, welding, and rigging. This specialty includes the fabrication, placement and tying of steel reinforcing bars (rods), and post-tensioning to reinforce concrete buildings and structures. The CBC and RBC classifications and HIC and CIC specialties also provide for this function.

"Swimming pool construction contracting" (Abbr: POL) means the service that provides for the construction, repair, improvement, or removal of in-ground swimming pools. The CBC and RBC classifications and the RFC specialty also provide for this function. No trade related plumbing, electrical, backflow, or HVAC work is included in this specialty.

"Tile, marble, ceramic, and terrazzo contracting" (Abbr: TMC) means the service that provides for the preparation, fabrication, construction, and installation of artificial marble, burned clay tile, ceramic, terrazzo, encaustic, faience, quarry, semi-vitreous, cementitious board, and other tile, excluding hollow or structural partition tile. The CBC and RBC classifications and HIC and CIC specialties also provide for this function.

"Underground utility and excavating contracting" (Abbr [ : ] UUC) means the service that provides for the construction, repair, improvement, or removal of main sanitary sewer collection systems, main water distribution systems, storm sewer collection systems, and the continuation of utility lines from the main systems to a point of termination up to and including the meter location for the individual occupancy, sewer collection systems at property line, or residential or single-occupancy commercial properties, or on multi-occupancy properties at manhole or wye lateral extend to an invert elevation as engineered to accommodate future building sewers, water distribution systems, or storm sewer collection systems at storm sewer structures. This specialty may install empty underground conduits in rights-of way, easements, platted rights-of-way in new site development, and sleeves for parking lot crossings if each conduit system does not include installation of any conductor wiring or connection to an energized electrical system. The H/H classification also provides for this function.

"Vessel construction contracting" (Abbr: VCC) means the service that provides for the construction, repair, improvement, or removal of nonresidential vessels, tanks, or piping that hold or convey fluids other than sanitary, storm, waste, or potable water supplies. The H/H classification also provides for this function.

"Water well/pump contracting" (Abbr: WWP) means the service that provides for the installation of a water well system, including geothermal wells, which includes construction of a water well to reach groundwater, as defined in § 62.1-255 of the Code of Virginia, and the installation of the well pump and tank, including pipe and wire, up to and including the point of connection to the plumbing and electrical systems. No other classification or specialty service provides for construction of water wells. This regulation shall not exclude the PLB, ELE, or HVA classification from installation of pumps and tanks.

Note: Specialty contractors engaging in construction that involves the following activities or items or similar activities or items may fall under the CIC, HIC, and FIC specialty services, or they may fall under the CBC or RBC classification.

Appliances	Fences	Railings
Awnings	Fiberglass	Rigging
Blinds	Fireplaces	Rubber linings
Bulkheads	Fireproofing	Sandblasting
Carpeting	Fixtures	Scaffolding
Ceilings	Grouting	Screens
Chimneys	Guttering	Shutters
Chutes	Interior decorating	Siding
Curtains	Lubrication	Skylights
Curtain walls	Metal work	Storage bins and lockers
Decks	Millwrighting	Stucco
Doors	Mirrors	Vaults
Drapes	Miscellaneous iron	Wall panels
Epoxy	Ornamental iron	Waterproofing
Exterior decoration	Partitions	Windows
Facings	Protective coatings

Part II
Entry

18VAC50-22-40. Requirements for a Class C license.

A. A firm applying for a Class C license must meet the requirements of this section.

B. For every classification or specialty in which the firm seeks to be licensed, the firm shall name a qualified individual who meets the following requirements:

1. Is at least 18 years old;

2. Has a minimum of two years experience in the classification or specialty for which he is the qualifier;

3. Is a full-time employee of the firm as defined in this chapter or is a member of the responsible management of the firm; and

4. a. Has obtained the appropriate certification for the following specialties:

(1) Blast/explosive contracting (Department of Fire Programs explosive use certification),

(2) Fire sprinkler (NICET Sprinkler III certification), and

(3) Radon mitigation (EPA or DEQ accepted radon certification).

b. Has obtained, pursuant to the Individual Licensing and Certification Regulations, a master license for Plumbing, HVAC, Electrical, Gas Fitting, Natural Gas Fitting Provider, and Liquefied Petroleum Gas Contracting.

c. Has completed, for the drug lab remediation specialty, a remediation course approved by the board and a board-approved examination.

c. d. Has obtained, pursuant to the Individual Licensing and Certification Regulations, certification as an Elevator Mechanic for Elevator Escalator Contracting and certification as a Water Well Systems Provider for Water Well/Pump Contracting.

d. e. Has completed a board-approved examination for all other classifications and specialties that do not require other certification or licensure.

C. The firm shall provide information for the past five years prior to application on any outstanding, past-due debts and judgments; outstanding tax obligations; defaults on bonds; or pending or past bankruptcies. The firm and all members of the responsible management of the firm shall submit information on any past-due debts and judgments or defaults on bonds directly related to the practice of contracting as defined in Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia.

D. The firm and all members of the responsible management of the firm shall disclose at the time of application any current or previous contractor licenses held in Virginia or in other jurisdictions and any disciplinary actions taken on these licenses. This includes but is not limited to any monetary penalties, fines, suspensions, revocations, surrender of a license in connection with a disciplinary action, or voluntary termination of a license in Virginia or in any other jurisdiction.

E. In accordance with § 54.1-204 of the Code of Virginia, all applicants shall disclose the following information about the firm, all members of the responsible management, and the qualified individual or individuals for the firm:

1. All misdemeanor convictions within three years of the date of application; and

2. All felony convictions during their lifetimes.

Any plea of nolo contendere shall be considered a conviction for purposes of this subsection. The record of a conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt. The board, in its discretion, may deny licensure to any applicant in accordance with § 54.1-204 of the Code of Virginia.

F. A member of responsible management shall have successfully completed a board-approved basic business course.

18VAC50-22-50. Requirements for a Class B license.

A. A firm applying for a Class B license must meet the requirements of this section.

B. A firm shall name a designated employee who meets the following requirements:

1. Is at least 18 years old;

2. Is a full-time employee of the firm as defined in this chapter, or is a member of responsible management as defined in this chapter;

3. Has passed a board-approved examination as required by § 54.1-1108 of the Code of Virginia or has been exempted from the exam requirement in accordance with § 54.1-1108.1 of the Code of Virginia; and

4. Has followed all rules established by the board or by the testing service acting on behalf of the board with regard to conduct at the examination. Such rules shall include any written instructions communicated prior to the examination date and any oral or written instructions given at the site on the date of the exam.

C. For every classification or specialty in which the firm seeks to be licensed, the firm shall name a qualified individual who meets the following requirements:

1. Is at least 18 years old;

2. Has a minimum of three years experience in the classification or specialty for which he is the qualifier;

3. Is a full-time employee of the firm as defined in this chapter or is a member of the responsible management of the firm;

4. a. Has obtained the appropriate certification for the following specialties:

(1) Blast/explosive contracting (Department of Fire Programs explosive use certification),

(2) Fire sprinkler (NICET Sprinkler III certification), and

(3) Radon mitigation (EPA or DEQ accepted radon certification).

b. Has obtained, pursuant to the Individual Licensing and Certification Regulations, a master license for Plumbing, HVAC, Electrical, Gas Fitting, Natural Gas Fitting Provider, and Liquefied Petroleum Gas Contracting.

c. Has completed, for the drug lab remediation specialty, a remediation course approved by the board and a board-approved examination.

c. d. Has obtained, pursuant to the Individual Licensing and Certification Regulations, certification as an Elevator Mechanic for Elevator Escalator Contracting and certification as a Water Well Systems Provider for Water Well/Pump Contracting.

d. e. Has completed a board-approved examination for all other classifications and specialties that do not require other certification or licensure.

D. Each firm shall submit information on its financial position. Excluding any property owned as tenants by the entirety, the firm shall state a net worth or equity of $15,000 or more.

E. Each firm shall provide information for the five years prior to application on any outstanding, past-due debts and judgments; outstanding tax obligations; defaults on bonds; or pending or past bankruptcies. The firm, its designated employee, and all members of the responsible management of the firm shall submit information on any past-due debts and judgments or defaults on bonds directly related to the practice of contracting as defined in Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia.

F. The firm, the designated employee, and all members of the responsible management of the firm shall disclose at the time of application any current or previous substantial identities of interest with any contractor licenses issued in Virginia or in other jurisdictions and any disciplinary actions taken on these licenses. This includes but is not limited to any monetary penalties, fines, suspension, revocation, or surrender of a license in connection with a disciplinary action. The board, in its discretion, may deny licensure to any applicant when any of the parties listed above in this subsection have had a substantial identity of interest (as deemed in § 54.1-1110 of the Code of Virginia) with any firm that has had a license suspended, revoked, voluntarily terminated or surrendered in connection with a disciplinary action in Virginia or any other jurisdiction.

G. In accordance with § 54.1-204 of the Code of Virginia, all applicants shall disclose the following information about the firm, designated employee, all members of the responsible management, and the qualified individual or individuals for the firm:

1. All misdemeanor convictions within three years of the date of application; and

2. All felony convictions during their lifetimes.

Any plea of nolo contendere shall be considered a conviction for purposes of this subsection. The record of a conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt. The board, in its discretion, may deny licensure to any applicant in accordance with § 54.1-204 of the Code of Virginia.

H. The designated employee or a member of responsible management shall have successfully completed a board-approved basic business course.

18VAC50-22-60. Requirements for a Class A license.

A. A firm applying for a Class A license shall meet all of the requirements of this section.

B. A firm shall name a designated employee who meets the following requirements:

1. Is at least 18 years old;

2. Is a full-time employee of the firm as defined in this chapter or is a member of the responsible management of the firm as defined in this chapter;

3. Has passed a board-approved examination as required by § 54.1-1106 of the Code of Virginia or has been exempted from the exam requirement in accordance with § 54.1-1108.1 of the Code of Virginia; and

4. Has followed all rules established by the board or by the testing service acting on behalf of the board with regard to conduct at the examination. Such rules shall include any written instructions communicated prior to the examination date and any oral or written instructions given at the site on the day of the exam.

C. For every classification or specialty in which the firm seeks to be licensed, the firm shall name a qualified individual who meets the following requirements:

1. Is at least 18 years old;

2. Has a minimum of five years of experience in the classification or specialty for which he is the qualifier;

3. Is a full-time employee of the firm as defined in this chapter or is a member of the firm as defined in this chapter or is a member of the responsible management of the firm;

4. a. Has obtained the appropriate certification for the following specialties:

(1) Blast/explosive contracting (DHCD explosive use certification),

(2) Fire sprinkler (NICET Sprinkler III certification), and

(3) Radon mitigation (EPA or DEQ accepted radon certification).

b. Has obtained, pursuant to the Individual Licensing and Certification Regulations, a master license for Plumbing, HVAC, Electrical, Gas Fitting, Natural Gas Fitting Provider, and Liquefied Petroleum Gas Contracting.

c. Has completed, for the drug lab remediation specialty, a remediation course approved by the board and a board-approved examination.

c. d. Has obtained, pursuant to the Individual Licensing and Certification Regulations, certification as an Elevator Mechanic for Elevator Escalator Contracting and certification as a Water Well Systems Provider for Water Well/Pump Contracting.

d. e. Has completed a board-approved examination for all other classifications and specialties that do not require other certification or licensure.

D. Each firm shall submit information on its financial position. Excluding any property owned as tenants by the entirety, the firm shall state a net worth or equity of $45,000.

E. The firm shall provide information for the five years prior to application on any outstanding, past-due debts and judgments; outstanding tax obligations; defaults on bonds; or pending or past bankruptcies. The firm, its designated employee, and all members of the responsible management of the firm shall submit information on any past-due debts and judgments or defaults on bonds directly related to the practice of contracting as defined in Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia.

F. The firm, the designated employee, and all members of the responsible management of the firm shall disclose at the time of application any current or previous substantial identities of interest with any contractor licenses issued in Virginia or in other jurisdictions and any disciplinary actions taken on these licenses. This includes but is not limited to, any monetary penalties, fines, suspensions, revocations, or surrender of a license in connection with a disciplinary action. The board, in its discretion, may deny licensure to any applicant when any of the parties listed above in this [ subdivision subsection ] have had a substantial identity of interest (as deemed in § 54.1-1110 of the Code of Virginia) with any firm that has had a license suspended, revoked, voluntarily terminated, or surrendered in connection with a disciplinary action in Virginia or in any other jurisdiction.

G. In accordance with § 54.1-204 of the Code of Virginia, all applicants shall disclose the following information about the firm, all members of the responsible management, the designated employee, and the qualified individual or individuals for the firm:

1. All misdemeanor convictions within three years of the date of application; and

2. All felony convictions during their lifetimes.

Any plea of nolo contendere shall be considered a conviction for purposes of this subsection. The record of a conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt. The board, in its discretion, may deny licensure to any applicant in accordance with § 54.1-204 of the Code of Virginia.

H. The designated employee or a member of responsible management shall have successfully completed a board-approved basic business course.

18VAC50-22-260. Filing of charges; prohibited acts.

A. All complaints against contractors and residential building energy analyst firms may be filed with the Department of Professional and Occupational Regulation at any time during business hours, pursuant to § 54.1-1114 of the Code of Virginia.

B. The following acts are prohibited acts:

1. Failure in any material way to comply with provisions of Chapter 1 (§ 54.1-100 et seq.) or Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia or the regulations of the board.

2. Furnishing substantially inaccurate or incomplete information to the board in obtaining, renewing, reinstating, or maintaining a license.

3. Failure of the responsible management, designated employee, or qualified individual to report to the board, in writing, the suspension or revocation of a contractor license by another state or conviction in a court of competent jurisdiction of a building code violation.

4. Publishing or causing to be published any advertisement relating to contracting which that contains an assertion, representation, or statement of fact that is false, deceptive, or misleading.

5. Negligence and/or or incompetence in the practice of contracting or residential building energy analyses.

6. Misconduct in the practice of contracting or residential building energy analyses.

7. A finding of improper or dishonest conduct in the practice of contracting by a court of competent jurisdiction or by the board.

8. Failure of all those who engage in residential contracting, excluding subcontractors to the contracting parties and those who engage in routine maintenance or service contracts, to make use of a legible written contract clearly specifying the terms and conditions of the work to be performed. For the purposes of this chapter, residential contracting means construction, removal, repair, or improvements to single-family or multiple-family residential buildings, including accessory-use structures as defined in § 54.1-1100 of the Code of Virginia. Prior to commencement of work or acceptance of payments, the contract shall be signed by both the consumer and the licensee or his agent.

9. Failure of those engaged in residential contracting as defined in this chapter to comply with the terms of a written contract which that contains the following minimum requirements:

a. When work is to begin and the estimated completion date;

b. A statement of the total cost of the contract and the amounts and schedule for progress payments including a specific statement on the amount of the down payment;

c. A listing of specified materials and work to be performed, which is specifically requested by the consumer;

d. A "plain-language" exculpatory clause concerning events beyond the control of the contractor and a statement explaining that delays caused by such events do not constitute abandonment and are not included in calculating time frames timeframes for payment or performance;

e. A statement of assurance that the contractor will comply with all local requirements for building permits, inspections, and zoning;

f. Disclosure of the cancellation rights of the parties;

g. For contracts resulting from a door-to-door solicitation, a signed acknowledgment by the consumer that he has been provided with and read the Department of Professional and Occupational Regulation statement of protection available to him through the Board for Contractors;

h. Contractor's name, address, license number, class of license, and classifications or specialty services;

i. A statement providing that any modification to the contract, which changes the cost, materials, work to be performed, or estimated completion date, must be in writing and signed by all parties; and

j. Effective with all new contracts entered into after July 1, 2015, a statement notifying consumers of the existence of the Virginia Contractor Transaction Recovery Fund that includes information on how to contact the board for claim information.

10. Failure to make prompt delivery to the consumer before commencement of work of a fully executed copy of the contract as described in subdivisions 8 and 9 of this subsection for construction or contracting work.

11. Failure of the contractor to maintain for a period of five years from the date of contract a complete and legible copy of all documents relating to that contract, including, but not limited to, the contract and any addenda or change orders.

12. Refusing or failing, upon request, to produce to the board, or any of its agents, any document, book, record, or copy of it in the licensee's possession concerning a transaction covered by this chapter or for which the licensee is required to maintain records.

13. Failing to respond to an agent of the board or providing false, misleading or incomplete information to an investigator seeking information in the investigation of a complaint filed with the board against the contractor. Failing or refusing to claim certified mail sent to the licensee's address of record shall constitute a violation of this regulation.

14. Abandonment defined as the unjustified cessation of work under the contract for a period of 30 days or more.

15. The intentional and unjustified failure to complete work contracted for and/or or to comply with the terms in the contract.

16. The retention or misapplication of funds paid, for which work is either not performed or performed only in part.

17. Making any misrepresentation or making a false promise that might influence, persuade, or induce.

18. Assisting another to violate any provision of Chapter 1 (§ 54.1-100 et seq.) or Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia, or this chapter; or combining or conspiring with or acting as agent, partner, or associate for another.

19. Allowing a firm's license to be used by another.

20. Acting as or being an ostensible licensee for undisclosed persons who do or will control or direct, directly or indirectly, the operations of the licensee's business.

21. Action by the firm, responsible management as defined in this chapter, designated employee or qualified individual to offer, give, or promise anything of value or benefit to any federal, state, or local employee for the purpose of influencing that employee to circumvent, in the performance of his duties, any federal, state, or local law, regulation, or ordinance governing the construction industry.

22. Where the firm, responsible management as defined in this chapter, designated employee or qualified individual has been convicted or found guilty, after initial licensure, regardless of adjudication, in any jurisdiction, of any felony or of any misdemeanor, there being no appeal pending therefrom or the time of appeal having elapsed. Any plea of guilty or nolo contendere shall be considered a conviction for the purposes of this subdivision. The record of a conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt.

23. Failure to inform the board in writing, within 30 days, that the firm, a member of responsible management as defined in this chapter, its designated employee, or its qualified individual has pleaded guilty or nolo contendere or was convicted and found guilty of any felony or of a Class 1 misdemeanor or any misdemeanor conviction for activities carried out while engaged in the practice of contracting.

24. Having been disciplined by any county, city, town, or any state or federal governing body including action by the Virginia Department of Health, which action shall be reviewed by the board before it takes any disciplinary action of its own.

25. Failure to abate a violation of the Virginia Uniform Statewide Building Code, as amended.

26. Failure of a contractor to comply with the notification requirements of the Virginia Underground Utility Damage Prevention Act, Chapter 10.3 (§ 56-265.14 et seq.) of Title 56 of the Code of Virginia (Miss Utility).

27. Practicing in a classification, specialty service, or class of license for which the contractor is not licensed.

28. Failure to satisfy any judgments.

29. Contracting with an unlicensed or improperly licensed contractor or subcontractor in the delivery of contracting services.

30. Failure to honor the terms and conditions of a warranty.

31. Failure to obtain written change orders, which are signed by both the consumer and the licensee or his agent, to an already existing contract.

32. Failure to ensure that supervision, as defined in this chapter, is provided to all helpers and laborers assisting licensed tradesman.

33. Failure to obtain a building permit or applicable inspection, where required.

34. Failure of a residential building energy analyst firm to ensure that residential building energy analyses conducted by the firm are consistent with the requirements set forth by the board, the U.S. Environmental Protection Agency, the U.S. Department of Energy, or the Energy Star Program.

35. Failure of a residential building energy analyst firm to maintain the general liability insurance required in 18VAC50-22-62 C at any time while licensed by the board.

36. Failure of a contractor holding the drug lab remediation specialty to ensure that remediation work conducted by the firm or properly licensed subcontractors is consistent with the guidelines set forth by the U.S. Environmental Protection Agency, Virginia Department of Environmental Quality, Virginia Department of Health, or Virginia Department of Forensic Science.

[ FORMS (18VAC50-22)

Contractor Licensing Information, A501-27INTRO-v4 (rev. 1/2016)

Requirements for Qualified Individuals, A501-27EXINFO-v5 (rev. 1/2016)

Contractor's License Application, A501-27LIC-v7 (rev. 1/2016)

Additional Specialty Designation Application, A501-27ADDSP-v7 (rev. 1/2016)

Contractor's License Application, A501-27LIC-v10 (rev. 1/2018)

Additional Specialty Designation Application, A501-27ADDSP-v10 (rev. 1/2018)

Adverse Financial History Reporting Form, A406-01AFIN-v1 (eff. 2/2015)

Change in Qualified Individual and Designated Employee Application, A501-27CH_QIDE-v7 (rev. 1/2016)

Change in Qualified Individual and Designated Employee Application, A501-27CH_QIDE-v9 (rev. 1/2018)

Change of Responsible Management Application, A501-27CHRM-v4 (rev. 1/2016)

Certificate of License Termination, A501-27TERM-v4 (rev. 12/2015)

Criminal Conviction Reporting Form, A406-01CCR-v1 (eff. 5/2015)

Disciplinary Action Reporting Form, A406-01DAR-v1 (eff. 5/2015)

Education Provider Registration/Course Approval Application, A501-27EDREG-v5 (rev. 1/2014)

Education Provider Listing Application, A501-27EDLIST-v4 (rev. 1/2014)

Financial Statement, A501-27FINST-v4 (rev. 12/2012)

Change in License Class Application, A501-27CHLIC-v7 (rev. 1/2016)

Change in License Class Application, A501CHLIC-v9 (rev. 1/2018)

Firm - Residential Building Energy Analyst Application, A501-2707LIC-v2 (rev. 7/2013)

Statement of Consumer Protections, RBC-9.1 (rev. 12/2014)

Contractor's Temporary License Application, A501-2703LIC-v2 (rev. 1/2016)

Contractor Temporary License Application, A501-2703LIC-v8 (rev. 1/2018)

Expedited Class A License Application, A501-2705A-v11 (rev. 1/2018) ]